KBR Annual Report 2012 | Quarterlytics

← All annual reports

FY2012 Annual Report · KBR

Loading PDF…

We Deliver 2012 Annual Report

2012 Awards & Achievements

KBR Ranked First in the Houston Business Journal’s Top Energy
Engineering Firms

KBR Building Group Won Four Engineering News-Record Southeast’s
“Best of 2012” Awards

KBR Ranked Fifth in the Engineering News-Record’s Top 400 Contractors

KBR Ranked Fifth in Modern Healthcare’s Largest Healthcare Construction
Services Providers

KBR Ranked Ninth in the Engineering News-Record’s Top 500 Design Firms

KBR Ranked Sixteenth in Washington Technology Magazine’s Top 100
Federal Contractors

KBR International Government, Defence and Support Services Won Two
Royal Society for the Prevention of Accidents Gold Safety Awards (Third
Consecutive Year)

KBR Building Group Won Six Associated Builders & Contractors Eagle
Awards for Excellence in Construction

KBR U.K. IMPACT Teams Won the Engineering Construction Industry Training
Board Active Cup and Gold-Level Award

KBR Infrastructure Won Consult Australia’s “Award of Excellence” in
the Export Category for the Australia Coal Connect Rail Line

KBR London Awarded Gold Partner Status for the Institution of
Chemical Engineers

KBR’s 6th Annual Charity Golf Tournament Raised $400,000 for 12 Charities

Team KBR Raised $100,000 at the BP MS 150 (Charity Bike Ride Supporting the
National Multiple Sclerosis Society)

Global Presence

KBR employs more than 27,000 people worldwide in locations that include North America, Australia, Africa, Europe, Asia and the

Middle East. We deliver a wide range of services supporting the energy, hydrocarbon, power, industrial, civil infrastructure, minerals,

government services and commercial markets.

Since our founding over 110 years ago, KBR has differentiated itself as a globally focused, technology-driven engineering, procurement

and construction company. KBR has built a proud history and leading market positions by being a high value and reliable service provider

to our diverse customer base.

Our track record has proven that regardless of the challenges, we deliver the work that is expected of us. Regardless of the size,

complexity, difficulty, remoteness or harsh environment, we deliver.

KBR employees come to work every day with a commitment to KBR’s values: An uncompromising commitment to Quality, Health,

Safety and Environment; an open relationship with our employees based on mutual Trust, Respect and Success; a commitment to

Transparency, Accountability and Discipline in our business; a focus on Best in Class Risk Awareness; demonstrating Integrity in

all we do; and Financial Responsibility to our stakeholders.

William P. Utt

Chairman, President

and Chief Executive

Officer

To My Fellow Shareholders:
2012 was a disappointing year for KBR. Our
financial performance was far below our
expectations. Our standards for performance are
much higher than what we achieved, and all of
KBR’s 27,000 employees are universally committed
to living up to that higher standard.

Despite disappointing 2012 performance, we
maintained our unwavering focus on the long-term
health of the enterprise and on the tremendous
global opportunities we have in front of us across
our 14 market-facing businesses. We continued
to build a strong platform for growth, leveraging
our broad geographic footprint, extensive
capabilities and strong customer relationships
to solidify our market positions and to win, or
advance our position on, a number of strategically
significant awards.

During 2012, our stock price increased 7% and we
also returned $77 million in cash to shareholders,
representing $40 million in share repurchases and
$37 million in dividend payments. Additionally,
during the fourth quarter, the Board of Directors
approved a 60% dividend increase beginning in the
first quarter of 2013, demonstrating our confidence
in the company going forward.

Financial and Business Highlights
Our earnings per diluted share were $0.97, which
included a negative impact of $1.19 per diluted
share related to a non-cash goodwill impairment
charge in our Minerals Business Unit. Net income
attributable to KBR was $144 million. Excluding the
goodwill impairment charge, earnings per share
were $2.16.

Revenue decreased by 14% during the year, driven
primarily by expected declines related to LogCap
work in Iraq. Excluding LogCap, revenues were
up 2%. Overall revenue backlog also grew 37%,
reflecting the strength of the underlying business
and the significant opportunities ahead for KBR.

Leveraging Our Diverse Platform
We continue to have a broad and diversified platform
of businesses to reliably deliver the most complex
projects in the world. In 2012, we had a number
of successes across our three primary Business
Groups: Hydrocarbons, Infrastructure, Government
and Power (IGP) and Services. In our Hydrocarbons
Business Group, KBR, along with our joint venture
partners, signed the EPC contract for the Ichthys

LNG project in Northern Australia which will be
one of the world’s largest LNG facilities. We
continue to pursue expanded roles as an EPC
contractor for additional onshore and offshore
projects as well as leverage our LNG and offshore
engineering capabilities to capture growing floating
LNG opportunities. Low-priced natural gas in the
U.S. is also creating strong market fundamentals
for the LNG, GTL, ammonia, power and chemicals
markets, which allows KBR to utilize its EPC
expertise and world-renowned technologies to
deliver projects in these important and rapidly
expanding markets. In our Technology Business Unit,
we saw another year of record sales and profits.

In our IGP Group, efforts to build our capabilities as
a full EPC provider in the power arena paid off as
we were awarded over $500 million in new work
in 2012. The infrastructure and minerals markets
remain challenged as customers re-evaluate their
global capital expenditures, but we remain well
positioned for growth as these markets improve.
The Middle East, however, is an exciting and
diversified area for new infrastructure projects,
from roads and bridges to rail and airports. In
our government businesses, we are diversifying
into more peace-time initiatives and expanding
our industrial customer base, while utilizing the
capabilities and expertise we built while providing
contingency, logistics and life support services
in war environments.

Our Services Business Group had a strong year
in Canada, with $1 billion in new awards in 2012
largely driven by robust activity in the Canadian oil
sands. In our operations and maintenance business
we continue to have a strong U.S. presence, and
we have also strategically expanded our business
internationally with a key contract in the Middle
East. Additionally, as the U.S. shows promising
signs of economic recovery, we anticipate an
improving climate for commercial and residential
building construction in the region. Low-cost shale
gas in the U.S. is also setting the stage for ample
opportunities within our construction business
across a number of commercial markets.

KBR Around the World
KBR seeks opportunities to continue to increase the
vertical integration of our EPC delivery capabilities
in order to take customer projects from initial concept
to EPC and into operations and maintenance.

We are a global business, and the challenges we
face are unique in every corner of the world. KBR
has continued to deploy key executive resources
to strategically important international locations to
better serve our customers and to be closer to our
projects. During 2011 and 2012, we established
regional Presidents both in the Australia-Asia
region and in the Middle East region. These leaders
are working with the Business Group and Unit
Presidents to support all aspects of their business
in the region, including key sales pursuits, partner
relationships and regional strategy implementation.

Also in 2012, KBR relocated its Operations’
headquarters to London from Houston, further
enhancing our global presence. This move
enhances our global oversight and proximity to
our employees and our projects.

KBR Culture and People
At KBR, we live by this simple truth: We Deliver.
We are experts in delivering the world’s largest
and most complex projects. And we continue to
safely and consistently deliver capital projects and
services anywhere in the world, creating value for
our customers.

KBR’s performance and growth are intrinsically
linked with the communities in which we operate.
Our projects generate new jobs and support local
businesses around the world. Our community
engagement programs are strategic investments in
building stronger communities for the future.

The strongest commitment we can make to our
people is to achieve our goal of an incident- and
injury-free workplace anywhere KBR employees
perform work. To continuously improve our safety
record as we work toward our goal of zero
incidents, we have developed systems and
processes that have helped drive down injury
rates to industry-leading levels.

A Brighter Future
KBR’s hard work continues to build on a business
foundation that will deliver consistent, profitable,
long-term growth. We strive to be the world’s
Contractor and Employer of Choice, and I want to
thank each of our 27,000 plus employees for every-
thing they have done to realize our many significant
achievements in 2012. These achievements were
only made possible through the teamwork and
efforts of our loyal and dedicated employees.

We derive our culture of integrity and ingenuity
from the likes of George and Herman Brown, Dan
Root, and Morris W. Kellogg; in fact, the word
“impossible” was simply unknown to them. As I
look ahead to 2013, we will continue to build on
our reputation that’s been established over the last
110 plus years so that KBR continues to contribute
to global economic expansion, building stronger
communities and creating enduring value for our
shareholders.

Very truly yours,

William P. Utt
Chairman, President and
Chief Executive Officer
April 2013

H Y D R O C A R B O N S

Fueled by strong industry fundamentals, economic growth in developing
nations and solid project execution performance, all four of KBR’s
Hydrocarbons Business Units turned in solid financial and operating results
in 2012. At the same time, we worked to enhance our future opportunities
by expanding our global footprint, adding new capabilities and increasing the
vertical integration of our businesses. We are exceptionally well positioned
to capitalize on continued strength in key international markets and a rebirth
of opportunities in North America. As we expand our business in diverse
regions, we will maintain our industry-leading commitment to health, safety
and the environment to constantly reinforce our standards and strive for an
injury- and incident-free workplace.

Gas Monetization
KBR is a recognized leader in designing and constructing multi-billion dollar
liquefied natural gas (LNG) and gas-to-liquids (GTL) plants that convert the
world’s abundant natural gas resources into products that are commercially
viable and easily transportable. Continued strong execution on existing projects
and growing contributions from an engineering, procurement and construction
(EPC) contract awarded early in the year drove income growth and margin
improvement for our Gas Monetization Business Unit during 2012.

Throughout the year, we continued to achieve milestones on projects at all
stages of development. By year-end, construction was winding down at the
Skikda LNG project in Algeria and at the Escravos GTL project in Nigeria,
with commissioning of both plants on track for early 2013. The Gorgon LNG
project located on Barrow Island, an environmentally sensitive area off the
Australian coast, is being constructed with the utmost care to minimize its
impact on the Barrow Island nature reserve under a unique quarantine plan
that has been rated world class by the Western Australian Environmental
Protection Agency.

We continued our participation at the Ichthys LNG project in Northern
Australia in early 2012 with the award of an EPC contract valued at
approximately $15 billion. The JKC joint venture, which includes JGC, KBR
and Chiyoda, received the EPC award after performing the FEED work for
the project. Our teams are at work in Yokohama, Perth and Darwin, with
fabrication yards in Thailand and China. When complete, the plant, owned
by INPEX and Total, will receive natural gas from the Ichthys Field in the
Browse Basin 200 miles offshore Western Australia via a 553-mile subsea
pipeline and process it to produce LNG, LPG and condensate.

Looking ahead, we continue to have a robust pipeline of projects globally
with numerous pre-FEED and FEED contracts that position us well for future
EPC opportunities. We are pleased with the increasing geographic diversity
of our project portfolio. While the last few years in our LNG business have
been Australia-centric, Gas Monetization opportunities are spreading into
other regions of the world including North America where shale gas is
providing an abundant and attractively priced feedstock for LNG and GTL
facilities. We have numerous prospective projects in emerging regions for
Gas Monetization, including East Africa, Canada and the United States, that
we anticipate will move forward over the next several years.

Oil & Gas
In the Oil & Gas Business Unit, KBR is expanding an already broad geographic
footprint, extending its participation in projects beyond the engineering
phase and into full EPC, and establishing a strong position in floating
liquefied natural gas (FLNG), a promising new market for the industry. During
2012, we made significant progress on the Big Foot and Jack St. Malo
projects in the Gulf of Mexico and the Quad 204 project in the North Sea.

The contract, awarded in November 2012 by GDF SUEZ Bonaparte Pty. Ltd.,
pre-qualifies KBR as a contender for the FEED and EPC delivery phases of
the project.

Well recognized as a leading provider of floating production, storage and
offloading vessels (FPSO), KBR also won a contract to perform FEED work
for the topsides and hull of an FPSO vessel to be located offshore Angola.
The project will draw on KBR’s recently established Luanda office to provide
local content.

Building on a long-standing relationship with BP, we continue to extend
our success in the Caspian Sea. We have steadily expanded our role at
BP’s Shah Deniz II project where we are transitioning from FEED work to
engineering, procurement and construction management for the onshore
and offshore project facilities. We believe the Caspian region, where we
have already completed 10 million man-hours of work, represents a long-
term pipeline of substantial business. During 2012, BP also selected KBR to
provide engineering and project management services for its Project 20K™,
a multi-year corporate initiative to pursue, with technology providers, the
development of systems needed to exploit energy resources from extremely
high-temperature, high-pressure reservoirs.

KBR has a substantial pipeline of offshore work and promising opportunities
in FLNG, an emerging area of opportunity for the industry. Our consulting
subsidiaries, Granherne, GVA and Energo, continue to play a key role in
accessing oil and gas projects at the very earliest stages as a foundation
for extending our involvement and building a position as a full-service EPC
contractor to the offshore industry.

Downstream
During 2012, KBR’s Downstream Business Unit benefited from a resurgence
of ammonia and chemical activity in the U.S., increased demand for fertilizer
plants spurred by economic recovery in developing nations and an expanded
role on major projects in the Middle East that progressed to the execution
phase during the year. In addition, we captured numerous opportunities to
bundle our proprietary technologies with our Downstream EPC capabilities to
provide an integrated offering.

Attracted by ample supplies of low-cost shale gas, our Downstream
customers are increasing their focus back to the U.S. when planning new
projects. During 2012, we brought two U.S. projects, the BP Toledo Refinery
and the KiOR, Inc. biomass-to-renewable fuels facility, to a successful
conclusion, and we continued building our pipeline of domestic downstream
opportunities. Under a contract awarded by DuPont’s Industrial Biosciences
Group, we will provide engineering and procurement services for a facility
that will produce an ethanol product using corn waste as a feedstock.
A number of FEED projects currently underway will lay the groundwork for
domestic EPC awards in early 2013.

In Saudi Arabia, where much of KBR’s Downstream business has
traditionally been concentrated, work progressed on plan at the Sadara
chemical complex, and the Yanbu and Jazan refineries. In November,
we received a new contract to execute FEED work for an integrated
gasification combined cycle (IGCC) project near Jazan Economic City, Saudi
Arabia. When complete, the IGCC complex, which will convert vacuum
residue into electricity, will be the largest gasifier-based power facility in
the world. Our KBR-AMCDE engineering joint venture in Saudi Arabia is
performing well as a platform for expanding our position and opportunities
in the region.

Drawing on its extensive capabilities in global offshore engineering as well
as onshore LNG EPC delivery, KBR won an award for design work on the
FLNG production vessel for the Bonaparte project offshore Darwin, Australia.

We capitalized on synergies between our Downstream and Technology busi-
nesses to provide an integrated technology, engineering procurement and
construction solution for several projects. One such project, the Uz-Kor Gas

KBR’s Hydrocarbons Group’s four Business

Units combine their intellectual property and

EPC project execution capability to safely

deliver capital projects across the complete

spectrum of the industry, including offshore oil

and gas production facilities and world-scale

LNG and GTL, refining and chemical projects.

Chemical ethylene plant in Uzbekistan will utilize KBR’s proprietary SCORE™
(Selective Cracking and Optimum Recovery) technology to optimize product
yield and reduce energy usage. A new ethylene furnace, to be designed
and constructed for the INEOS olefins complex in Texas, will incorporate
SCORE™ as well as several technologies to reduce nitrous oxide emissions.

We see global strength in our Downstream business continuing into 2013,
with robust demand for ammonia and ethylene plus the emergence of some
large petrochemical opportunities.

Technology
A consistently strong performer, KBR’s Technology Business Unit continued
on a growth trajectory with both sales and profit growth exceeding
20% in 2012. Driven by a resurgence in the U.S. for ammonia projects and
a rebound in demand for fertilizer facilities in developing nations,
ammonia was the leading driver of outstanding 2012 results.

Under a contract from Iowa Fertilizer Company, KBR will provide technology
licensing, engineering services and proprietary equipment for the first world-
scale ammonia plant to be built in the U.S. in nearly a quarter century.
The 2,200 metric-tons-per-day ammonia plant, part of a grassroots fertilizer
facility in Iowa, will utilize KBR’s Purifier™ technology to achieve reliability
as well as the lowest proven energy consumption. This milestone for the
North American fertilizer industry illustrates the tremendous potential of
low-cost natural gas to drive domestic demand. Our Purifier™ technology
will also be utilized in two grassroots ammonia plants in Indonesia where

KBR has licensed a total of 13 plants, as well as at a world-scale
fertilizer complex in Nigeria, one of the largest emerging markets for the
fertilizer business.

A contract to establish a Veba Combi Cracker (VCC™) processing unit
in Russia marks the third unit of its kind under construction, the first in
Russia and KBR’s largest VCC™ project award since acquiring rights to the
technology in January 2010. We are providing licensing and engineering
services for the implementation of the VCC™ technology which converts
petroleum residues into high-value products at a refinery in the Republic
of Tatarstan, Russia.

With an excellent inventory of intellectual property and a strong global sales
organization, offices in key regions of the world and four global technology
centers, we continue working to expand our portfolio of technology offerings
through alliances as well as acquisitions. During 2012, we expanded a global
marketing alliance with Shell Global Solutions International B.V. to include a
much broader scope of their value-focused refinery technologies. Under an
agreement with a Southern Company subsidiary, we will lead sales, delivery
and project management for TRIG™ (Transport Integrated Gasification), a
clean coal technology jointly developed by KBR and Southern Company.

Looking to 2013 and beyond, we see strong growth continuing for our
Technology business. In addition to the momentum our ammonia technolo-
gies are showing, we anticipate strength for refining and ethylene in Asia
Pacific and the Middle East as well as good prospects for TRIG™ in China.

I N F R A S T R U C T U R E , G O V E R N M E N T & P O W E R

Strategic investments in our Power, Infrastructure and Minerals businesses
are building leadership positions in industries where increased demand, a
desire for a cleaner environment and improved infrastructure present great
prospects for KBR. In an era of shrinking defense budgets and government
austerity programs, KBR’s government services businesses are meeting the
challenge of change as a premier provider of complex deliveries, logistics
support and outsourcing services in some of the world’s most demanding
environments.

well as environmentally driven opportunities, including coal plant retrofits
and replacements.

Infrastructure
In KBR’s Infrastructure Business Unit, government austerity programs in
Australia and the U.S. continued to dampen infrastructure spending during
2012. The energy-based economies of the Middle East remain the most
consistent infrastructure markets with an active bidding environment.

Power & Industrial
During 2012, KBR continued building its reputation as a premier, full-service
EPC provider to the power industry and advanced its strategy to expand
internationally in the industrial arena. Strong progress on four EPC projects,
including a waste-to-energy project for the Solid Waste Authority of Palm
Beach County and a cellulosic fiber project in Florida, highlighted the full-
service capabilities we bring to these markets.

New power awards during the year included EPC services contracts for a
range of services for Kentucky Utilities’ Ghent Generating Stations and
the Kincaid Power Station in Illinois. Kincaid is an important win for the
company as we pursue our strategy of growing our business in regions of
the country where unions are prevalent.

In the industrial arena, we advanced our strategy for international
expansion with a new pulp and paper award in Saudi Arabia, supported
by the KBR-AMCDE engineering joint venture which has expanded our
position and opportunities in the region.

In Australia, a traditional region of strength for KBR, a government focus
on debt reduction has slowed spending for government-sponsored projects.
Softness in minerals has also reduced demand for mining infrastructure.
However, KBR has maintained a good win rate for smaller projects as we
await a rebound in larger opportunities.

In the Middle East, we continue to see a great deal of activity in Qatar and
Saudi Arabia as well as emerging opportunities in Iraq. We are building on
KBR’s strong wastewater experience and KBR’s newly-established Baghdad
office to pursue water projects in Iraq, primarily with major international oil
companies. At the same time, we are focused on excellence in execution of
our management on the Doha Expressway program in Qatar.

We see encouraging signs that EPC opportunities may increase in 2013 and
beyond. We are continuing to expand our opportunities with hydrocarbons
infrastructure projects as well as expanding our presence in the Middle East
with a focus on Iraq, Oman, UAE, Saudi Arabia and Qatar.

Our Power & Industrial Business Unit entered 2013 with the largest prospect
list we have seen in several years. We expect power markets to remain
active with several large EPC combined cycle opportunities likely in 2013 as

Minerals
In 2012, the global minerals market faced softer market conditions as the
re-evaluation of project economics by Minerals’ customers delayed many of
the larger opportunities.

KBR’s Infrastructure, Government and Power

Group, with five discrete Business Units, is

focused on its diverse customers and is well

positioned for global growth in the power,

industrial, infrastructure, transportation,

water, minerals, government, defense and

logistics markets.

Another important win was KBR’s selection as a prime contractor for the
U.S. Army’s Enhanced Army Global Logistics Enterprise program to compete
for task orders to provide supply, maintenance and transportation support at
major Army installations globally.

Against a backdrop of decreasing budgets, KBR is focused on delivering
projects on time and on budget to remain a top choice for federal contracts.
We believe we are well positioned in the government and commercial
markets and future revenues and earnings should be relatively stable off
our current base.

R E G I O N S

Australia-Asia Region
The Australia-Asia region, rich in resources and coupled with high demand
from growing Asian markets, is strategically important to KBR. Not only a
significant contributor to KBR’s revenue and income through successful
execution of projects such as Gorgon, Ichthys, and Hope Downs 4, this
vibrant region also offers long-term sustainable growth through a
multi-faceted set of opportunities stretched across the breadth and depth
of KBR’s diverse service offerings. In 2012, KBR created an Australia–Asia
regional leadership team and integrated cross-functional organization with
the primary role of supporting KBR’s Business Units in their key sales efforts,
project execution and in the enhancement of growth opportunities.

In order to support these tremendous opportunities, the regional team
will be focused on both leveraging and developing existing resources
and capabilities to sustain growth across multiple business lines, and
on expanding KBR’s “share of wallet” by developing a new direct hire
construction and maintenance offering that provides strong local content
throughout the region, further enhancing KBR’s global capabilities.

Middle East Region
The Middle East region has remained a robust area for growth given its
vast natural and financial resources and its continued rapid economic
development. As a key contractor in the region for decades, opportunities
abound for KBR where our knowledge and experience are utilized across a
broad spectrum of areas, including Oil and Gas, Downstream, Infrastructure
and Services. The end of the war in Iraq has also opened up substantial
opportunities for new and necessary infrastructure advancement.

In support of these remarkable opportunities, the team is focused on
continuing to build our regional capabilities and on strengthening our
regional customer relationships. In addition, the team is also focused on
furthering key initiatives in the region relative to expanding KBR’s “share
of wallet” by developing stronger local content through our KBR-AMCDE
joint venture as well as through the development of more direct hire
construction and partnership capabilities in order to meet the growing
need for high local content in the region.

Building on our traditional strength in Australia, we won an engineering,
procurement and contract management award early in 2012 for the upgrade
of Rio Tinto’s fuel assets at five sites in western Australia. At Rio Tinto’s
Hope Downs 4 mine, we culminated a year of good progress by expanding
the scope of work to be performed under our EPCM contract.

We continue to view the minerals arena as a key component of our overall
strategy for growth long term.

International Government, Defence & Support Services
Our International Government, Defence and Support Services business
continues to diversify into new markets and clients. A valued, long-term
supplier to the U.K. Ministry of Defence (MOD), we are well positioned for
more enduring peace-time work as a trend toward outsourcing continues.

During 2012, contract extensions in Afghanistan continued to provide a
steady source of business with a diverse set of clients. Under the Afghan
Infrastructure Support Project, we provide operations and maintenance
services for U.K. assets across multiple sites. Under contracts with the
NATO Support Agency, we provide a variety of services at Kabul and
Kandahar airfields. Other contracts in Afghanistan extended in 2012 include
life support, healthcare and vehicle maintenance for the U.K. Foreign and
Commonwealth Office and aircraft loading and offloading services for
the Royal Air Force.

We continue to perform well on the multi-decade Allenby and Connaught
project with the MOD. We expect to complete the construction phase in
2014, and we will continue providing services under a 35-year contract.
During 2012, we won two new MOD awards in support of military
operations and exercises worldwide.

Looking ahead, we expect some contraction of our International Government,
Defence and Support Services business due to the withdrawal of troops
from Afghanistan and the completion of the construction phase of the
Allenby and Connaught project. However, we see several strategic
opportunities to take advantage of proposed outsourcing opportunities at the
MOD and with the local police operations in the U.K. We also see numerous
emerging opportunities in Libya where we have opened an office to position
KBR for work with the Libyan Air Force, Border Guard Force and Navy
providing construction, training and support services. We also plan to
leverage our people-support skills with minerals companies operating in
remote locations and to capitalize on our demonstrated success in providing
life support and camp services.

North America Government and Logistics
Despite economic and political uncertainty that canceled or delayed some
work, KBR’s North America Government and Logistics Business Unit finished
2012 on a strong note with a number of significant contract extensions and
new awards.

In a multi-year transition phase in Iraq, KBR has shifted its role from
supporting the U.S. Department of Defense to supporting U.S. diplomatic
efforts serving the U.S. Embassy staff at more than 13 locations.

KBR also expanded its support of the U.S. Army in Europe under an
ongoing contract over five years. Initially focused in Kosovo and Romania,
this contract provides a platform for extending our activities within a region
that encompasses 51 countries.

Recently, KBR won a contract from the U.S. Navy at Camp Lemonnier in
Djibouti, Africa and Manda Bay, Kenya covering a comprehensive range of
services in a region that remains a top priority for U.S. national interests.

S E R V I C E S

KBR’s Services Business Group provides a broad spectrum of construction,
maintenance and fabrication services, primarily in the U.S. and Canada.
In addition to adding capabilities designed to grow these businesses in
North America, we have successfully pursued international expansion of
our Industrial Services business. During 2012, we achieved solid results
in Industrial Services and strong growth from our Canadian Operations.
Economic headwinds, which moderated activity at our Building Group, show
signs of abating and we have taken decisive action to resolve the changing
market conditions in our U.S. Construction business. We continue positioning
these businesses for the future and see good medium-term opportunities to
provide construction support to other KBR business units, which are seeing
a rebound in North American activity.

Canada Operations
For KBR’s Canada Operations, which include construction, module assembly
and fabrication as well as turnaround and maintenance services, 2012 was
a year of strong growth and expanding opportunities. We doubled the size of
the business during the year and booked approximately $1.0 billion of new
business, a five-fold increase compared to the prior year.

A 60-year veteran of the Canadian oil sands and mining industries, we have
delivered some of Canada’s largest and most technologically advanced
hydrocarbons projects. The energy sector, including oil sands and the rapidly
expanding shale gas market, continues to fuel our growth. New contract
awards during 2012 include construction of a natural gas processing plant,
which will monetize recent shale gas discoveries, and expansion of a
Dawson Creek raw gas processing and compression facility. Both projects
are in British Columbia.

We also won contracts for module fabrication as well as field construction
at a Syncrude Canada Ltd. facility in Alberta that is being constructed to
manage tailings, a by-product of energy production from oil sands. Module
fabrication work will extend through the end of 2013. Construction will
follow with plant start-up scheduled for 2015. Another significant win, a
five-year contract with Suncor Energy to provide pipe fabrication and module
assembly services, reinforces our position as a major module supplier in
Alberta and underscores our commitment to increase our presence and grow
our business in the region. In addition, we have secured long-term, multi-use
contracts for construction and turnarounds with a major oil sands provider.

Drawing on our experience in the mining sector, we received a contract for
boiler demolition and construction at Cameco Corporation’s Rabbit Lake
operation, which is the world’s second-largest uranium mill by capacity and
Canada’s longest operating uranium production facility.

We expect continued strong investment in energy to drive ongoing growth
in Canada. We have expanded our execution capacity, enhanced our module
fabrication capabilities and localized our operations to capture a diverse
set of opportunities for our Canada Operations, in concert with other KBR
business units.

Industrial Services
Working under long-term contracts that reduce cyclical swings, Industrial
Services is a stable business that continues to deliver solid results year after
year. We are building on a legacy of excellence by providing maintenance
services to customers in the U.S. to grow this business in North America
and beyond. Already providing maintenance services to International Paper
facilities in Russia and Poland, we reached a major milestone in further
expanding this business internationally with a new contract in Saudi Arabia.

In December 2012, we won a seven-year contract, valued at up to $170
million, for maintenance services at the Saudi Aramco Total Refining
and Petrochemical Company (SATORP) refinery in Jubail, Saudi Arabia.

Scheduled to begin production in 2013, the facility presents unique technical
challenges due to its scale and complexity. This landmark agreement
represents the first time a major participant in the Saudi Arabian
hydrocarbons industry has outsourced a full-service maintenance contract.

Through a joint venture with Jubail-based AYTB, KBR will be a full-service
provider of maintenance to the refinery with responsibility for overall site
management and field supervision of a craft workforce that includes all
mechanical, electrical and instrumentation disciplines. KBR and AYTB
also will provide detailed planning and scheduling services as well as
preventive and predictive maintenance. Additionally, the joint venture
will work in partnership with SATORP on developing reliability and cost
optimization programs for the refinery that demonstrate a new model for
delivering plant maintenance services in Saudi Arabia.

We see solid performance and growth prospects for this business continuing
in 2013 and beyond.

Building Group
Faced with persistent economic headwinds, our Building Group continues
to successfully execute projects and hold its position in a flat market.
Despite weak demand in healthcare during 2012, our strong credentials
and experience in this segment resulted in a contract for major renovations
and new construction at Providence Hospital in Columbia, South Carolina.
We also capitalized on strengthening demand in the light manufacturing
and residential markets.

We received contracts for four high-rise residential or mixed-use projects
in the Washington, D.C. area. The Acadia, located in Arlington, Virginia, is
in the third phase at the Metropolitan Park development where two prior
projects constructed by KBR won awards for construction excellence. The
Aurora, a luxury high-rise residential project in Bethesda, Maryland, is the
second of four planned phases of a neighborhood revitalization project.
We also are building The Place at Founders Square, the residential tower
of a large, mixed-use development in Arlington, Virginia and The Premier,
a residential project in Silver Spring, Maryland.

In the industrial arena, we leveraged our prior success with Boeing with
an expansion project for their 787 aircraft, which is expected to be complete
in 2014. We were also successful in winning a contract for the construction
of a 90,000 square-foot aircraft maintenance, repair and overhaul facility
adjacent to Honda Aircraft Company’s world headquarters in Greensboro,
North Carolina. CTL Packaging USA awarded KBR a 160,000 square-foot
industrial manufacturing plant being built in Dallas, North Carolina to
produce plastic tubes and caps for cosmetics and personal care products.

While project awards grew 50% in 2012, it was from a low prior-year
base. The business environment remains challenging, but it is stabilizing.
In 2013, we will build on our solid execution platform, increase our
capabilities, and continue working to expand our business into additional
industries and geographic markets.

U.S. Construction
Our U.S. Construction business builds a wide variety of industrial facilities
in multiple regions of the country. While most projects progressed
successfully, others experienced challenges related to the beginning of
an economic rebound in some regions of the country which impacted craft
labor availability and productivity.

As demand for qualified craft labor tightened in these markets, more sharply
and earlier than we had forecast, we experienced higher labor costs, lower
productivities and longer project schedules that negatively affected three
projects being constructed under fixed-price contracts. We took charges to

reflect the increased costs and actions to bring them on track for scheduled
completion in 2013. Our construction projects in other regions of the country
continue performing according to expectations.

As a result of strengthening market conditions, we shifted to a cost-
reimbursable approach in bidding construction-only projects starting at
the beginning of the third quarter of 2012. We continue to support KBR
in EPC projects where our self-perform construction capabilities represent
a major differentiator.

Looking ahead, the upturn we have been anticipating for this business is
underway. We are focused on building our capabilities to support the growing
demand for construction across the southern U.S., as well as opportunities
related to the shale gas phenomenon in other parts of the country. In addition
to projects related to natural gas processing, abundant and low-cost gas
supplies are driving demand for other types of industrial projects.

V E N T U R E S

KBR Ventures supports the company’s core businesses by investing
alongside KBR customers in projects where our equity and ownership
position can make a positive difference. Our long-term positions, which
generate a return for KBR, continued to perform well in 2012.

completion, and the second which is working under an operating contract,
expanding as assets and services are added. During 2012, Ventures also
benefited from an improvement across its investments in a heavy equipment
transport project and several roads projects.

Our ongoing evaluation of potential investments considers the needs of our
customers, project specifics and competing uses of capital.

O P E R A T I O N S

KBR Operations enables our business units to focus their full attention on
winning work and executing it well. With approximately 8,000 employees
strategically deployed around the world, this group supplies the personnel,
work processes and tools needed to successfully deliver projects. It also
plays a key role in oversight and control of our projects.

Our 24 worldwide operating locations provide a local presence that repre-
sents a strong competitive advantage in winning bids as well as access to
local content, which is a prerequisite for some opportunities. During 2012,
we opened new offices in Luanda, Angola, Baghdad, Iraq and Al-Khobar,
Saudi Arabia, and we are already seeing benefits from these additions.
Standard processes and electronic communications at all locations enable
seamless work-sharing that balances the load among regions.

Our 10 percent stake in the EBIC ammonia plant in Egypt benefited from
strong worldwide commodity prices and exceptional operating performance.
Completed by KBR in 2009, the EBIC plant has been very reliable and
productive with high availability. Our Ventures portfolio also includes a 45
percent interest in Allenby & Connaught, a multi-decade project to construct
and operate facilities for the British Army. KBR is part of two joint ventures,
one that is executing work under a construction contract, currently nearing

With the anticipated increase in work volumes over the next several
years, we expect to flex up our staffing levels in 2013 as our pipeline of
opportunities continues to grow. We also are focused on a global staffing
strategy with additional operations centers in more regions and an internal
construction management staffing agency to provide and manage contract
labor for international projects.

KBR’s Services Group, primarily focused

in North America and expanding globally

through its four Business Units, is positioned

to deliver full-scope construction, construction

management, fabrication, operations

and maintenance, and turnaround services

to its customers.

Q U A L I T Y , H E A L T H , S A F E T Y & E N V I R O N M E N T

KBR is committed to leadership in all aspects of its business. In addition to
utilizing our vast global capabilities to deliver quality products and services,
we want to make responsible, sustainable practices an integral part of our
business and be the company most recognized for safety performance.

KBR was the first engineering, procurement and construction company to
receive global Integrated Management Systems certifications in ISO 9001
(Quality Management), ISO 14001 (Environmental Management), and OHSAS
18001 (Occupational Health and Safety Management). Our integrated global
approach ensures that all locations utilize processes designed to uphold
our standards of corporate responsibility and consistently deliver quality,
sustainable solutions worldwide.

Keeping Focused – Keeping Fresh
Safety is integral to excellence in project execution, and it is a key measure
of our overall performance. By providing visible leadership throughout the
organization, our executive management teams are committed to creating
and sustaining a culture of personal accountability. Recognizing that
front-line supervisors are the key to driving a quantum leap toward our goal
of eliminating safety incidents, we are working to develop a certification
program that goes beyond current training to better prepare supervisors
for this role.

A key area of focus during 2012 was keeping safety complacency out of the
workplace while placing additional emphasis on the most urgent issues. Our
“Keeping Focused – Keeping Fresh” initiative reinvigorated overall safety
awareness, and a “Hand Safety” program heightened the focus in an area
that had been identified as the source of 40% of all accidents.

In addition, our “7 Keys to Life” initiative raised the profile of seven high-risk
areas of our activities and reinforced the associated safety procedures. Our
plans call for the development of an email safety bulletin that will go out to
all employees when one of the “keys” is compromised with a near miss or
an actual event.

While we will never be completely satisfied with our safety performance
until we have eliminated all workplace safety incidents, we are proud to
be among the leaders in our industry. As an example, KBR received two
gold occupational health and safety awards from the Royal Society for the
Prevention of Accidents for the third consecutive year.

Leadership by Example
In addition to safety leadership, we strive to incorporate industry best
practices for environmentally responsible and sustainable business practices.
We have many opportunities to impact the environment, from the way we
choose to conduct business, develop our employees, and promote energy-
efficient or environmentally-supportive engineering designs, to where we
choose to put our volunteer time and charitable contributions. This demands
an integrated approach that strikes a balance among customer requirements,
corporate objectives and protection of health, safety and the environment.

Sustainability demands an enduring, balanced approach to economic
activity, environmental responsibility and social progress. As a global
company, KBR and its employees are in a position to make a significant
impact, not only as a valued service provider to our clients, but as a positive
steward of the environment and a good corporate citizen to the communities
in which we live and work.

2012 Community Matters
With businesses and employees touching six of the seven continents,
KBR has a vital interest in thriving communities around the globe. KBR
actively engages in finding sustainable solutions to the problems facing
the communities where we live and work. With a primary focus on health,
environment and education, we leverage our commitment through monetary
and in-kind support, volunteerism and employee giving.

Our goal is to support initiatives that create mutual benefit and lead to
shared progress. Our international partnership with The Nature Conservancy
supports Oyster Reef Restoration off the U.S. Gulf Coast. Our support of
the Indigenous Rangers Program, part of the organization’s Karrkard-Kanji
Trust in Australia leads to shared progress. KBR also supports the
development of the first tidal wetlands restoration methodology in
conjunction with Restore America’s Estuaries. These are just a few
examples of how we build a better world.

The volunteer spirit of KBR employees forms the heart and soul of our
connection to the communities in which we operate. In 2012, KBR volunteers
devoted over 13,000 hours to partnership with communities for a better
future and donated over $3 million. IMPACT, a network of developing
professionals that has flourished in more than eight countries, is just one
example of community giving. Since its inception in 2006, IMPACT
has raised more than $1.5 million for charity through KBR’s annual golf
tournament in Houston, Texas.

At KBR, an uncompromising commitment to

health, safety, the environment and being a

positive force in our communities is at the

heart of who we are, what we believe and

how we conduct our business.

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549

FORM 10-K

 Annual Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

For the fiscal year ended December 31, 2012

 Transition Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 for the transition period from to

Commission File Number 1-33146

KBR, Inc.
(Exact name of registrant as specified in its charter)

Delaware
(State or other jurisdiction of incorporation or organization)

20-4536774
(I.R.S. Employer Identification No.)

601 Jefferson Street Suite 3400
Houston, Texas
(Address of principal executive offices)

77002
Zip Code
Telephone Number - Area code (713) 753-3011

Securities registered pursuant to Section 12(b) of the Act:

Title of each class
Common Stock par value $0.001 per share

Name of each Exchange on which registered
New York Stock Exchange

Securities registered pursuant to Section 12(g) of the Act: None

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes  No 

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. Yes  No 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of
1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to
such filing requirements for the past 90 days. Yes  No 

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File
required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such
shorter period that the registrant was required to submit and post such files). Yes  No 

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained,
to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any
amendment to this Form 10-K. 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting
company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.
(Check one):

Large accelerated filer
Non-accelerated filer


 (Do not check if a smaller reporting company)

Accelerated filer
Smaller reporting company




Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes  No 

The aggregate market value of the voting stock held by non-affiliates on June 29, 2012, was approximately $3.6 billion, determined using the
closing price of shares of common stock on the New York Stock Exchange on that date of $24.71.

As of January 31, 2013, there were 147,615,219 shares of KBR, Inc. Common Stock, $0.001 par value per share, outstanding.

DOCUMENTS INCORPORATED BY REFERENCE
Portions of the KBR, Inc. Company Proxy Statement for our 2013 Annual Meeting of Stockholders are incorporated by reference into Part III of this
report.

TABLE OF CONTENTS

Page

PART I
Item 1. Business

Item 1A. Risk Factors

Item 1B. Unresolved Staff Comments

Item 2. Properties

Item 3. Legal Proceedings

Item 4. Mine Safety Disclosures

PART II

Item 5. Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity
Securities

Item 6. Selected Financial Data

Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Item 7A. Quantitative and Qualitative Disclosures About Market Risk

Item 8. Financial Statements and Supplementary Data

Report of Independent Registered Public Accounting Firm

FINANCIAL STATEMENTS

Consolidated Statements of Income

Consolidated Statements of Comprehensive Income

Consolidated Balance Sheets

Consolidated Statements of Shareholders’ Equity

Consolidated Statements of Cash Flows

Notes to Consolidated Financial Statements

Item 9. Changes In and Disagreements with Accountants on Accounting and Financial Disclosure

Item 9A. Controls and Procedures

Item 9B. Other Information

PART III

Item 10. Directors, Executive Officers and Corporate Governance

Item 11. Executive Compensation

Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

Item 13. Certain Relationships and Related Transactions, and Director Independence

Item 14. Principal Accounting Fees and Services

PART IV

Item 15. Exhibits and Financial Statement Schedules

SIGNATURES

115

117

123

Forward-Looking and Cautionary Statements

This report contains certain statements that are, or may be deemed to be, “forward-looking statements” within the meaning
of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended. The
Private Securities Litigation Reform Act of 1995 provides safe harbor provisions for forward looking information. Some of the
statements contained in this annual report are forward-looking statements. All statements other than statements of historical fact
are, or may be deemed to be, forward-looking statements. The words “believe,” “may,” “estimate,” “continue,” “anticipate,”
“intend,” “plan,” “expect” and similar expressions are intended to identify forward-looking statements. Forward-looking
statements include information concerning our possible or assumed future financial performance and results of operations.

We have based these statements on our assumptions and analyses in light of our experience and perception of historical
trends, current conditions, expected future developments and other factors we believe are appropriate in the circumstances.
Forward-looking statements by their nature involve substantial risks and uncertainties that could significantly affect expected
results, and actual future results could differ materially from those described in such statements. While it is not possible to identify
all factors, factors that could cause actual future results to differ materially include the risks and uncertainties described under
“Risk Factors” contained in Part I of this Annual Report on Form 10-K.

Many of these factors are beyond our ability to control or predict. Any of these factors, or a combination of these factors,
could materially and adversely affect our future financial condition or results of operations and the ultimate accuracy of the
forward-looking statements. These forward-looking statements are not guarantees of our future performance, and our actual results
and future developments may differ materially and adversely from those projected in the forward-looking statements. We caution
against putting undue reliance on forward-looking statements or projecting any future results based on such statements or on
present or prior earnings levels. In addition, each forward-looking statement speaks only as of the date of the particular statement,
and we undertake no obligation to publicly update or revise any forward-looking statement.

PART I

Item 1. Business

General

KBR, Inc. and its subsidiaries (collectively, “KBR”) is a global engineering, construction and services company supporting
the energy, hydrocarbons, government services, minerals, civil infrastructure, power, industrial and commercial markets. We offer
a wide range of services through our Hydrocarbons, Infrastructure, Government and Power (“IGP”), Services and Other groups.
Information regarding segment disclosures are incorporated by reference in Note 5 to our consolidated financial statements and
“Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations.”

KBR, Inc. was incorporated in Delaware on March 21, 2006 prior to an exchange offer transaction that separated us from
our former parent, Halliburton Company, which was completed on April 5, 2007. We trace our history and culture to two
businesses, The M.W. Kellogg Company (Kellogg) and Brown & Root, Inc. (Brown & Root). Kellogg dates back to a pipe
fabrication business which was founded in New York in 1901 and has been creating technology for petroleum refining and
petrochemicals processing since 1919. Brown & Root was founded in Houston, Texas in 1919 and built the world’s first offshore
platform in 1947. Brown & Root was acquired by Halliburton in 1962 and Kellogg was acquired by Halliburton in 1998 through its
merger with Dresser Industries.

Our Business Groups and Business Units

We operate in four business groups which are consistent with our segment reporting under Financial Accounting Standards
Board ("FASB") Accounting Standards Codification (“ASC”) 280 - Segment Reporting: Hydrocarbons; IGP; Services; and Other as
described below.

Hydrocarbons. Our Hydrocarbons business group provides services ranging from prefeasibility studies to front-end
engineering design (“FEED”) through construction and commissioning of process facilities in remote locations and developed areas
around the world. We are involved in hydrocarbon processing which includes constructing liquefied natural gas (“LNG”) plants in
several countries. Our global teams of engineers also provide process technology and project delivery for projects in the oil and
gas, olefins, refining, petrochemical, biofuels and carbon capture markets. The Hydrocarbons business group is comprised of the
Gas Monetization, Oil & Gas, Downstream and Technology business units.

Gas Monetization business unit – Our Gas Monetization business unit designs and constructs facilities that enable our
customers to monetize their natural gas resources. We design and build LNG and gas-to-liquids (“GTL”) facilities that allow for
the economical development and transportation of resources across the globe. Additionally, we make significant contributions in
advancing gas processing development, equipment design and innovative construction methods.

Oil & Gas business unit – Our Oil & Gas business unit delivers onshore and offshore oil and natural gas production
facilities which include platforms, floating production and subsea facilities and pipelines. We also provide specialty consulting
services which include field development studies and planning, structural integrity management and proprietary designs for ship
and semi-submersible hulls.

Downstream business unit – Our Downstream business unit serves clients in the petrochemical, refining, chemicals, biofuels
and syngas markets throughout the world. We utilize our differentiated process technologies, but also execute projects and
complexes using technologies supplied by others. Our success is based on delivering value over the lifecycle of projects in the
hydrocarbon market.

Technology business unit – Our Technology business unit offers highly efficient, differentiated proprietary process
technologies for the coal monetization, petrochemical, refining and syngas markets. Our Downstream business unit is often
contracted to provide project management and engineering, procurement and construction (“EPC”) delivery of our process
technology as part of fully integrated solutions worldwide.

Infrastructure, Government & Power. Our IGP business group delivers effective solutions to industrial commercial,
defense and governmental agencies worldwide, providing base operations, facilities management, border security, EPC services and
logistics support. We also provide project management, construction management, design and support services for an array of
complex infrastructure initiatives including aviation, road, rail, maritime, water, wastewater, building and pipeline projects. For the
industrial manufacturing and process markets, we provide a full range of pre-FEED, FEED and EPC services to a variety of heavy
industrial and advanced manufacturing clients, frequently employing our clients’ proprietary knowledge and technologies in
strategically critical projects. For the power market, we use our full-scope EPC expertise to execute projects which play a
distinctive role in increasing the world’s power generation capacity from multiple fuel sources and in enhancing the efficiency and
environmental compliance of existing power facilities. The IGP business group includes the North American Government and
Logistics (“NAGL”), International Government, Defence and Support Services (“IGDSS”), Infrastructure, Minerals and the Power
and Industrial (“P&I”) business units.

North American Government and Logistics business unit – Our NAGL business unit offers operations, maintenance and
logistics support in both contingency and sustainment environments as well as construction and design/build services to the United
States Department of Defense (“DoD”), Department of State (“DoS”) and other federal government agencies.

International Government, Defence and Support Services business unit – Our IGDSS business unit supports armed forces
and government departments around the world by providing logistics and field support, operations and maintenance of equipment,
camps and bases, program and project management, construction management, training, visualization software and engineering and
support services. We provide services to government departments in the United Kingdom (“U.K.”), Europe, Middle East and
Australia.

Infrastructure business unit – Our Infrastructure business unit provides engineering, construction and project management
services across the world on complex infrastructure projects. The Infrastructure business unit provides global focus and leadership
in three key markets – transport (aviation, ports, rail and roads); water (water and wastewater); and facilities (includes buildings and
pipelines).

Minerals business unit – Our Minerals business unit provides EPC and EPC management ("EPCm") services across the
world on complex mining and minerals projects. The Minerals unit operates in three key markets – bulk materials handling (pit-to-
port-to-plant); minerals processing; and support infrastructure (camps, power, water, transport, port, marine, rail and road).

Power & Industrial business unit – Our P&I business unit provides full-scope EPC services for the industrial and power
markets globally. Within the Power product line, we deliver fossil fuel and renewable power generation projects, plant re-powering
projects and emissions control projects to customers that include regulated utilities, power cooperatives, municipalities, independent
power producers and industrial cogeneration providers. Within the Industrial product line, we serve clients in the forest products,
manufacturing, technology, life sciences, consumer products, metals and materials sectors.

Services.

Our Services business group delivers full-scope construction, construction management, fabrication,
operations/maintenance, commissioning/startup and turnaround expertise worldwide to a broad variety of markets including oil and
gas, petrochemicals processing, mining, power, alternate energy, pulp and paper, industrial and manufacturing and consumer
product industries. Specifically, Services is organized around four major product lines; U.S. Construction, Industrial Services,
Building Group and Canada Operations.

Our U.S. Construction product line delivers direct hire construction and construction management for stand-alone
construction projects to a variety of markets and works closely with the Hydrocarbons group, Minerals and Power and Industrial
business units to provide construction execution support on all domestic EPC projects.

Our Industrial Services product line is a diversified global maintenance organization providing maintenance, on-call
construction, turnaround and specialty services to a variety of markets at over 90 locations where we have embedded KBR
personnel. This product line works with our other business units to identify potential for pull through opportunities and to identify
upcoming EPC projects.

Our Building Group product line provides commercial general contractor services to education, food and beverage,

manufacturing, health care, hospitality and entertainment, life science and technology and mixed-use building clients.

Our Canada Operations product line is a diversified construction and fabrication operation providing direct hire
construction, construction management, module assembly, fabrication and maintenance services to our Canadian customers. This
product line serves a number of markets including oil and gas customers operating in the oil sands, pulp and paper, mining and
industrial markets.

Other. Included in Other is the Ventures business unit and other operations. The Ventures business unit invests KBR
equity alongside clients’ equity in projects where one or more of KBR’s other business units has a direct role in technology supply,
engineering, construction, construction management or operations and maintenance. Project equity investments under current
management include defense equipment and housing, toll roads and petrochemicals.

In addition to the Ventures business unit, other business operations are reported in our Other group including the Allstates
staffing business, our engineering resource operations and other operations that do not individually meet the criteria for group
presentation under ASC 280.

Our Business Strategy

Our business strategy is to create shareholder value by providing our customers differentiated capital project delivery and
services offerings across the entire engineering, construction and operations project lifecycle as a vertically integrated global
contractor. We execute our business strategy on a global scale delivering consistent results anywhere in the world. An essential
feature of our global strategy is to establish local operations in market geographies where demand for our services is expected to
grow. Our core skills are conceptual design, FEED, engineering, project management, procurement, construction, construction
management, logistics, commissioning, operations and maintenance. We will complement organic growth by pursuing targeted
acquisitions that focus on expanding our capabilities and market coverage or accelerating business growth strategies. Key features
of our business unit strategies include:

•

The Hydrocarbons business group will build on our world-class strength and experience with hydrocarbon
processing projects and seek to expand our footprint in both offshore and onshore oil and gas services. Our business
will grow by utilizing our leading technology and execution excellence to provide high value process facilities to
customers. Our Technology business unit will expand its portfolio of differentiated process technologies and
associated service, proprietary equipment and catalyst offerings and deliver through an expanded global platform.
The Infrastructure, Government & Power business group will broaden our commercial, government operations, EPC
logistics, construction and maintenance services internationally. We will apply our design, project management and
construction skills to infrastructure, industrial, mining, minerals and power markets utilizing the same global
delivery platform already in place for Hydrocarbons.
The Services business group will capitalize on our brand reputation and core competencies to expand our direct hire
construction, general contracting and industrial services operations both domestically and internationally with focus
on safe operations and high value outcomes.
The Ventures business unit will invest alongside our clients in selected projects to both earn a return on our capital
and secure capital projects for our business units to design, build and maintain.

Competition and Scope of Global Operations

We operate in highly competitive markets throughout the world. The types of competition with respect to sales of our

capital project and service offerings include:

•
•
•
•
•

customer relationships;
successful prior execution of large projects in difficult locations;
technical excellence and differentiation;
high value in delivered projects and services measured by performance, quality, operability and cost;
service delivery, including the ability to deliver personnel, processes, systems and technology on an “as needed,
where needed and when needed” basis with the required local content and presence;
consistent superior service quality;

•
• market leading health, safety and environmental standards and sustainable practices;
•
•
•

financial strength through liquidity and capital capacity and the ability to support warranties;
breadth of proprietary technology and technical sophistication; and
robust risk awareness and management processes.

We conduct business in over 70 countries. Based on the location of services provided, our operations in countries other than
the United States accounted for 73% of our consolidated revenue during 2012, 78% of our consolidated revenue during 2011, and
79% of our consolidated revenue during 2010. Our international revenues in the Asia Pacific geographic region accounted for 24%,
16% and 10% of our consolidated revenue during 2012, 2011 and 2010, respectively. Our international revenues in the Africa
geographic region accounted for 21%, 23% and 21% of our consolidated revenue during 2012, 2011 and 2010, respectively.
Revenue from our operations in Iraq, primarily related to our work for the U.S. government, was 6%, 21% and 29% of our
consolidated revenue in 2012, 2011 and 2010, respectively. See Note 5 to our consolidated financial statements for selected
geographic information.

We market substantially all of our capital project and service offerings through our business units. We have many
substantial competitors in the markets that we serve. The competitors include but are not limited to AMEC, Bechtel Corporation,
CH2M Hill Companies Ltd., Chicago Bridge and Iron Co., N.V., Chiyoda, Fluor Corporation, Foster Wheeler Ltd., Jacobs
Engineering Group, Inc., JGC Corp, John Wood Group PLC, McDermott International, Petrofac PLC, Saipem S.p.A., Technip,
URS Corporation, AECOM Technology Corporation and Worley Parsons Ltd. Since the markets for our services are vast and
extend across multiple geographic regions, we cannot make a meaningful estimate of the total number of our competitors.

Our operations in some countries may be adversely affected by unsettled political conditions, acts of terrorism, civil unrest,
force majeure, war or other armed conflict, expropriation or other governmental actions, inflation, foreign currency exchange
controls and fluctuations. We strive to manage or mitigate these risks through a variety of means including contract provisions,
contingency planning, insurance schemes, hedging and other risk management activities. See “Item 7. Management’s Discussion

and Analysis of Financial Condition and Results of Operations - Financial Instruments Market Risk,” “Risk Factors - International
and political events may adversely affect our operations,” and Note 14 to our consolidated financial statements for information
regarding our exposures to foreign currency fluctuations, risk concentration and financial instruments used to manage our risks.

Significant Acquisitions and Other Transactions

In November 2012, the joint venture in which we hold a 50% interest sold the office building in which we lease office space
for our corporate headquarters and business unit offices in Houston, Texas, for $175 million. Since we will continue to lease the
office building from the new owner under essentially the same lease terms, the $44 million pre-tax gain on the sale will be deferred
and amortized using the straight-line method over the remaining term of the lease, which expires in 2030.

In November 2012, we closed on the sale of our former headquarters campus located at 4100 Clinton Drive in Houston,
Texas for approximately $42 million in cash. The sale resulted in a $27 million pre-tax gain on disposal of assets in "Operating
income" in our consolidated statements of income.

On December 31, 2010, we obtained control of the remaining 44.94% interest in our M.W. Kellogg Limited (“MWKL”)
consolidated joint venture previously held by JGC Corporation. MWKL is located in the U.K. and provides EPC services primarily
for LNG, GTL and onshore oil and gas projects. MWKL will continue to support our LNG and other Hydrocarbons projects.

See Note 3 to our consolidated financial statements for further discussion of our recent acquisitions.

Joint Ventures and Alliances

We enter into joint ventures and alliances with other industry participants in order to reduce and diversify risk, increase the
number of opportunities that can be pursued, capitalize on the strengths of each party, facilitate relationships between us, our
venture partners and different potential customers and allow for greater flexibility in delivering our services based on cost and
geographical efficiency. Our significant joint ventures and alliances are described below. All joint venture ownership percentages
presented are as of December 31, 2012.

JKC is a joint venture consisting of JGC Corporation, KBR and Chiyoda for the purpose of design, procurement,
fabrication, construction, commissioning and testing of the Ichthys Onshore LNG Export Facility in Darwin, Australia ("Inpex
LNG project"). The project will be executed using two joint ventures in which we own a 30% equity interest. The investments are
accounted for using the equity method of accounting and reported in our Hydrocarbons business group.

Kellogg Joint Venture (“KJV”) is a joint venture consisting of JGC Corporation, Hatch Associates PTY LTD (“Hatch”),
Clough Projects Australia PTY LTD (“Clough”) and KBR for the purpose of design, procurement, fabrication, construction,
commissioning and testing of the Gorgon Downstream LNG Project located on Barrow Island off the northwest coast of Western
Australia. We hold a 30% interest in the joint venture which is consolidated for financial accounting purposes and reported in our
Hydrocarbons business group.

Aspire Defence Holdings Limited (“Aspire Defence”) is a joint venture between us, Carillion Private Finance Limited and
two financial investors formed to contract with the U.K. Ministry of Defence (“MoD”) to upgrade and provide a range of services to
the British Army’s garrisons at Aldershot and around the Salisbury Plain in the United Kingdom. We own a 45% interest in Aspire
Defence which is reported in our Ventures business unit that is included in our Other group. In addition, we own a 50% interest in
each of the two joint ventures within our IGP group that provide the construction and related support services to Aspire Defence.
We account for our investments in these entities using the equity method of accounting.

Mantenimiento Marino de Mexico (“MMM”) is a joint venture formed under a Partners Agreement with Grupo R affiliated
entities. The principal Grupo R entity is Corporative Grupo R, S.A. de C.V. and Discoverer ASA, Ltd., a Cayman Islands
company. The Partners’ Agreement covers five joint venture entities executing Mexican contracts with PEMEX. The MMM joint
venture was set up under Mexican maritime law in order to hold navigation permits to operate in Mexican waters. The scope of the
business is to render maintenance, repair and restoration services of offshore oil and gas platforms and provisions of quartering in
the territorial waters of Mexico. We own a 50% interest in MMM and in each of the four other joint ventures. We account for our
investment in these entities using the equity method of accounting within our Services business group.

Backlog

Backlog represents the dollar amount of revenue we expect to realize in the future as a result of performing work on
contracts awarded and in progress. For our projects related to unconsolidated joint ventures, we have included our percentage
ownership of the joint venture’s estimated revenue in backlog. Our backlog was $14.9 billion and $10.9 billion at December 31,
2012 and 2011, respectively. We estimate that as of December 31, 2012, 48% of our backlog will be recognized as revenue within
one year. All backlog is attributable to firm orders at December 31, 2012 and 2011. For additional information regarding backlog
see our discussion within “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations.”

Contracts

Our contracts are broadly categorized as either cost-reimbursable or fixed-price, although a portion of our contracts are

“hybrid” contracts containing both cost-reimbursable and fixed-price scopes.

Fixed-price contracts are for a fixed sum to cover all costs and any profit element for a defined scope of work. Fixed-price
contracts entail more risk to us because they require us to predetermine both the quantities of work to be performed and the costs
associated with executing the work. Although fixed-price contracts involve greater risk than cost-reimbursable contracts, they also
are potentially more profitable since the owner/customer pays a premium to transfer project risks to us.

Cost-reimbursable contracts include contracts where the price is variable based upon our actual costs incurred for time and
materials, or for variable quantities of work priced at defined unit rates and reimbursable labor hour contracts. Profit on cost-
reimbursable contracts may be a fixed amount, a mark-up applied to costs incurred, or a combination of the two. Cost reimbursable
contracts are generally less risky than fixed-price contracts because the owner/customer retains many of the project risks.

Our IGP business group provides substantial work under cost-reimbursable contracts with the DoD and other governmental
agencies which are generally subject to applicable statutes and regulations. If the government finds that we improperly charged any
costs to a contract under the terms of the contract or applicable Federal Procurement Regulations, these costs are potentially not
reimbursable or, if already reimbursed, we may be required to refund the costs to the customer. Such conditions may also include
financial penalties. If performance issues arise under any of our government contracts, the government retains the right to pursue
remedies, which could include termination under any affected contract. Furthermore, the government has the contractual right to
terminate or reduce the amount of work under our contracts at any time. See “Risk Factors - Our U.S. government contracts work
is regularly reviewed and audited by our customer, U.S. government auditors and others, and these reviews can lead to withholding
or delay of payments to us, non-receipt of award fees, legal actions, fines, penalties and liabilities and other remedies against us.”

Significant Customers

We provide services to a diverse customer base, including international and national oil and gas companies, independent
refiners, petrochemical producers, fertilizer producers and domestic and foreign governments. A considerable percentage of
revenue is generated from transactions with the Chevron Corporation (“Chevron”) primarily from our Hydrocarbons business group
and the U.S. government from our IGP business group. No other customers represented 10% or more of consolidated revenues in
any of the periods presented. The information in the following tables has summarized data related to our revenue from Chevron
and the U.S. government.

Revenues and percent of revenues from major
customers by year:

Millions of dollars, except percentage amounts

Chevron revenue

U.S. government revenue

Years ended December 31,

2012

2011

2010

$ 2,302

690

29% $ 2,047

22%

$ 1,783

9% $ 2,219

24%

$ 3,277

18%

32%

Raw Materials

Equipment and materials essential to our business are obtained from a variety of sources throughout the world. The
principal equipment and materials we use in our business are subject to availability and price fluctuations due to customer demand,
producer capacity and market conditions. We monitor the availability and price of equipment and materials on a regular basis. Our
procurement department actively leverages our size and buying power to ensure that we have access to key equipment and materials
at the best possible prices and delivery schedule. While we do not currently foresee any significant lack of availability of
equipment and materials in the near term, the availability of these items may vary significantly from year to year and any prolonged
unavailability or significant price increases for equipment and materials necessary to our projects and services could have a material
adverse effect on our business. See, “Risk Factors - The nature of our contracts, particularly those that are fixed-price, subject us
to risks associated with cost over-runs, operating cost inflation and potential claims for liquidated damages.” and “Risk Factors -
Current or future economic conditions in the credit markets may negatively affect ability to operate our or our customers’
businesses, finance working capital, implement our acquisition strategy and access our cash and short-term investments.”

Intellectual Property

We have developed or otherwise have the right to license leading technologies, including technologies held under license
from third parties, used for the production of a variety of petrochemicals and chemicals and in the areas of olefins, refining,
fertilizers, coal gasification and semi-submersible technology. We also license a variety of technologies for the transformation of
raw materials into commodity chemicals such as phenol and aniline used in the production of consumer end-products. We are a
licensor of ammonia process technologies used in the conversion of synthetic gas to ammonia. We believe our technology portfolio
and experience in the commercial application of these technologies and related know-how differentiates us, enhances our margins
and encourages customers to utilize our broad range of engineering, procurement, construction and construction services (“EPC-
CS”) services.

Our rights to make use of technologies licensed to us are governed by written agreements of varying durations, including
some with fixed terms that are subject to renewal based on mutual agreement. Generally, each agreement may be further extended
and we have historically been able to renew existing agreements before they expire. We expect these and other similar agreements
to be extended so long as it is mutually advantageous to both parties at the time of renewal. For technologies we own, we protect
our rights, know-how and trade secrets through patents and confidentiality agreements. Our expenditures for research and
development activities were immaterial in each of the past three fiscal years.

Seasonality

On an overall basis, our operations are not generally affected by seasonality. Weather and natural phenomena can

temporarily affect the performance of our services.

Employees

As of December 31, 2012, we had approximately 27,000 employees, of which approximately 16% were subject to collective
bargaining agreements. Based upon the geographic diversification of our employees, we believe any risk of loss from employee
strikes or other collective actions would not be material to the conduct of our operations taken as a whole.

Health and Safety

We are subject to numerous health and safety laws and regulations. In the United States, these laws and regulations include:
the Federal Occupational Safety and Health Act and comparable state legislation, the Mine Safety and Health Administration laws,
and safety requirements of the Departments of State, Defense, Energy and Transportation. We are also subject to similar
requirements in other countries in which we have extensive operations, including the United Kingdom where we are subject to the
various regulations enacted by the Health and Safety Act of 1974.

These laws and regulations are frequently changing, and it is impossible to predict the effect of such laws and regulations on
us in the future. We actively seek to maintain a safe, healthy and environmentally friendly work place for all of our employees and
those who work with us. However, we provide some of our services in high-risk locations and, as a result, we may incur substantial
costs to maintain the safety and security of our personnel.

Environmental Regulation

We are subject to numerous environmental, legal and regulatory requirements related to our operations worldwide. In the
United States, these laws and regulations include, among others: the Comprehensive Environmental Response, Compensation and
Liability Act; the Resources Conservation and Recovery Act; the Clean Air Act; the Clean Water Act; and the Toxic Substances
Control Act. In addition to federal and state laws and regulations, other countries where we do business often have numerous
environmental regulatory requirements by which we must abide in the normal course of our operations. These requirements apply
to our business groups where we perform construction and industrial maintenance services or operate and maintain facilities.

We continue to monitor conditions at sites owned or previously owned and until further information is available, we are
only able to estimate a possible range of remediation costs. These locations were primarily utilized for manufacturing or fabrication
work and are no longer in operation. The use of these facilities created various environmental issues including deposits of metals,
volatile and semi-volatile compounds and hydrocarbons impacting surface and subsurface soils and groundwater. The range of
remediation costs could change depending on our ongoing site analysis and the timing and techniques used to implement
remediation activities. We do not expect that costs related to environmental matters will have a material adverse effect on our
consolidated financial position or results of operations. Based on the information presently available to us, as of December 31,
2012, we have accrued approximately $6 million for the assessment and remediation costs associated with all environmental
matters, which represents the low end of the range of estimated possible costs that could be as much as $11 million. See Note 10 to
our consolidated financial statements for more information on environmental matters.

We have been named as a potentially responsible party (“PRP”) in various clean-up actions taken by federal and state
agencies in the U.S. Based on the early stages of these actions, we are unable to determine whether we will ultimately be deemed
responsible for any costs associated with these actions.

Existing or pending climate change legislation, regulations, international treaties or accords are not expected to have a
material direct effect on our business or the markets that we serve, nor on our results of operations or financial position. However,
climate change legislation could have a direct effect on our customers or suppliers, which could have an indirect effect on our
business. For example, our commodity-based markets depend on the level of activity of mineral and oil and gas companies and
existing or future laws, regulations, treaties or international agreements related to climate change, including incentives to conserve
energy or use alternative energy sources, could have an indirect impact on our business if such laws, regulations, treaties or
international agreements reduce the worldwide demand for minerals, oil and natural gas. We will continue to monitor
developments in this area.

Compliance

We are subject to numerous compliance-related laws and regulations, including the Foreign Corrupt Practices Act, the U.K.
Bribery Act, other applicable anti-bribery legislation and laws and regulations regarding trade and exports. We are also governed
by our own Code of Business Conduct and other compliance-related corporate policies and procedures that mandate compliance
with these laws. Conducting our business with ethics and integrity is a key priority for KBR. Our Code of Business Conduct is a
guide for every employee in applying legal and ethical practices to our everyday work. The Code of Business Conduct describes
not only our standards of integrity but also some of the specific principles and areas of the law that are most likely to affect our
business. We regularly train our employees regarding anti-bribery issues and our Code of Business Conduct.

Website Access

Our annual reports on Form 10-K, quarterly reports on Form 10-Q, current reports on Form 8-K and amendments to those
reports filed or furnished pursuant to Section 13(a) or 15(d) of the Securities Exchange Act of 1934 are made available free of
charge on our Internet website at www.kbr.com as soon as reasonably practicable after we have electronically filed the material
with, or furnished it to, the SEC. The public may read and copy any materials we have filed with the SEC at the SEC’s Public
Reference Room at 100 F Street, NE, Washington, DC 20549. Information on the operation of the Public Reference Room may be
obtained by calling the SEC at 1-800-SEC-0330. The SEC maintains an Internet site that contains our reports, proxy and
information statements and our other SEC filings. The address of that site is www.sec.gov. We have posted on our website our
Code of Business Conduct, which applies to all of our employees and Directors and serves as a code of ethics for our principal
executive officer, principal financial officer, principal accounting officer and other persons performing similar functions. Any
amendments to our Code of Business Conduct or any waivers from provisions of our Code of Business Conduct granted to the
specified officers above are disclosed on our website within four business days after the date of any amendment or waiver
pertaining to these officers.

Item 1A. Risk Factors

Risks Related to Operations of our Business

Our results of operations depend on the award of new contracts and the timing of the performance of these contracts.

A substantial portion of our revenue is directly or indirectly derived from new contract awards. Delays in the timing of the
awards or potential cancellations of such prospects as a result of economic conditions, material and equipment pricing and
availability or other factors could impact our long term projected results. It is particularly difficult to predict whether or when we
will receive large-scale international and domestic projects as these contracts frequently involve a lengthy and complex bidding and
selection process, which is affected by a number of factors, such as market conditions, governmental and environmental approvals.
Because a significant portion of our revenue is generated from such projects, our results of operations and cash flows can fluctuate
significantly from quarter to quarter depending on the timing of our contract awards and the commencement or progress of work
under awarded contracts. In addition, many of these contracts are subject to financing contingencies and, as a result, we are subject
to the risk that the customer will not be able to secure the necessary financing for the project.

The uncertainty of our contract award timing can also present difficulties in matching workforce size with contract needs.
In some cases, we maintain and bear the cost of a ready workforce that is larger than necessary under existing contracts, in
anticipation of future workforce needs for expected contract awards. If an expected contract award is delayed or not received, we
may incur additional costs resulting from reductions in staff or redundancy of facilities, which could have a material adverse effect
on us.

The nature of our contracts, particularly those that are fixed-price, subject us to risks associated with cost over-runs, operating
cost inflation and potential claims for liquidated damages.

We conduct our business under various types of contracts where costs are estimated in advance of our performance.
Approximately 43% of the value of our backlog is attributable to fixed-price contracts where we bear a significant portion of the
risk of cost over-runs. These types of contracts are priced based in part on cost and scheduling estimates which are based on
assumptions including prices and availability of labor, equipment and materials as well as productivity, performance and future
economic conditions. If these estimates prove inaccurate, there are errors or ambiguities as to contract specifications or if
circumstances change due to, among other things, unanticipated technical problems, difficulties in obtaining permits or approvals,
changes in local laws or labor conditions, weather delays, changes in the costs of equipment and materials or our suppliers’ or
subcontractors’ inability to perform, then cost over-runs may occur. We may not be able to obtain compensation for additional
work performed or expenses incurred. Additionally, we may be required to pay liquidated damages upon our failure to meet
schedule or performance requirements of our contracts. Our failure to accurately estimate the resources and time required for fixed-
price contracts or our failure to complete our contractual obligations within the time frame and costs committed could result in
reduced profits or, in certain cases, a loss for that contract. If the contract is significant, or we encounter issues that impact multiple
contracts, cost over-runs could have a material adverse effect on our business, financial condition and results of operations.

If we are unable to attract and retain a sufficient number of affordable trained engineers and other skilled workers, our ability
to pursue projects may be adversely affected and our costs may increase.

Our rate of growth and the success of our business depends upon our ability to attract, develop and retain a sufficient
number of affordable trained engineers and other skilled workers either through direct hire or acquisition of other firms employing
such professionals. The market for these professionals is competitive. If we are unable to attract and retain a sufficient number of
skilled personnel, our ability to pursue projects may be adversely affected, the costs of executing our existing and future projects
may increase, and our financial performance may decline.

We conduct a portion of our engineering and construction operations through joint ventures and partnerships exposing us to
risks and uncertainties, many of which are outside of our control.

We conduct a portion of our engineering, procurement and construction operations through large project-specific joint
ventures, where control may be shared with unaffiliated third parties. As with any joint venture arrangement, differences in views
among the joint venture participants may result in delayed decisions or in failures to agree on major issues. We also cannot control
the actions of our joint venture partners, including any nonperformance, default or bankruptcy of our joint venture partners, and we
typically share liabilities on a joint and several basis with our joint venture partners under these joint venture arrangements. If our
partners do not meet their contractual obligations, the joint venture may be unable to adequately perform and deliver its contracted
services requiring us to make additional investments or perform additional services to ensure the adequate performance and delivery
of services to our customer. We could be liable for both our obligations and those of our partners which may result in reduced
profits or, in some cases, significant losses on the project. Additionally, these factors could have a material adverse affect on the
business operations of the joint venture and, in turn, our business operations and reputation.

Operating through joint ventures in which we have a minority interest could result in us having limited control over many
decisions made with respect to projects and internal controls relating to projects. These joint ventures may not be subject to the
same requirements regarding internal controls and internal control reporting that we follow. As a result, internal control issues may
arise, which could have a material adverse effect on our financial condition and results of operation. Additionally, in order to
establish or preserve relationships with our joint venture partners, we may agree to risks and contributions of resources that are
proportionately greater than the returns we could receive, which could reduce our income and returns on these investments
compared to what we may have received if the risks and resources we contributed were always proportionate to our returns.

The nature of our engineering and construction business exposes us to potential liability claims and contract disputes which
may exceed or are excluded from existing insurance coverage.

We engage in engineering and construction activities for large facilities where design, construction or systems failures can
result in substantial injury or damage to employees or other third parties exposing us to legal proceedings, investigations and
disputes. The nature of our business results in clients, subcontractors and vendors occasionally presenting claims against us for
recovery of cost they incurred in excess of what they expected to incur or for which they believe they are not contractually liable.
When it is determined that we have liability, we may not be covered by insurance or, if covered, the dollar amount of these
liabilities may exceed our policy limits. Our professional liability coverage is on a “claims-made” basis covering only claims
actually made during the policy period currently in effect. In addition, even where insurance is maintained for such exposures, the
policies have deductibles, which result in us assuming exposure for a layer of coverage with respect to any such claims. Any
liability not covered by our insurance, in excess of our insurance limits or, if covered by insurance but subject to a high deductible,
could result in a significant loss for us, which may reduce our profits and cash available for operations.

We occasionally bring claims against project owners for additional cost exceeding the contract price or for amounts not
included in the original contract price. These types of claims occur due to matters such as owner-caused delays or changes from the
initial project scope, which may result in additional cost, both direct and indirect. Often, these claims can be the subject of lengthy
arbitration or litigation proceedings, and it is often difficult to accurately predict when these claims will be fully resolved. When
these types of events occur and unresolved claims are pending, we may invest significant working capital in projects to cover cost
overruns pending the resolution of the relevant claims. A failure to promptly recover on these types of claims could have a material
adverse impact on our liquidity and financial results.

International and political events may adversely affect our operations.

A significant portion of our revenue is derived from foreign operations, which exposes us to risks inherent in doing business
in each of the countries where we transact business. The occurrence of any of the risks described below could have a material
adverse effect on our business operations and financial performance. With respect to any particular country, these risks may
include, but not limited to:

•
•
•
•
•
•

expropriation and nationalization of our assets in that country;
political and economic instability;
civil unrest, acts of terrorism, force majeure, war or other armed conflict;
currency fluctuations, devaluations and conversion restrictions;
confiscatory taxation or other adverse tax policies;
governmental activities or judicial actions that limit or disrupt markets, restrict payments, limit the movement of
funds, result in the deprivation of contract rights or result in the inability for us to obtain or retain licenses required
for operation.

Due to the unsettled political conditions in many oil-producing countries and other countries where we provide
governmental logistical support, our financial performance is subject to the adverse consequences of war, the effects of terrorism,
civil unrest, strikes, currency controls and governmental actions. Our operations are conducted in areas that have significant
amounts of political risk. In addition, military action or continued unrest in the Middle East could impact the supply and price of oil
and gas, disrupt our operations in the region and elsewhere and increase our costs related to security worldwide.

We may have additional tax liabilities associated with our domestic and international operations.

We are subject to income taxes in the United States and numerous foreign jurisdictions, many of which are developing
countries. Significant judgment is required in determining our worldwide provision for income taxes due to lack of clear and
concise tax laws and regulations in certain developing jurisdictions. It is not unlikely that laws may be changed or clarified and
such changes may adversely affect our tax provisions. We are audited by various U.S. and foreign tax authorities and in the
ordinary course of our business there are many transactions and calculations where the ultimate tax determination may be uncertain.
Although we believe that our tax estimates are reasonable, the final outcome of tax audits and related litigation could be materially
different from that which is reflected in our financial statements.

We work in international locations where there are high security risks, which could result in harm to our employees and
contractors or substantial costs.

Some of our services are performed in high-risk locations, such as Iraq, Afghanistan, Nigeria, Algeria, Egypt and Saudi
Arabia where the country or location and surrounding area is suffering from political, social, economic issues, war or civil unrest.
In those locations where we have employees or operations, we have and may continue to incur substantial costs to maintain the
safety of our personnel. Despite these precautions, we have suffered the loss of employees and contractors which could expose us
to claims and litigation. In the future, the safety of our personnel in these and other locations may continue to be at risk, exposing
us to the potential loss of additional employees and contractors.

Demand for our services depends on demand and capital spending by customers in their target markets, many of which are
cyclical in nature.

Demand for many of our services in our commodity-based markets depends on capital spending by oil and natural gas
companies, including national and international oil companies, and by industrial, mining and power companies, which is directly
affected by trends in oil, natural gas and commodities prices. Capital expenditures for refining and distribution facilities by large
oil and gas companies have a significant impact on the activity levels of our businesses. Demand for LNG facilities for which we
provide construction services could decrease in the event of a sustained reduction in demand for crude oil or natural gas.
Perceptions of longer-term lower oil and natural gas prices by oil and gas companies or longer-term higher material and contractor
prices impacting facility costs can similarly reduce or defer major expenditures given the long-term nature of many large-scale
projects. Prices for oil, natural gas and commodities are subject to large fluctuations in response to relatively minor changes in
supply and demand, market uncertainty and a variety of other factors that are beyond our control. Factors affecting the prices of oil,
natural gas and other commodities include:

• worldwide political, social unrest, military and economic conditions;
•
•

the level of demand for oil, natural gas, industrial services and power generation;
governmental regulations or policies, including the policies of governments regarding the use of energy and the
exploration for and production and development of their oil and natural gas reserves;
a reduction in energy demand as a result of energy taxation or a change in consumer spending patterns;
global economic growth or decline;
the level of oil production by non-OPEC countries and the available excess production capacity within OPEC;
global weather conditions and natural disasters;
oil refining capacity;
shifts in end-customer preferences toward fuel efficiency and the use of natural gas;
potential acceleration of the development and expanded use of alternative fuels;
environmental regulation, including limitations on fossil fuel consumption based on concerns about its relationship
to climate change; and
reduction in demand for the commodity-based markets in which we operate.

•
•
•
•
•
•
•
•

•

Historically, the markets for oil and natural gas have been volatile and are likely to continue to be volatile in the future.

Our backlog is subject to unexpected adjustments and cancellations and, therefore, may not be a reliable indicator of our future
revenue or earnings.

As of December 31, 2012, our backlog was approximately $14.9 billion. We cannot guarantee that the revenue projected in
our backlog will be realized or profitable. Many of our contracts are subject to cancellation, termination or suspension at the
discretion of the customer. From time to time, changes in project scope may occur with respect to contracts reflected in our backlog
and could reduce the dollar amount of our backlog and the timing of the revenue and profits that we actually earn. Projects may
remain in our backlog for an extended period of time because of the nature of the project and the timing of the particular services or
equipment required by the project. Additionally, poor project performance could also impact our backlog and profits if it results in
termination of the contract. We cannot predict the impact that future economic conditions may have on our backlog which could
include a diminished ability to replace backlog once projects are completed and/or could result in the termination, modification or
suspension of projects currently in our backlog. Such developments could have a material adverse affect on our financial condition,
results of operations and cash flows.

Intense competition in the engineering and construction industry could reduce our market share and profits.

We serve markets that are highly competitive and in which a large number of multinational companies compete. These
highly competitive markets require substantial resources and capital investment in equipment, technology and skilled personnel.
Our projects are frequently awarded through a competitive bidding process, which is standard in our industry. We are constantly
competing for project awards based on pricing and the breadth and technical sophistication of our services. Any increase in
competition or reduction in our competitive capabilities could have a significant adverse impact on the margins we generate from
our projects as well as our ability to maintain or increase market share.

A portion of our revenues is generated by large, recurring business from certain significant customers. A loss, cancellation or
delay in projects by our customers in the future could negatively affect our revenues.

We provide services to a diverse customer base, including international and national oil and gas companies, independent
refiners, petrochemical producers, fertilizer producers and domestic and foreign governments. A considerable percentage of
revenue is generated from transactions with Chevron primarily from our Hydrocarbons business group and the U.S. government
from our IGP business group. Revenue from Chevron and the U.S. government in 2012 represented 29% and 9%, respectively, of
our total consolidated revenue.

If we are unable to enforce our intellectual property rights or if our intellectual property rights become obsolete, our competitive
position could be adversely impacted.

We utilize a variety of intellectual property rights in the provisioning of services to our customers. We view our portfolio of
process and design technologies as one of our competitive strengths and we use it as part of our efforts to differentiate our service
offerings. We may not be able to successfully preserve these intellectual property rights in the future and these rights could be
invalidated, circumvented, challenged or infringed upon. In addition, the laws of some foreign countries in which our services may
be sold do not protect intellectual property rights to the same extent as the laws of the United States. Because we license
technologies from third parties, there is a risk that our relationships with licensors may terminate, expire or be interrupted or
harmed. In some, but not all cases, we may be able to obtain the necessary intellectual property rights from alternative sources. If
we are unable to protect and maintain our intellectual property rights, or if there are any successful intellectual property challenges
or infringement proceedings against us, our ability to differentiate our service offerings could diminish. In addition, if our
intellectual property rights or work processes become obsolete, we may not be able to differentiate our service offerings and some
of our competitors may be able to offer more attractive services to our customers. As a result, our business and financial
performance could be materially and adversely affected.

Our current business strategy includes acquisitions which present certain risks and uncertainties.

We seek business acquisition activities as a means of broadening our offerings and capturing additional market opportunities
by our business units and we may be exposed to certain additional risks resulting from these activities. These risks include the
following:

• Valuation methodologies may not accurately capture the value proposition;
•

Future completed acquisitions may not be integrated within our operations with the efficiency and effectiveness
initially expected resulting in a potentially significant detriment to the associated product service line financial
results, and pose additional risks to our operations as a whole;

• We may have difficulty managing the growth from acquisition activities;
• Key personnel within an acquired organization may resign from their related positions resulting in a significant loss

•

to our strategic and operational efficiency associated with the acquired company;
The effectiveness of our daily operations may be reduced by the redirection of employees and other resources to
acquisition activities;

• We may assume liabilities of an acquired business (e.g. litigation, tax liabilities, contingent liabilities, environmental
issues), including liabilities that were unknown at the time of the acquisition, that pose future risks to our working
capital needs, cash flows and the profitability of related operations;

• We may assume unprofitable projects that pose future risks to our working capital needs, cash flows and the

•

profitability of related operations;
Business acquisitions may include substantial transactional costs to complete the acquisition that exceed the
estimated financial and operational benefits;
Future acquisitions may require us to obtain additional equity or debt financing, which may not be available on
attractive terms. Moreover, to the extent an acquisition transaction results in additional goodwill, it will reduce our
tangible net worth, which might have an adverse effect on our credit capacity.

An impairment of all or part of our goodwill and/or our intangible assets could have a material adverse impact to our net
earnings and net worth.

As of December 31, 2012, we had $779 million of goodwill and $99 million of intangible assets recorded on our
consolidated balance sheet. Goodwill represents the excess of cost over the fair market value of net assets acquired in business
combinations. If our market capitalization drops significantly below the amount of net equity recorded on our balance sheet, it
might indicate a decline in our fair value and would require us to further evaluate whether our goodwill has been impaired. We
perform an annual and an interim analysis, if appropriate, of our goodwill to determine if it has become impaired. The analysis
requires us to make assumptions in estimates of fair value of our reporting units. If actual results are significantly different from the
estimates, we might be required to impair a portion of our goodwill, as occurred during 2012 with respect to our Minerals reporting
unit, which is part of our IGP segment, resulting in a $178 million impairment of goodwill. An impairment of all or a part of our
goodwill and/or intangible assets could have a material adverse impact to our net earnings and net worth.

We ship a significant amount of cargo using seagoing vessels exposing us to certain maritime risks.

We execute different projects in remote locations around the world. Depending on the type of contract, location and the
nature of the work, we may charter vessels under time and bareboat charter parties that assume certain risks typical of those
agreements. Such risks may include damage to the ship and liability for cargo and liability which charterers and vessel operators
have to third parties “at law”. In addition, we ship a significant amount of cargo and are subject to hazards of the shipping and
transportation industry.

We rely on information technology systems to conduct our business, and disruption, failure or security breaches of these systems
could adversely affect our business and results of operations.

We rely heavily on information technology (IT) systems in order to achieve our business objectives. We also rely upon
industry accepted security measures and technology to securely maintain confidential and proprietary information maintained on
our IT systems. However, our portfolio of hardware and software products, solutions and services and our enterprise IT systems
may be vulnerable to damage or disruption caused by circumstances beyond our control such as catastrophic events, power outages,
natural disasters, computer system or network failures, computer viruses, cyber attacks or other malicious software programs. The
failure or disruption of our IT systems to perform as anticipated for any reason could disrupt our business and result in decreased
performance, significant remediation costs, transaction errors, loss of data, processing inefficiencies, downtime, litigation and the
loss of suppliers or customers. A significant disruption or failure could have a material adverse effect on our business operations,
financial performance and financial condition. We have experienced limited and infrequent security threats, none of which we
considered to be significant to our business or results of operations.

We are implementing a new enterprise resource planning software system ("ERP") and failure to implement the ERP
successfully could adversely affect our business and results of operations.

We are incurring costs associated with designing and implementing a new company-wide enterprise ERP with the objective
of gradually migrating to the new system. We had capital expenditures of $53 million in 2012 for design and implementation. In
addition we incurred expenses related to the ERP initiative of $20 million during 2012. Capital expenditures and expenses for ERP
for 2013 and beyond will depend upon the pace of conversion. If implementation is not executed successfully, this could result in
business interruptions. If we do not complete the implementation of ERP timely and successfully, we may incur additional costs
associated with completing this project and a delay in our ability to improve existing operations, support future growth and enable
us to take advantage of new applications and technologies.

Risks Related to U.S. Government Operations of our Business

The U.S. government awards its contracts through a rigorous competitive process and our efforts to obtain future contract
awards from the U.S. government may be unsuccessful.

The U.S. government conducts a rigorous competitive process for awarding most contracts. In the services arena, the U.S.
government uses multiple contracting approaches. Historically, omnibus contract vehicles, such as LogCAP, have been used for
work that is done on a contingency or as-needed basis. In more predictable “sustainment” environments, contracts may include
both fixed-price and cost-reimbursable elements. The U.S. government has also favored multiple award task order contracts in
which several contractors are selected as eligible bidders for future work. Such processes require successful contractors to
continually anticipate customer requirements and develop rapid-response bid and proposal teams as well as have supplier
relationships and delivery systems in place to react to emerging needs. We will face rigorous competition and pricing pressures for
any additional contract awards from the U.S. government, and we may be required to qualify or continue to qualify under the
various multiple award task order contract criteria. It may be more difficult for us to win future awards from the U.S. government
and we may have other contractors sharing in any U.S. government awards that we win. In addition, negative publicity regarding
findings stemming from Defense Contract Audit Agency (“DCAA”) audits and Congressional investigations may adversely affect
our ability to obtain future awards. See “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of
Analysis - U.S. Government Matters.”

Demand for our services provided under U.S. government contracts are directly affected by spending and capital expenditures
by our customers.

We derive a portion of our revenue from contracts with agencies and departments of the U.S. government which is directly
affected by changes in government spending and availability of adequate funding. Additionally, U.S. government regulations
generally include the right for government agencies to modify, delay, curtail, renegotiate or terminate contracts at their convenience
any time prior to their completion. As a defense contractor, our financial performance is impacted by the allocation and
prioritization of U.S. defense spending and sequestration is one of those impacts. Factors that could impact current and future U.S.
government spending include:

•
•
•
•
•

policy and/or spending changes implemented by the current administration, DoD or other government agencies;
changes, delays or cancellations of U.S. government programs or requirements;
adoption of new laws or regulations that affect companies providing services to the U.S. government;
curtailment of the U.S. governments’ outsourcing of services to private contractors; and
level of political instability due to war, conflict or natural disasters.

We face uncertainty with respect to our U.S. government contracts due to the fiscal and economic challenges facing the U.S.
government, including the potential for sequestration and issues surrounding the U.S. national debt ceiling. Potential contract
cancellations, modifications or terminations may arise from resolution of these issues and could cause our revenues, profits and
cash flows to be lower than our current projections. The loss of work we perform for the U.S. government or other decreases in
governmental spending and outsourcing could have a material adverse effect on our business, results of operations and cash flow.

Our U.S. government contract work is regularly reviewed and audited by our customer, U.S. government auditors and others,
and these reviews can lead to withholding or delay of payments to us, non-receipt of award fees, legal actions, fines, penalties
and liabilities and other remedies against us.

U.S. government contracts are subject to specific regulations such as the Federal Acquisition Regulation (“FAR”), the Truth
in Negotiations Act, the Cost Accounting Standards (“CAS”), the Service Contract Act and DoD security regulations. Failure to
comply with any of these regulations, requirements or statutes may result in contract price adjustments, financial penalties and
contract termination. Our U.S. government contracts are subject to audits, cost reviews and investigations by U.S. government
contracting oversight agencies such as the DCAA. The DCAA reviews the adequacy of, and our compliance with, our internal
control systems and policies, including our labor, billing, accounting, purchasing, property, estimating, compensation and
management information systems. The DCAA has the authority to conduct audits and reviews to determine if KBR is complying
with the requirements under the FAR and CAS, pertaining to the allocation, period assignment, allowability and allocation of costs
assigned to U.S. government contracts. The DCAA presents its report findings to the Defense Contract Management Agency
(“DCMA”). Should the DCMA determine that we have not complied with the terms of our contract and applicable statutes and
regulations, payments to us may be disallowed which could result in adjustments to previously reported revenues and refunding of
previously collected cash proceeds. Additionally, we may be subject to qui tam litigation brought by private individuals on behalf
of the U.S. government under the Federal False Claims Act, which could include claims for treble damages.

Given the demands of working for the U.S. government, we expect that from time to time we will have disagreements or
experience performance issues with our government customers. If performance issues arise under any of our government contracts,
the government retains the right to pursue remedies, which could include termination under any affected contract. If any contract
were so terminated, we may not receive award fees under the affected contract and our ability to secure future contracts could be
adversely affected, although we would expect to receive payment for amounts owed for our allowable costs under cost-
reimbursable contracts. Other remedies that our government customers may seek for performance issues include sanctions such as
forfeiture of profits, suspension of payments, fines and suspensions or debarment from doing business with the government.
Further, the negative publicity that could arise from disagreements with our customers or sanctions as a result thereof, could have
an adverse effect on our reputation in the industry, reduce our ability to compete for new contracts and may also have a material
adverse effect on our business, financial condition, results of operations and cash flow.

Risks Related to Governmental Regulations and Law

We are subject to certain U.S. laws and regulations, which are the subject of rigorous enforcement by the U.S. government.

To the extent that we export products, technical data and services outside of the United States we are subject to laws and
regulations governing trade and exports, including but not limited to, the International Traffic in Arms Regulations, the Export
Administration Regulations and trade sanctions against embargoed countries, which are administered by the Office of Foreign Asset
Control within the Department of the Treasury. A failure to comply with these laws and regulations could result in civil and/or
criminal sanctions, including the imposition of fines upon us as well as the denial of export privileges and debarment from
participation in U.S. government contracts. Additionally, we may be subject to qui tam litigation brought by private individuals on
behalf of the U.S. government under the Federal False Claims Act, which could include claims for treble damages. U.S.
government contract violations could result in the imposition of civil and criminal penalties or sanctions, contract termination,
forfeiture of profit and/or suspension of payment, any of which could make us lose our status as an eligible U.S. government
contractor and cause us to suffer serious harm to our reputation. Any suspension or termination of our U.S. government contractor
status could have a negative adverse impact to our business, financial condition or results of operations.

We are subject to anti-bribery laws in the U.S. and other jurisdictions, violations of which could include suspension or
debarment of our ability to contract with the United States, state or local governments, U.S. government agencies or the U.K.
MoD, third party claims, loss of customers, adverse financial impact, damage to reputation and adverse consequences on
financing for current or future projects.

The Foreign Corrupt Practices Act (“FCPA”) in the U.S., the U.K. Anti-Bribery Act and similar anti-bribery laws in other
jurisdictions generally prohibit companies and their intermediaries from making improper payments to non-U.S. officials for the
purpose of obtaining or retaining business. Our policies mandate compliance with these anti-bribery laws. We operate in many
parts of the world that have experienced governmental corruption to some degree and, in certain circumstances, strict compliance
with anti-bribery laws may conflict with local customs and practices. We train our staff concerning FCPA issues, and we also
inform our partners, subcontractors, agents and other third parties who work for us or on our behalf that they must comply with the
requirements of the FCPA and other anti-corruption laws. We also have procedures and controls in place to monitor internal and
external compliance. We cannot provide complete assurance that our internal controls and procedures will always protect us from
the reckless or criminal acts committed by our employees or third parties working on our behalf. If we are found to be liable for
violations of these laws (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others), we could
suffer from criminal or civil penalties or other sanctions which could have a material adverse effect on our business.

Risks Related to Financial Conditions and Markets

Current or future economic conditions in the credit markets may negatively affect the ability to operate our or our customers’
businesses, finance working capital, implement our acquisition strategy, and access our cash and short-term investments.

We finance most of our operations using cash provided by operations, but also depend on the availability of credit to grow
our businesses. Unfavorable economic conditions have brought uncertainty to the capital and credit markets in the U.S. and abroad,
which could make it more difficult for us to raise additional capital or obtain additional financing. Our ability to obtain such
additional capital or financing will depend in part upon prevailing market conditions as well as conditions in our business and our
operating results, and those factors may affect our efforts to arrange additional financing on terms that are satisfactory to us. We
cannot be certain that additional funds will be available if needed to make future investments in certain projects, take advantage of
acquisitions or other opportunities or respond to competitive pressures. If additional funds are not available, or are not available on
terms satisfactory to us, there could be a material adverse impact on our business and financial performance.

Disruptions of the credit markets could also adversely affect our clients’ borrowing capacity, which supports the
continuation and expansion of projects worldwide, and could result in contract cancellations or suspensions, project delays and
payment delays or defaults by our clients. In addition, clients may choose to make fewer capital expenditures or otherwise slow
their spending on our services or to seek contract terms more favorable to them. Our government clients may face budget deficits
that prohibit them from funding proposed and existing projects or that cause them to exercise their right to terminate our contracts
with little or no prior notice. Furthermore, any financial difficulties suffered by our subcontractors or suppliers could increase our
cost or adversely impact project schedules. These disruptions could materially impact our backlog and financial performance.

In addition, we are subject to the risk that the counterparties to our Credit Agreement may be unable to meet their
obligations if they suffer catastrophic demand on their liquidity that will prevent them from fulfilling their contractual obligation to
us. We also routinely enter into contracts with counterparties, including vendors, suppliers and subcontractors that may be
negatively impacted by events in the credit markets. If those counterparties are unable to perform their obligations to us or our
clients, we may be required to provide additional services or make alternate arrangements on less favorable terms with other parties
to ensure adequate performance and delivery of service to our clients. These circumstances could also lead to disputes and
litigation with our partners or clients, which could have a material adverse impact on our reputation, business, financial condition
and results of operations.

Furthermore, our cash balances and short-term investments are maintained in accounts held at major banks and financial
institutions located primarily in North America and the United Kingdom. Deposits are in amounts that exceed available insurance.
Although none of the financial institutions in which we hold our cash and investments have gone into bankruptcy, been forced into
receivership or have been seized by their governments, there is a risk that this may occur in the future. If this were to occur, we
would be at risk of not being able to access our cash which may result in a temporary liquidity crisis that could impede our ability to
fund operations.

We may be unable to obtain new contract awards if we are unable to provide our customers with bonds, letters of credit or other
credit enhancements.

Customers may require us to provide credit enhancements, including surety bonds, letters of credit or bank guarantees. We
are often required to provide performance guarantees to customers to indemnify the customer should we fail to perform our
obligations under the contract. Failure to provide a bond on terms required by a customer may result in an inability to bid on or win
a contract award. Historically, we have had adequate bonding capacity but such bonding beyond the capacity of our Credit
Agreement is generally at the provider’s sole discretion. Due to events that affect the banking and insurance markets generally,
bonding may be difficult to obtain or may only be available at significant cost. Moreover, many projects are often very large and
complex, which often necessitates the use of a joint venture, often with a market competitor, to bid on and perform the contract.
However, entering into joint ventures or partnerships exposes us to the credit and performance risk of third parties, many of whom
may not be financially strong. If our joint ventures or partners fail to perform, we could suffer negative results. In addition, future
projects may require us to obtain letters of credit that extend beyond the term of our current Credit Agreement. Any inability to bid
for or win new contracts due to the failure of obtaining adequate bonding, letters of credit and/or other customary credit
enhancements could have a material adverse effect on our business prospects and future revenue.

Our Credit Agreement imposes restrictions that limit our operating flexibility and may result in additional expenses, and this
credit agreement may not be available if financial covenants are violated or if an event of default occurs.

Our Credit Agreement provides a credit line of up to $1.0 billion, and expires in December 2016. It contains a number of
covenants restricting, among other things, our ability to incur liens and indebtedness, sell assets, repurchase our equity shares and
make certain types of investments. We are also subject to certain financial covenants, including maintenance of a maximum ratio
of consolidated debt to consolidated EBITDA and a minimum consolidated net worth. If we fail to meet the covenants, or an event
of default occurs, the credit line would not be available unless the necessary waivers or amendments of lenders participating in the
bank syndicate could be obtained.

A breach of any covenant or our inability to comply with the required financial ratios could result in a default under our
Credit Agreement, and we can provide no assurance that we will be able to obtain the necessary waivers or amendments from our
lenders to remedy a default. In the event of any default not cured or waived, the lenders are not obligated to provide funding or
issue letters of credit and could elect to require us to apply available cash to collateralize any outstanding letters of credit and
declare any outstanding borrowings, together with accrued interest and other fees, to be immediately due and payable, thus
requiring us to apply available cash to repay any borrowings then outstanding. If we are unable to cash collateralize our letters of
credit or repay borrowings with respect to our Credit Agreement when due, our lenders could proceed against the guarantees of our
major domestic subsidiaries. If any future indebtedness under our Credit Agreement is accelerated, we can provide no assurance
that our assets would be sufficient to repay such indebtedness in full.

Provisions in our charter documents, Delaware law and our Credit Agreement may inhibit a takeover or impact operational
control which could adversely affect the value of our common stock.

Our certificate of incorporation and bylaws, as well as Delaware corporate law, contain provisions that could delay or
prevent a change of control or changes in our management that a stockholder might consider favorable. These provisions include,
among others, prohibiting stockholder action by written consent, advance notice for raising business or making nominations at
meetings of stockholders and the issuance of preferred stock with rights that may be senior to those of our common stock without
stockholder approval. These provisions would apply even if a takeover offer may be considered beneficial by some of our
stockholders. If a change of control or change in management is delayed or prevented, the market price of our common stock could
decline. Additionally, our Credit Agreement contains a default provision that is triggered upon a change in control of at least 25%.

We are subject to significant foreign exchange and currency risks that could adversely affect our operations, and our ability to
reinvest earnings from operations, as well as mitigate our foreign exchange risk through hedging transactions may be limited.

We generally attempt to denominate our contracts in U.S. Dollars or in the currencies of our costs. However, we do enter
into contracts that subject us to currency risk exposure, primarily when our contract revenue is denominated in a currency different
from the contract costs. A significant portion of our consolidated revenue and consolidated operating expenses are in foreign
currencies. As a result, we are subject to significant foreign currency risks, including risks resulting from changes in foreign
exchange rates and limitations on our ability to reinvest earnings from operations in one country to fund the financing requirements
of our operations in other countries.

The governments of certain countries have or may in the future impose restrictive exchange controls on local currencies and
it may not be possible for us to engage in effective hedging transactions to mitigate the risks associated with fluctuations of a
particular currency. We are often required to pay all or a portion of our costs associated with a project in the local currency. As a
result, we generally attempt to negotiate contract terms with our customer, who is often affiliated with the local government, or has
a significant local presence, to provide that we are only paid in the local currency for amounts that match our local expenses. If we
are unable to match our local currency costs with revenue in the local currency, we would be exposed to the risk of adverse changes
in currency exchange rates.

If we need to sell or issue additional common shares to finance future acquisitions, our existing shareholder ownership could be
diluted.

Part of our business strategy is to expand into new markets and enhance our position in existing markets both domestically
and internationally through the acquiring and merging of complementary businesses. To successfully fund and complete such
potential acquisitions, we may issue additional equity securities that may result in dilution of our existing shareholder ownership
earnings per share.

We make equity investments in privately financed projects in which we could sustain significant losses.

We participate in privately financed projects that enable governments and other customers to finance large-scale projects,
such as major military equipment, capital project and service purchases. These projects typically include the facilitation of non-
recourse financing, the design and construction of facilities and the provision of operation and maintenance services for an agreed
upon period after the facilities have been completed. We may incur contractually reimbursable costs and typically make an equity
investment prior to an entity achieving operational status or receiving project financing. If a project is unable to obtain financing,
we could incur losses on our equity investments and any related contractual receivables. After completion of these projects, the
return on our equity investments can be dependent on the operational success of the project and market factors, which may not be
under our control. As a result, we could sustain a loss on our equity investment in these projects.

Item 1B. Unresolved Staff Comments

None.

Item 2. Properties

We own or lease properties in domestic and foreign locations. The following locations represent our major facilities.

Location

Houston, Texas

Newark, Delaware

Arlington, Virginia

South Brisbane, Perth,
Australia

Birmingham, Alabama

Leatherhead, United
Kingdom

Greenford, Middlesex
United Kingdom

Owned/Leased

Leased(1)

Leased

Owned

Description
Office facilities

Office facilities

Office and project
facilities

Campus facility

Business Segment

All and Corporate

All

IGP

All

Office facilities

Hydrocarbons

(1)

In November 2012, our 50% owned joint venture sold the office building in which we lease office space for our corporate
headquarters and business unit offices in Houston, Texas. We will continue to lease space from the new owner under
essentially the same terms through the expiration of the lease in 2030.

We also own or lease numerous small facilities that include sales offices and project offices throughout the world and lease
office space in other buildings owned by unrelated parties. All of our owned properties are unencumbered and we believe all
properties that we currently occupy are suitable for their intended use. In the fourth quarter of 2012, we sold a former campus
facility located on Clinton Drive in Houston, Texas.

Item 3. Legal Proceedings

Information relating to various commitments and contingencies is described in “Risk Factors” contained in Part I of this
Annual Report on Form 10-K and “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of
Operations” and in Notes 9 and 10 to our consolidated financial statements and the information discussed therein is incorporated by
reference into this Item 3.

Item 4. Mine Safety Disclosures

None.

PART II

Item 5. Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

Our common stock is traded on the New York Stock Exchange under the symbol “KBR.” The following table sets forth, on
a per share basis for the periods indicated, the high and low sale prices per share for our common stock as reported by the New
York Stock Exchange and dividends declared. In the fourth quarter of 2012, we declared dividends of $0.05 per share on
October 22, 2012, and $0.08 per share on December 18, 2012.

Fiscal Year 2012

First quarter ended March 31, 2012

Second quarter ended June 30, 2012

Third quarter ended September 30, 2012

Fourth quarter ended December 31, 2012

Fiscal Year 2011

First quarter ended March 31, 2011

Second quarter ended June 30, 2011

Third quarter ended September 30, 2011

Fourth quarter ended December 31, 2011

Common Stock Price Range

High

Low

Dividends
Declared
Per Share

38.00

35.97

32.10

31.84

38.28

38.79

39.34

30.17

27.68

22.73

22.09

25.95

28.43

33.79

23.29

20.86

0.05

0.13

0.05

At January 31, 2013, there were 126 shareholders of record. In calculating the number of shareholders, we consider clearing

agencies and security position listings as one shareholder for each agency or listing.

On August 26, 2011, KBR announced that its Board of Directors authorized a share repurchase program to repurchase up to
10 million of our outstanding common shares. The authorization does not specify an expiration date. The following is a summary
of share repurchases of our common stock settled during the three months ended December 31, 2012. We also have a share
maintenance program to repurchase shares based on vesting and other activity under our equity compensation plans. Shares
purchased under "Employee transactions" in the table below reflects shares acquired from employees in connection with the
settlement of income tax and related benefit withholding obligations arising from vesting of restricted stock units.

Purchase Period
October 1 – 30, 2012

Repurchase program

Employee transactions

November 2 – 30, 2012

Repurchase program

Employee transactions

December 7 – 31, 2012

Repurchase program

Employee transactions

Total

Repurchase program

Employee transactions

Total Number
of Shares
Purchased (b)

Average
Price Paid
per Share

Total Number of
Shares Purchased
as Part of Publicly
Announced Plans
or Programs (b)

Maximum Number of
Shares that May Yet Be
Purchased Under the
Plans or Programs (a)

— $

—

1,174

30.45

— $

111,500

3,631

111,500

4,871

—

26.97

29.34

29.67

29.34

29.82

—

3,901

—

3,901

—

7,588,665

—

7,588,665

—

7,584,764

—

7,584,764

—

(a)

(b)

Represents remaining common shares that may be repurchased pursuant to the August 26, 2011 announced share repurchase
program.
The difference between total number of shares purchased and total number of shares purchased as part of publicly
announced plans or programs pertains to repurchases under our share maintenance program.

Under our Credit Agreement, we are permitted to repurchase our common stock, provided that no such repurchases shall be
made from the proceeds borrowed under the Credit Agreement, and that the aggregate purchase price and dividends paid after
December 2, 2012, does not exceed the Distribution Cap. At December 31, 2012, the remaining availability under the Distribution
Cap was approximately $659 million. The declaration, payment or increase of any future dividends will be at the discretion of our
Board of Directors and will depend upon, among other things, future earnings, general financial condition and liquidity, success in
business activities, capital requirements and general business conditions.

Performance Graph

The chart below compares the cumulative total shareholder return on our common shares for the five-year period ended
December 31, 2012, with the cumulative total return on the Dow Jones Heavy Construction Industry Index and the Russell 1000
Index for the same period. The comparison assumes the investment of $100 on December 31, 2007, and reinvestment of all
dividends. The shareholder return is not necessarily indicative of future performance.

KBR

12/31/2007

12/31/2008

12/31/2009

100.00

39.53

49.99

Dow Jones Heavy Construction

Russell 1000

100.00

44.74

60.98

50.92

76.52

12/31/2010 12/30/2011
74.43
$
53.49
86.69

80.93
65.12
87.13

12/31/2012

80.45

64.62

98.76

Item 6. Selected Financial Data

The following table presents selected financial data for the last five years. You should read the following information in
conjunction with “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations” and the
consolidated financial statements and the related notes to the consolidated financial statements.

2012

Years Ended December 31,
2010

2009

2011

2008

(In millions, except for per share amounts)

Statements of Operations Data:

Total revenue

Operating income

Impairment of goodwill and long-lived assets (a)

Income from continuing operations, net of tax

Income from discontinued operations, net of tax (b)

Net income attributable to noncontrolling interests

Net income attributable to KBR

Basic net income attributable to KBR per share:

—Continuing operations

—Discontinued operations (b)

Basic net income attributable to KBR per share

Diluted net income attributable to KBR per share:

—Continuing operations

—Discontinued operations (b)

Diluted net income attributable to KBR per share

Basic weighted average shares outstanding

Diluted weighted average shares outstanding

Cash dividends declared per share (d)

Balance Sheet Data (as of the end of period):

Cash and equivalents

Net working capital

Total assets

Non-recourse project-finance debt

Total shareholders’ equity

Other Financial Data:

Backlog at year end

Gross operating margin percentage

Capital expenditures (c)

Depreciation and amortization expense

7,921

9,261

299

180

202

—

(58)

144

0.97

—

0.97

—

0.97

148

149

0.28

1,053

1,391

5,767

2,511

14,931

3.8%

587

—

540

—

(60)

480

3.18

—

3.18

3.16

—

3.16

150

151

0.20

966

1,158

5,673

2,442

10,931

6.3%

12,105

11,581

10,099
609
5
395
—
(68 )

327

2.08
—
2.08

2.07
—
2.07
156
157
0.15

786
923
5,417
101
2,204

536

364

—

(74)

290

1.80

—

1.80

1.79

—

1.79

160

161

0.20

941

1,350

5,327

—

2,296

12,041

14,098

6.0 %

4.4%

541

—

356

(48)

319

1.84

0.07

1.91

1.84

0.07

1.90

166

167

0.25

1,145

1,099

5,884

—

2,034

14,097

4.7%

(a) In accordance with ASC 350-20, the goodwill of our Minerals reporting unit, which is part of our IGP segment, was written
down to its implied fair value of $85 million from its carrying value of $263 million at December 31, 2011, resulting in an
impairment charge of $178 million in the third quarter of 2012. Included in 2009 is a goodwill impairment charge of $6
million related to the Allstates staffing business. Included in 2012 and 2010 are impairment of long-lived asset charges of
$2 million and $5 million, respectively, primarily related to equipment, land and buildings.

(b) We completed the sale of the Production Services group in May 2006 and the disposition of our 51% interest in Devonport
Management Limited (“DML”) in June 2007. The results of operations of the Production Services group and DML for all
periods presented have been reported as discontinued operations.

(c) Capital expenditures do not include expenditures related to the noncash investing activities for the purchase of computer

software of $19 million for the year ended December 31, 2010.

(d) In 2012, we declared five dividends totaling $0.28 per share. In each quarter during 2012, we declared a dividend $0.05
per share. In the fourth quarter of 2012, we declared an additional dividend of $0.08 per share on December 18, 2012.

Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Introduction

Management’s discussion and analysis (“MD&A”) should be read in conjunction with the consolidated financial statements

and related notes included in Item 8 of this Annual Report.

Executive Overview

Business Environment

Hydrocarbon Markets. We provide a full range of engineering, procurement and construction services for large and
complex upstream and downstream projects, including LNG and GTL facilities, onshore and offshore oil and gas production
facilities, refining, petrochemicals, biofuels and other projects throughout the world. Our projects are generally long term in nature
and are impacted by factors including market conditions, financing arrangements, governmental approvals and environmental
matters. Demand for our services depends primarily on our customers' capital expenditures in our market sectors.

Capital expenditures in our petroleum and petrochemical markets are driven by global and regional economic growth
expectations reflected in a long global spending cycle. The spending cycle is moderated by fluctuations in crude oil prices and
chemical feedstock costs including natural gas prices, and is also partially subject to volatility of financial markets. The
hydrocarbons market in most international regions is improving from the downturn that occurred as a result of the worldwide
economic recession. We now see long term growth in energy projects including demand for related licensed process technologies,
offshore oil and gas production, LNG, biofuels, motor fuels, chemicals and fertilizers. Upstream and downstream investment plans
are advancing in such resource rich areas as the Middle East, Brazil, North Sea and East and West Africa. LNG prospects continue
to develop in the Asia-Pacific region, as well as in East Africa and North America as a result of the recent gas discoveries. Each of
these trends lends to our particular capability to deliver large projects in remote locations and harsh environments.

Abundant shale gas supplies and resulting low prices in North America are driving renewed interest in petrochemical project
investments. Feasibility studies and front-end engineering and design projects continue to grow, reflecting clients’ intentions to
invest in capital intensive energy projects that utilize our process technologies and EPC project delivery skills.

Infrastructure, Government and Power Markets (“IGP”). A significant portion of our IGP business group’s current
activities supports the United States’ and the United Kingdom’s government operations in Iraq, Afghanistan and in other parts of
the Middle East region. As a defense contractor, our financial performance is impacted by the allocation and prioritization of U.S.
defense spending, including the effects of sequestration. The logistics support services we provide to the U.S. government are
delivered under the LogCAP IV contract and other competitively bid contracts. As a result of withdrawal of U.S. combat troops in
Iraq, we demobilized our operations under the LogCAP III contract, which effectively ended in December 2011, while continuing
to support the U.S. Department of State's presence in Iraq under LogCAP IV. Although we expect the volume of services we
provide to the U.S. and U.K. governments in the Middle East to continue to decline as troop counts are drawn down, we anticipate
increased spending for logistics and infrastructure for these clients as troops and equipment return to home base. We also view
increased infrastructure spending by Middle Eastern governments as a core opportunity.

We operate in diverse civil infrastructure markets, including transportation, water and waste treatment and facilities. In
addition to U.S. state, local and federal agencies, we provide these services to governments around the world including the U.K.,
Australia and the Middle East. There has been a general trend of under-investment in public infrastructure, particularly related to
the quality of water, wastewater, roads and transit, rail, airports and educational facilities, where demand for expanded and
improved infrastructure has historically outpaced funding. We have seen increased activity related to these types of projects
particularly in the Middle East; however, the global economic recession has caused markets to remain flat in the U.S. and the U.K.,
which has resulted in delays or slow start-ups to major projects.

In the industrial sector, we operate in a number of markets, including utility and non-utility power, forest products, advanced
manufacturing, mining, minerals and metals and consumer products, both domestically and internationally. Forest products,
advanced manufacturing and consumer products are experiencing modest market improvements. However, the mining, minerals
and metals markets are experiencing a decline driven by U.S. demand for commodities. We see modest market improvements
internationally related to mining, minerals and metals markets driven by international commodity demand growth. In the power
sector, we serve regulated utilities, power cooperatives, municipalities and various non-regulated providers, primarily in the U.S.
and U.K. markets. The power sector continues to be driven by long-term economic and demographic trends and changes in
environmental regulations. Projects in the power sector are currently concentrated in emissions control, repowering, renewable
power and new gas-fired power generation.

We provide a wide range of construction and maintenance services to a variety of industries in the U.S. and Canada,
including forest products, power, commercial and institutional buildings, general industrial and manufacturing. Demand for
industrial construction services is increasing markedly in Canada, while the commercial building market shows signs of
improvement.

For a more detailed discussion of the results of operations for each of our business groups and business units, corporate

general and administrative expense, income taxes and other items, see “Results of Operations” section.

Summary of Consolidated Results

2012 compared to 2011

Consolidated revenue in 2012 decreased $1.3 billion, or 14%, to $7.9 billion compared to $9.3 billion in 2011 primarily due
to declines in the IGP business group, mainly as a result of the December 2011 completion of operations in Iraq under the LogCAP
III contract and lower progress on Minerals projects. The decrease was also due to lower project activity and project completions
on the Escravos, Skikda and Pearl GTL projects. Partially offsetting these declines in revenue were aggregate increases of $612
million on increased activity on the Gorgon project and the EPC phase of the Ichthys LNG project in 2012, as well as milestone
incentive awards for the Gorgon LNG project. Also, P&I revenue increased by $130 million in 2012 compared to 2011 primarily
due to new project awards, including an air emissions controls system project, and increased volume and progress on existing
projects awarded in late 2011 and early 2012, such as coal gasification and waste-to-energy expansion projects.

Consolidated operating income in 2012 decreased $288 million, or 49%, to $299 million compared to $587 million in 2011
mainly due to a $178 million goodwill impairment charge of our Minerals reporting unit and the decline in operations in NAGL of
$145 million which was primarily due to the completion of operations in Iraq under the LogCAP III contract. In addition, operating
income from Services and Minerals declined $82 million and $54 million, respectively, in 2012. Operating income from Services
declined due to increased estimated costs to complete several U.S. construction fixed-price projects and the decline in our U.S.
Construction business. The decline in Minerals is a result of additional project costs and liquidated damages related to two projects
in Indonesia associated with issues encountered during the commissioning and pre-commissioning phase of these projects. Partially
offsetting this decline was increased income in 2012 from our Gas Monetization reporting unit of $188 million as a result of
increased activity from the Gorgon, Skikda and Ichthys LNG projects, that included change orders which revised estimated cost to
complete the Skikda LNG project, as well as milestone awards for the Gorgon LNG project.

2011 compared to 2010

Consolidated revenue in 2011 decreased $838 million, or 8%, to $9.3 billion compared to $10.1 billion in 2010 primarily
due to declines in the IGP and Services business groups. The decrease in IGP business group revenue included a $1.1 billion
decline resulting from an overall reduction in volume for U.S. military support activities, primarily in Iraq, under our LogCAP III
contract. In 2011, the total number of staff working on the LogCAP III contract decreased by 76% including direct hires,
subcontractors and local hires as a result of demobilization. The Services business group experienced a $165 million decline in
revenue for 2011 primarily driven by the completion of several large projects in the U.S. and Canada. Revenue increased in our
Hydrocarbons business group by $289 million primarily driven by further progress on our LNG and GTL projects in Gas
Monetization as well as additional phase awards and new technical service projects in Oil & Gas.

Consolidated operating income in 2011 decreased $22 million, or 4%, to $587 million compared to $609 million in 2010.
Operating income in 2011 from the IGP business group was down $6 million. The decline was primarily due to lower activity on
our LogCAP III contract but offset by income from the Aspire project as well as increased activity on NATO contracts in
Afghanistan. Services operating income declined $44 million primarily due to the completion or winding-down of several large
projects in the U.S. and Canada. Operating income from Hydrocarbons increased by $8 million largely due to new projects in
Oil & Gas and Downstream. Operating income from Ventures increased by $9 million primarily due to improved performance
from the EBIC ammonia plant in Egypt.

Acquisition of Roberts & Schaefer Company

On December 21, 2010, we completed the acquisition of 100% of the outstanding common shares of ENI Holdings, Inc.
(“ENI”). ENI is the parent to the Roberts & Schaefer Company (“R&S”), a privately held, EPC services company for material
handling and processing systems. Headquartered in Chicago, Illinois, R&S provides services and associated material handling
infrastructure to customers in the mining and minerals, power, industrial, refining, aggregates, precious and base metals industries.
The purchase price was $280 million plus estimated working capital of $17 million which included cash acquired of $8 million.
The total net cash paid at closing of $289 million is subject to an escrowed holdback. As of December 31, 2012, the remaining
escrowed holdback was $25 million and primarily related to security for indemnification obligations. R&S and its acquired
divisions have been integrated into the Minerals reporting unit. As a result of our interim goodwill impairment test, we recorded a
noncash goodwill impairment charge in our Minerals reporting unit, which is part of our IGP segment, of $178 million in the third
quarter of 2012. See Note 3 and Note 6 to our consolidated financial statements for further discussion of the R&S acquisition and
the goodwill impairment charge. On December 6, 2012, ENI Holdings, LLC filed a lawsuit in Delaware Chancery Court alleging
KBR is wrongfully withholding the escrowed holdback. On January 25, 2013, we filed an answer denying the wrongful
withholding allegation. In addition we filed a counterclaim for indemnity and fraud under the terms of the Stock Purchase
Agreement.

Acquisition of remaining interest in M.W. Kellogg Limited.

On December 31, 2010, we obtained control of the remaining 44.94% interest of our MWKL subsidiary located in the U.K.
for £107 million subject to certain post-closing adjustments. The acquisition was recorded as an equity transaction that reduced
noncontrolling interests, accumulated other comprehensive income (“AOCI”) and additional paid-in capital by $180 million. We
recognized direct transaction costs associated with the acquisition of $1 million as a direct charge to additional paid in capital. The
initial purchase price of $164 million was paid on January 5, 2011. During the third quarter of 2011, we settled various post-closing
adjustments that resulted in a decrease to “Paid-in capital in excess of par” of approximately $5 million. We also agreed to pay the
former noncontrolling interest 44.94% of future proceeds collected on certain receivables owed to MWKL. Additionally, the
former noncontrolling interest agreed to indemnify us for 44.94% of certain MWKL liabilities to be settled and paid in the future.
As of December 31, 2012, we have liabilities of $14 million classified on our balance sheet as “Other current liabilities” reflecting
our accrual of 44.94% of proceeds from certain receivables owed to the former noncontrolling interest partner in MWKL. See Note
3 and Note 10 for additional details of obligations due to the former noncontrolling interest partner in MWKL.

Sale of Interest in LNG Joint Venture

On January 5, 2011, we sold our 50% interest in a joint venture to our joint venture partner for $22 million. The joint
venture was formed to execute an EPC contract for construction of an LNG plant in Indonesia. We recognized a gain on the sale of
our interest of $8 million which is included in “Equity in earnings of unconsolidated affiliates, net” in our consolidated income
statement.

Critical Accounting Policies

The preparation of financial statements in conformity with accounting principles generally accepted in the United States
requires management to select appropriate accounting policies and to make estimates and judgments that affect the reported
amounts of assets, liabilities, revenue and expenses. Our critical accounting policies are described below to provide a better
understanding of how we develop our assumptions and judgments about future events and related estimates and how they can
impact our financial statements. A significant accounting estimate is one that requires our most difficult, subjective or complex
estimates and assessments and is fundamental to our results of operations.

We base our estimates on historical experience and on various other assumptions we believe to be reasonable according to
the current facts and circumstances, the results of which form the basis for making judgments about the carrying values of assets
and liabilities that are not readily apparent from other sources. We believe the following are the critical accounting policies used in
the preparation of our consolidated financial statements in accordance with accounting principles generally accepted in the United
States, as well as the significant estimates and judgments affecting the application of these policies. This discussion and analysis
should be read in conjunction with our consolidated financial statements and related notes.

Engineering and Construction Contracts. Revenue from long-term contracts to provide construction, engineering, design or
similar services is recognized as contract performance progresses using the percentage-of-completion method. We estimate the
progress towards completion to determine the amount of revenue and profit to be recognized in each reporting period, based upon
estimates of the total cost to complete the project; estimates of the project schedule and completion date; estimates of the extent of
progress toward completion; and amounts of any probable claims and change orders included in revenue. Progress is generally
based upon a cost-to-cost approach but we also use alternative methods including physical progress, labor hours or others
depending on the type of job.

At the outset of each contract, we prepare a detailed analysis of our estimated cost to complete the project. Risks relating to
service delivery, usage, productivity and other factors are considered in the estimation process. Our project personnel periodically
evaluate the estimated costs, claims, change orders and percentage of completion at the project level. The recording of profits and
losses on long-term contracts requires an estimate of the total profit or loss over the life of each contract. This estimate requires
consideration of total contract value, change orders and claims, less costs incurred and estimated costs to complete. We also take
into account liquidated damages when determining total contract profit or loss. Our contracts often require us to pay liquidated
damages should we not meet certain performance requirements, including completion of the project in accordance with a scheduled
timeline. We generally include an estimate of liquidated damages in contract costs when it is deemed probable that they will be
paid. Profits are recorded based upon the product of estimated contract profit at completion times the current percentage-complete
for the contract.

When calculating the amount of total profit or loss on a long-term contract, we include claims in contract value only when it
is probable that the claim will result in additional revenue and the amount can be reliably estimated. Including claims in this
calculation increases the operating income (or reduces the operating loss) that would otherwise be recorded without consideration of
the claims. Claims are recorded to the extent of costs incurred and include no profit element. We are actively engaged in claims
negotiations with our customers, and the success of claims negotiations has a direct impact on the profit or loss recorded for any
related long-term contract. Unsuccessful claims negotiations could result in decreases in estimated contract profits or additional
contract losses, and successful claims negotiations could result in increases in estimated contract profits or recovery of previously
recorded contract losses.

At least quarterly, significant projects are reviewed in detail by senior management. We have a long history of working
with multiple types of projects and in preparing cost estimates. However, there are many factors that impact future costs, including
but not limited to weather, inflation, labor and community disruptions, timely availability of materials, productivity and other
factors as outlined in our “Risk Factors” contained in Part I of this Annual Report on Form 10-K. These factors can affect the
accuracy of our estimates and materially impact our future reported earnings.

For contracts containing multiple deliverables we analyze each activity within the contract to ensure that we adhere to the

separation guidelines of ASC 605 - Revenue Recognition and ASC 605-25 - Multiple-Element Arrangements.

Our revenue includes revenue from services provided to our unconsolidated affiliates or joint ventures, the equity in the

earnings of unconsolidated affiliates or joint ventures and gains and losses on disposal of our interest in joint ventures.

Estimated Losses on Uncompleted Contracts and Changes in Contract Estimates. We record provisions for estimated losses
on uncompleted contracts in the period in which such losses are identified. The cumulative effects of revisions to contract revenue
and estimated completion costs are recorded in the accounting period in which the amounts become evident and can be reasonably
estimated. These revisions can include such items as the effects of change orders and claims, warranty claims, liquidated damages
or other contractual penalties, adjustments for audit findings on U.S. government contracts and contract closeout settlements.

Accounting for government contracts. Most of the services provided to the United States government are governed by cost-
reimbursable contracts. Generally, these contracts may contain base fees (a fixed profit percentage applied to our actual costs to
complete the work), fixed fees and award fees (a variable profit percentage applied to definitized costs, which is subject to our
customer’s discretion and tied to the specific performance measures defined in the contract, such as adherence to schedule, health
and safety, quality of work, responsiveness, cost performance and business management).

Revenue is recorded at the time services are performed, and such revenue includes base fees, actual direct project costs
incurred and an allocation of indirect costs. Indirect costs are applied using rates approved by our government customers. The
general, administrative and overhead cost reimbursement rates are estimated periodically in accordance with government contract
accounting regulations and may change based on actual costs incurred or based upon the volume of work performed. Revenue is
reduced for our estimate of costs that either are in dispute with our customer or have been identified as potentially unallowable
pursuant to the terms of the contract or the federal acquisition regulations.

For contracts containing multiple deliverables we analyze each activity within the contract to ensure that we adhere to the

separation guidelines of ASC 605 - Revenue Recognition and ASC 605-25 - Multiple-Element Arrangements.

Similar to many cost-reimbursable contracts, these government contracts are typically subject to audit and adjustment by our
customer. Each contract is unique; therefore, the level of confidence in our estimates for audit adjustments varies depending on
how much historical data we have with a particular contract. KBR excludes from billings to the U.S. government costs that are
expressly unallowable, or mutually agreed to be unallowable, or not allocable to government contracts based on the applicable
regulations. Revenue recorded for government contract work is reduced for our estimate of potentially unallowable costs related to
issues that may be categorized as disputed or unallowable as a result of cost overruns or the audit process. Our estimates of
potentially unallowable costs are based upon, among other things, our internal analysis of the facts and circumstances, terms of the
contracts and the applicable provisions of the FAR, quality of supporting documentation for costs incurred and subcontract terms,
as applicable. From time to time, we engage outside counsel to advise us in determining whether certain costs are allowable. We
also review our analysis and findings with the administrative contracting officer (“ACO”) as appropriate. In some cases, we may
not reach agreement with the DCAA or the ACO regarding potentially unallowable costs which may result in our filing of claims in
various courts such as the Armed Services Board of Contract Appeals (“ASBCA”) or the United States Court of Federal Claims
(“COFC”). We only include amounts in revenue related to disputed and potentially unallowable costs when we determine it is
probable that such costs will result in revenue. We generally do not recognize additional revenue for disputed or potentially
unallowable costs for which revenue has been previously reduced until we reach agreement with the DCAA and/or the ACO that
such costs are allowable.

Goodwill Impairment Testing. Goodwill represents the excess of cost over the fair market value of net assets acquired in
business combinations and, in accordance with ASC 350 Intangibles - Goodwill and Other, we are required to test goodwill for
impairment on an annual basis, and more frequently when negative conditions or other triggering events arise. We test goodwill for
impairment annually as of October 1. As of December 31, 2012, we had goodwill totaling $779 million on our consolidated
balance sheet. Our operations are grouped into four segments: Hydrocarbons, IGP, Services and Other. Within those segments we
operate 11 business units which are also our operating segments as defined by ASC 280 - Segment Reporting and reporting units as
defined by ASC 350. In accordance with ASC 350, we conduct our goodwill impairment testing at the reporting unit level which
consists of the 11 business units and our Allstates reporting unit. The reporting units include Gas Monetization, Oil & Gas,
Downstream, Technology, North American Government & Logistics, International Government, Defense and Support Services,
Power & Industrial, Infrastructure, Minerals, Services, Ventures and the Allstates staffing reporting units.

In the third quarter of 2012, during the course of our annual strategic planning process, we determined that both the actual
and expected income and cash flows for our Minerals reporting unit were substantially lower than previous forecasts due to lower
than expected project bookings and losses from ongoing projects acquired as part of the acquisition of R&S. We also identified a
deterioration in economic conditions in the minerals markets and less than expected actual and projected income and cash flows for

the Minerals reporting unit, which reduced forecasts of the sales, operating income and cash flows expected in 2013 and beyond. As
a result of these triggering events, we performed an interim goodwill impairment test on our Minerals reporting unit and recorded a
noncash goodwill impairment charge of $178 million in the third quarter of 2012.

Our October 1, 2012, annual impairment test for goodwill was a quantitative analysis using a two-step process that involves
comparing the estimated fair value of each reporting unit to its carrying value, including goodwill. If the fair value of a reporting
unit exceeds its carrying value, the goodwill of the reporting unit is not considered impaired; therefore, the second step of the
impairment test is unnecessary. If the carrying value of a reporting unit exceeds its fair value, we perform the second step of the
goodwill impairment test to measure the amount of goodwill impairment loss to be recorded, as necessary. The second step
compares the implied fair value of the reporting unit's goodwill to the carrying value of that goodwill. We determine the implied
fair value of the goodwill in the same manner as determining the amount of goodwill to be recognized in a business combination.

Under the market approach, we estimate fair value by applying earnings and revenue market multiples to a reporting unit’s
operating performance for the trailing twelve-month period. The earnings multiples for the market approach ranged from 5.9 times
to 8.1 times the earnings for each of our reporting units. The income approach estimates fair value by discounting each reporting
unit’s estimated future cash flows using a weighted-average cost of capital that reflects current market conditions and the risk
profile of the reporting unit. To arrive at our future cash flows, we use estimates of economic and market assumptions, including
growth rates in revenues, costs, estimates of future expected changes in operating margins, tax rates and cash expenditures. The
risk-adjusted discount rates applied to our future cash flows under the income approach ranged from 14.1% to 20.5%. We believe
these two approaches are appropriate valuation techniques and we generally weight the two resulting values equally as an estimate
of a reporting unit's fair value for the purposes of our impairment testing. However, we may weigh one value more heavily than the
other when conditions merit doing so. Other significant estimates and assumptions include terminal value growth rates, future
estimates of capital expenditures and changes in future working capital requirements. The fair value derived from the weighting of
these two methods provides appropriate valuations that, in the aggregate, reasonably reconcile to our market capitalization, taking
into account observable control premiums.

In addition to the earnings multiples and the discount rates disclosed above, certain other judgments and estimates are used
in our goodwill impairment test. Given our use of judgments and estimates in the performance of our goodwill impairment test, if
market conditions change compared to those used in our market approach, or if actual future results of operations fall below the
projections used in the income approach, our goodwill could become impaired in the future.

At the annual testing date of October 1, 2012, our market capitalization exceeded the carrying value of our consolidated net
assets by $2.6 billion and, except for the Minerals, Services and Downstream reporting units, the fair value of all our reporting units
substantially exceeded their respective carrying amounts as of that date. If future variances for projected growth rates and other
market inputs are significant, the fair values of some business units may not substantially exceed their carrying values in future
periods.

The fair value of the Services reporting unit exceeded its carrying value by approximately 16% and total goodwill
allocated to the reporting unit was $287 million at October 1, 2012. The valuation model for the Services reporting unit assumes
continuing growth in the Canadian module fabrication, turnaround and construction markets as well as additional maintenance
opportunities in the Middle East. The fair value of the Downstream reporting unit exceeded its carrying value by approximately
29% and total goodwill allocated to the reporting unit was $78 million at October 1, 2012. The valuation model for the
Downstream reporting unit assumes an emerging market growth opportunity in the Middle East and North America in EPC projects
involving ammonia, syngas and chemicals. The carrying value of the Minerals reporting unit exceeded its fair value by
approximately 30%, thus failing Step 1. We then performed Step 2 of the goodwill impairment test which compares the implied
fair value of Mineral's goodwill to the carrying value of that goodwill. The implied fair value of Mineral's goodwill exceed its
carrying value by approximately 14%.

Deferred taxes and tax contingencies. Deferred tax assets and liabilities are recognized for the expected future tax
consequences of events that have been recognized in the financial statements or tax returns. A deferred tax asset or liability is
recognized for the estimated future tax effects attributable to temporary differences between the financial reporting basis and the
income tax basis of assets and liabilities. A current tax asset or liability is recognized for the estimated taxes refundable or payable
on tax returns for the current year. The measurement of current and deferred tax assets and liabilities is based on provisions of the
enacted tax law, and the effects of potential future changes in tax laws or rates are not considered.

In assessing the realizability of deferred tax assets, we consider whether it is more likely than not that some portion or all of
the deferred tax assets will not be realized. The ultimate realization of deferred tax assets is dependent upon the generation of
future taxable income during the periods in which those temporary differences become deductible. A valuation allowance is
provided for deferred tax assets if it is more likely than not that these items will not be realized. We consider the scheduled reversal
of deferred tax liabilities, projected future taxable income and available tax planning strategies in making this assessment.
Additionally, we use forecasts of certain tax elements such as taxable income and foreign tax credit utilization and the evaluation of

tax planning strategies in making an assessment of realization. Given the inherent uncertainty involved with the use of such
assumptions, there can be significant variation between anticipated and actual results. As of December 31, 2012, we had net
deferred tax assets of $333 million, which are net of deferred tax liabilities of $264 million and a valuation allowance of $36 million
primarily related to certain foreign branch net operating losses.

We have operations in the United States and in numerous other countries. Consequently, we are subject to the jurisdiction
of a significant number of taxing authorities. The income earned in these various jurisdictions is taxed on differing bases, including
income actually earned, income deemed earned and revenue-based tax withholding. The final determination of our worldwide tax
liabilities involves the interpretation of local tax laws, tax treaties and related authorities in each jurisdiction. Changes in the
operating environment, including changes in tax law and currency/repatriation controls, could impact the determination of our tax
liabilities for a tax year.

Income tax positions must meet a more-likely-than-not recognition threshold to be recognized. Income tax positions that
previously failed to meet the more-likely-than-not threshold are recognized in the first subsequent financial reporting period in
which that threshold is met. Previously recognized tax positions that no longer meet the more-likely-than-not threshold are
derecognized in the first subsequent financial reporting period in which that threshold is no longer met. The company recognizes
potential interest and penalties related to unrecognized tax benefits in income tax expense.

Tax filings of our subsidiaries, unconsolidated affiliates and related entities are routinely examined in the normal course of
business by tax authorities. These examinations may result in assessments of additional taxes, which we work to resolve with the
tax authorities and through the judicial process. Predicting the outcome of disputed assessments involves some uncertainty.
Factors such as the availability of settlement procedures, willingness of tax authorities to negotiate and the operation and
impartiality of judicial systems vary across the different tax jurisdictions and may significantly influence the ultimate outcome. We
review the facts for each assessment, and then utilize assumptions and estimates to determine the most likely outcome and provide
taxes, interest and penalties as needed based on this outcome.

Legal and Investigation Matters. As discussed in Notes 9 and 10 of our consolidated financial statements, as of
December 31, 2012 and 2011, we have accrued an estimate of the probable and estimable costs for the resolution of some of our
legal and investigation matters. For other matters for which the liability is not probable and reasonably estimable, we have not
accrued any amounts. Attorneys in our legal department monitor and manage all claims filed against us and review all pending
investigations. Generally, the estimate of probable costs related to these matters is developed in consultation with internal and
outside legal counsel representing us. Our estimates are based upon an analysis of potential results, assuming a combination of
litigation and settlement strategies. The precision of these estimates and the likelihood of future changes depend on a number of
underlying variables and a range of possible outcomes. We attempt to resolve these matters through settlements, mediation and
arbitration proceedings when possible. If the actual settlement costs, final judgments or fines, differ from our estimates after
appeals, our future financial results may be materially and adversely affected. We record adjustments to our initial estimates of
these types of contingencies in the periods when the change in estimate is identified.

Pensions. Our pension benefit obligations and expenses are calculated using actuarial models and methods, in accordance
with ASC 715 - Compensation - Retirement Benefits. Two of the more critical assumptions and estimates used in the actuarial
calculations are the discount rate for determining the current value of benefit obligations and the expected rate of return on plan
assets. Other assumptions and estimates used in determining benefit obligations and plan expenses, including demographic factors
such as retirement age, mortality and turnover, are evaluated periodically and updated accordingly to reflect our actual experience.

The discount rate used to determine the benefit obligations was determined using a cash flow matching approach, which
uses projected cash flows matched to spot rates along a high quality corporate yield curve to determine the present value of cash
flows to calculate a single equivalent discount rate. The expected long-term rate of return on assets was determined by a stochastic
projection that takes into account asset allocation strategies, historical long-term performance of individual asset classes, an analysis
of additional return (net of fees) generated by active management, risks using standard deviations and correlations of returns among
the asset classes that comprise the plans' asset mix. Plan assets are comprised primarily of equity securities, fixed income funds and
securities, hedge funds, real estate and other funds. As we have both domestic and international plans, these assumptions differ
based on varying factors specific to each particular country or economic environment. During 2012, plan fiduciaries of our
international plan implemented a revised investment strategy that reduces risk associated with fulfilling our pension obligations by
further diversifying assets from equities to other asset classes along with the consideration of other risk reduction strategies that
include liability hedging. This revised investment strategy is expected to be completed in the first quarter of 2013.

The discount rate utilized to calculate the projected benefit obligation at the measurement date for our U.S. pension plan
decreased to 3.09% at December 31, 2012 from 3.74% at December 31, 2011. The discount rate utilized to determine the projected
benefit obligation at the measurement date for our U.K. pension plans, which constitutes all of our international plans and 95% of
all plans, decreased to 4.50% at December 31, 2012 from 4.90% at December 31, 2011. An additional future decrease in the
discount rate of 25 basis points for our pension plans would increase our projected benefit obligation by an estimated $89 million
and $2 million for the U.K. and U.S. plans, respectively, while a similar increase in the discount rate would reduce our projected
benefit obligation by an estimated $83 million and $2 million for the U.K. and U.S. plans, respectively. Our expected long-term
rates of return on plan assets utilized at the measurement date remained unchanged at 7.00% for our U.S. pension plans and
decreased to 6.15% from 6.60% for our U.K. pension plans.

Unrecognized actuarial gains and losses are generally recognized over a period of 10 to 15 years, which represents a
reasonable systematic method for amortizing gains and losses for the employee group. Our unrecognized actuarial gains and losses
arise from several factors, including experience and assumption changes in the obligations and the difference between expected
returns and actual returns on plan assets. The difference between actual and expected returns is deferred as an unrecognized
actuarial gain or loss and is recognized as future pension expense. Our pretax unrecognized actuarial loss in accumulated other
comprehensive income at December 31, 2012 was $723 million, of which $36 million is expected to be recognized as a component
of our expected 2013 pension expense compared to $27 million in 2012. During 2012, we made contributions to fund our defined
benefit plans of $30 million. We currently expect to make contributions in 2013 of approximately $25 million.

The actuarial assumptions used in determining our pension benefits may differ materially from actual results due to
changing market and economic conditions, higher or lower withdrawal rates and longer or shorter life spans of participants. While
we believe that the assumptions used are appropriate, differences in actual experience or changes in assumptions may materially
affect our financial position or results of operations. Our actuarial estimates of pension benefit expense and expected pension
returns of plan assets are discussed in Note 17 in the accompanying financial statements.

Variable Interest Entities. We account for variable interest entities (“VIEs”) in accordance with ASC 810 - Consolidation
which requires the consolidation of VIEs in which a company has both the power to direct the activities of the VIE that most
significantly impact the VIE’s economic performance and the obligation to absorb losses or the right to receive the benefits from
the VIE that could potentially be significant to the VIE. If a reporting enterprise meets these conditions then it has a controlling
financial interest and is the primary beneficiary of the VIE. An unconsolidated VIE is accounted for under the equity method of
accounting.

We assess all newly created entities and those with which we become involved to determine whether such entities are VIEs
and, if so, whether or not we are their primary beneficiary. Most of the entities we assess are incorporated or unincorporated joint
ventures formed by us and our partner(s) for the purpose of executing a project or program for a customer, such as a governmental
agency or a commercial enterprise, and are generally dissolved upon completion of the project or program. Many of our long-term
energy-related construction projects in our Hydrocarbons business segment are executed through such joint ventures. Typically,
these joint ventures are funded by advances from the project owner, and accordingly, require little or no equity investment by the
joint venture partners but may require subordinated financial support from the joint venture partners such as letters of credit,
performance and financial guarantees or obligations to fund losses incurred by the joint venture. Other joint ventures, such as
privately financed initiatives in our Ventures business unit, generally require the partners to invest equity and take an ownership
position in an entity that manages and operates an asset post construction.

As required by ASC 810, we perform a qualitative assessment to determine whether we are the primary beneficiary once an
entity is identified as a VIE. Thereafter, we continue to re-evaluate whether we are the primary beneficiary of the VIE in
accordance with ASC 810-10. A qualitative assessment begins with an understanding of the nature of the risks in the entity as well
as the nature of the entity’s activities including terms of the contracts entered into by the entity, ownership interests issued by the
entity and how they were marketed and the parties involved in the design of the entity. We then identify all of the variable interests
held by parties involved with the VIE including, among other things, equity investments, subordinated debt financing, letters of
credit, financial and performance guarantees and contracted service providers. Once we identify the variable interests, we
determine those activities which are most significant to the economic performance of the entity and which variable interest holder
has the power to direct those activities. Though infrequent, some of our assessments reveal no primary beneficiary because the
power to direct the most significant activities that impact the economic performance is held equally by two or more variable interest
holders who are required to provide their consent prior to the execution of their decisions. Most of the VIEs with which we are
involved have relatively few variable interests and are primarily related to our equity investment, significant service contracts and
other subordinated financial support.

Results of Operations

We analyze the financial results for each of our four business groups including the related business units within
Hydrocarbons and IGP. The business groups presented are consistent with our reportable segments discussed in Note 5 to our
consolidated financial statements. While certain business units and product service lines presented below do not meet the criteria
for reportable segments in accordance with ASC 280 - Segment Reporting, we believe this supplemental information is relevant and
meaningful to our investors. In the first quarter of 2012, we began reporting Infrastructure and Minerals as separate business units.
Prior periods have been conformed to the current presentation.

For purposes of reviewing the results of operations, “business group income” is calculated as revenue less cost of services
managed and reported by the business group and are directly attributable to the business group. Business group income excludes
unallocated corporate, general and administrative expenses and other non-operating income and expense items.

Revenue by Business Group

Years Ended December 31,

Millions of dollars

Revenue: (1)

Hydrocarbons:

2012

2011

2010

2012 vs. 2011

2011 vs. 2010

Gas Monetization

3,040

3,044

Oil & Gas

Downstream

Technology

483

575

202

488

557

169

Total Hydrocarbons

4,300

4,258

(4)

(5)

—

2,829

(1)%

20%

426

584

130

3,969

215

(27)

289

15%

(5)%

30%

Infrastructure, Government and Power
(“IGP”):

North American Government and
Logistics

International Government,
Defence and Support Services

Infrastructure

Minerals

Power and Industrial

Total IGP

Services

Ventures

Other

725

360

255

192

372

1,904

1,633

2,198

(1,473)

(67)%

3,307

(1,109)

(34)%

378

246

264

242

3,328

1,590

(18)

(72)

130

(1,424)

(4)

(5)%

(27)%

54%

(43)%

(6)%

15%

369

236

352

4,299

1,755

229

(110)

(971)

(165)

(1)

654%

(31)%

(23)%

(9)%

18%

(5)%

(8)%

Total revenue

7,921

9,261

(1,340)

(14)% $

10,099

(838)

(1) We often participate in larger projects as a joint venture partner and provide services to the joint venture as a subcontractor.
The amount included in our revenue represents our share of the earnings (loss) from joint ventures and revenue from
services provided to joint ventures.

Income (loss) by Business Group

Years Ending December 31,

2012 vs. 2011

2011 vs. 2010

2012

2011

2010

Millions of dollars

Business group income (loss):

Hydrocarbons:

Gas Monetization

Oil & Gas

Downstream

Technology

Total job income

Impairment of long-lived assets

Gain (loss) on sale of assets

Divisional overhead

Total Hydrocarbons

Infrastructure, Government and Power (“IGP”):

North American Government and Logistics

International Government, Defence and Support
Services

Infrastructure

Minerals

Power and Industrial

Total job income

Impairment of goodwill

Loss on sale of assets

Divisional overhead

Total IGP

Services:

Job income

Gain (loss) on sale of assets

Divisional overhead

Total Services

Ventures:

Job income (loss)

Gain on sale of assets

Divisional overhead

Total Ventures

Other:

Job income

Impairment of long-lived assets

Gain (loss) on sale of assets

Divisional overhead

Total Other

445

115

729

—

(128)

601

113

(56)

217

(178)

(1)

(142)

(104)

—

(58)

(16)

—

(3)

(2)

(8)

257

104

513

—

(106)

408

212

128

(2)

429

—

(1)

(162)

266

124

(67)

(4)

—

(8)

188

73%

11%

(3)%

25%

42%

252
90
117
55
514

—

(4)

(100)%

(21)%

47%

—
(110)

400

(145)

(68)%

(2)

216

—

(1)

(22)

193

(15)

(3)

(54)

(212)

(178)

—

(5)

(1)

(5)

(1)

(2)

—

12%

(145)

(370)

(139)%

272

(82)

(1)

(66)%

(100)%

13%

(74)

(128)%

(12)%

(5)%

n/m

17%

(49)%

—

(11)%

(100)%

25%

(12)%

(6)%

—

n/m

—

322%

(29)%

230

417

—

172

(1)

(69)

102

(3)

(1)

(2)

(7)

809

(40)

(1)

16%

(34)%

36%

—

100%

—

(18)

(8)%

(8)

—

(1)

(17)

(6)

(48)

45%

11%

(133)%

(22)%

—

(12)%

(2)%

(28)%

200%

(44)

(43)%

(2)

(1)

(26)

36%

(67)%

(33)%

27%

33%

100%

150%

(14)%

350%

(3)%

50%

Total business group income

556

783

(227)

Unallocated amounts:

Labor cost absorption income (expense)

(35)

(53)

(294)%

Income (loss) by Business Group

Years Ending December 31,

Millions of dollars

Business group income (loss):

2012 vs. 2011

2011 vs. 2010

2012

2011

2010

Corporate general and administrative expense

(222)

(214)

(8)

(4)%

(212)

Total operating income

299

587

(288)

(49)% $

609

(2)

(22)

(1)%

(4)%

n/m - not meaningful

Hydrocarbons

Gas Monetization. Gas Monetization revenue decreased by $4 million in 2012 compared to 2011, primarily driven by lower
volume of work associated with project completions or near completions on the Escravos, Skikda and Pearl GTL projects, as well
as the FEED phase of the Ichthys LNG project. The decrease in 2012 revenues is offset by increased activity and milestone
incentive awards on the Gorgon project and the start of the EPC phase of the Ichthys LNG project.

Gas Monetization job income increased by $188 million in 2012 compared to 2011. Job income increased $230 million as a
result of increased activity from the Gorgon, Skikda and Ichthys LNG projects. Included in the increased activity are change orders
which revised estimated cost to complete for Skikda, as well as milestone awards for Gorgon. Partially offsetting these increases in
job income were decreases of $47 million primarily due to lower activity and project completions on Escravos, Pearl and other
projects.

Gas Monetization revenue increased by $215 million in 2011 compared to 2010, primarily due to higher progress on
Gorgon and Escravos which increased revenue by $232 million in the aggregate. Revenue further increased by $121 million as a
result of higher activity on a FEED project awarded in late 2010 and activity on other projects. Partially offsetting the increases
were declines in revenue of $142 million in the aggregate due to lower activity on Skikda and Pearl as well as the completion of
other LNG and GTL projects in 2010.

Gas Monetization job income increased by $5 million in 2011 compared to 2010. Job income increased by $41 million as a
result of increased activity on the EPCm portion of Gorgon, the sale of our interest in an unconsolidated joint venture, the reversal
of previously accrued commercial agent fees on a completed LNG project and activity on other projects. These increases were
partially offset by a decrease of $32 million primarily due to income in 2010 related to change orders associated with the
completion of an LNG project that did not recur in 2011 and lower subcontractor activity on Skikda.

Oil & Gas. Oil & Gas revenue decreased by $5 million and job income increased by $11 million in 2012 compared to 2011.
The decrease in revenue is primarily due to the completion or near-completion of several long term projects in late 2011 and during
2012. These project completions were offset by other long term technical service projects and increased progress on existing
projects primarily located in the North Sea and Azerbaijan, as well as the recognition of $8 million in license fee revenue for several
semi-submersible hulls. The increase in job income is primarily due to increased progress for projects in the North Sea and
Azerbaijan, as well as the recognition of the license fees, partially offset by the completion or near completion of other projects.

Oil & Gas revenue and job income increased by $62 million and $14 million, respectively, in 2011 compared to 2010. New
technical service projects and additional phases of existing projects primarily in the North Sea, Caspian Sea and Gulf of Mexico
contributed $127 million to the increase in 2011 revenue, partially offset by a decrease of $75 million due to lower volume and
progress on projects that were either completed or nearing completion during 2011. Job income increased mainly as a result of new
project awards, increased activity on existing projects and close-out activity on completed projects.

Downstream. Downstream revenue increased by $18 million and job income decreased by $2 million in 2012 compared to
2011. The increase in revenue in 2012 is primarily driven by additional revenue of $20 million related to the $39 million FAO
claim settlement, of which $19 million was previously recorded. The decrease in job income is driven primarily by the completion
of engineering on a refinery project in Africa in early 2012 and lower volumes on projects in the Middle East. These decreases are
partially offset by our portion of the FAO settlement of $14 million, as well as activity from newly awarded projects in North
America and Saudi Arabia.

Downstream revenue and job income decreased by $27 million and $40 million, respectively, in 2011 compared to 2010.
Revenue decreased by $186 million primarily due to several projects that were either completed or nearing completion. This
decrease was partially offset by additional revenue of $122 million from newly awarded projects started in late 2010 or during 2011
as well as increased activity on existing projects including the Yanbu and DuPont projects. Job income decreased primarily due to
the completion or near completion of projects in Africa and the Middle East, partly offset by additional activity from new projects.

Technology. Technology revenue and job income increased by $33 million and $19 million, respectively, in 2012 compared
to 2011. This increase is primarily due to the progress achieved on license and engineering projects in Egypt, the U.S., Uzbekistan,
Russia, India, Bolivia and China which collectively contributed $55 million to revenues and $36 million to job income. The

increase in revenue and job income also includes $8 million associated with the completion of ammonia license and basic
engineering contracts in Venezuela. Partially offsetting these increases were decreases in revenue and job income associated with
the completion of engineering services on an ammonia project located in Brazil and on other projects.

Technology revenue and job income increased by $39 million and $20 million, respectively, in 2011 compared to 2010,
primarily due to the progress achieved on a new grassroots ammonia, urea and granulation project in Brazil and other petrochemical
and ammonia projects located in China, India, Indonesia and Korea. These new projects contributed $73 million to the increases in
revenue and $36 million to the increases in job income. Partially offsetting these increases were decreases in revenue and job
income associated with the completion of engineering services on several projects located in Turkmenistan, India, China, Korea and
Angola.

Infrastructure, Government and Power (“IGP”)

North American Government and Logistics (“NAGL”). NAGL revenue decreased by $1.5 billion in 2012 compared to
2011, due to the December 2011 completion of operations in Iraq under the LogCAP III contract. Our services in the region have
shifted to the LogCAP IV contract supporting the U.S. Department of State in Iraq.

NAGL job income decreased by $145 million in 2012 compared to 2011, primarily due to the completion of services under
the LogCAP III contract. The decrease includes the unfavorable ruling from the U.S. COFC regarding costs associated with dining
facility services. This resulted in a noncash, pre-tax charge of $28 million. Partially offsetting the decrease was higher income
related to the LogCAP IV contract.

NAGL revenue decreased by $1.1 billion in 2011 compared to 2010 primarily due to an overall reduction in the volume of
U.S. military support activities due to troop drawdown and related base closures in Iraq and completion of work in Afghanistan
under our LogCAP III contract. Revenue from the LogCAP III contract declined $1.3 billion in 2011. Revenue decreases were
partially offset by an increase of $188 million associated with our LogCAP IV task order that began in mid-2010.

NAGL job income decreased by $18 million in 2011 compared to 2010. Lower volume of activity on our LogCAP III
contract resulted in a reduction to income of $46 million. Additionally, recognized LogCAP III award fees declined by $54 million
in 2011 compared to 2010. These declines in job income were partially offset by increases of $69 million related to fixed-fees and
lower adjustments recognized for potentially unallowable costs on the LogCAP III contract and higher income related to the
LogCAP IV contract.

International Government, Defence and Support Services (“IGDSS”). IGDSS revenue decreased by $18 million and job
income decreased by $15 million in 2012 compared to 2011, driven by lower activity on the Aspire Defence project and reduced
margins on a U.K. MoD contract in Afghanistan. These decreases were partially offset by increased activity related to support
services in Africa and a NATO contract in Afghanistan.

IGDSS revenue increased by $9 million in 2011 compared to 2010 primarily due to commencement of service under new
NATO contracts in Afghanistan, reduced cost estimates for the remaining period of performance for construction activities on
Aspire Defence and various other new project awards. These increases in revenue were partially offset by lower activity on the
Temporary Deployable Accommodation project as well as absence of new task orders.

IGDSS job income increased by $40 million in 2011 compared to 2010 primarily due to reduced cost estimates on Aspire
Defence that produced $33 million of additional job income during 2011, increased activity on NATO contracts in Afghanistan and
operations-related efficiencies in other contingency logistics and construction management projects.

Infrastructure. Infrastructure revenue increased by $9 million and job income decreased by $3 million in 2012 compared to
2011. The increase in revenue is due to increased activity in the Middle East associated with the expansion of the Doha
Expressway program. The decrease in job income is a result of a decline in market conditions in the APAC market.

Infrastructure revenue and job income increased by $10 million and $6 million in 2011 compared to 2010. The increase in
revenue is due a transport project in Qatar which commenced in late 2010. This increase was partially offset by revenue reductions
due to the completion of water projects in the U.K. and Australia as well lower activity on various infrastructure projects due to
deferred government spending resulting from flooding in Queensland, Australia. The increase in job income is primarily as a result
of increased progress on a transport project in Qatar as well as $10 million in project incentives earned on a transport project in
Australia. These increases were partially offset by lower overall activity on various other infrastructure projects in the U.K. and
Australia.

Minerals. Minerals revenue decreased by $72 million in 2012 compared to 2011, due to a decline in project awards, a
general decline in economic conditions, as well as lower volume of work and progress on existing projects. This includes a $56
million reduction in revenue related to two projects in Indonesia.

Minerals job income decreased by $54 million in 2012 compared to 2011. The decrease is primarily due to various projects
encountering increased operating costs, funding of liquidated damages and other project items. Job income related to the two
Indonesian projects declined $38 million as a result of additional project costs and liquidated damages related to two projects in

Indonesia associated with issues encountered during the commissioning, pre-commissioning and earthworks phase of the these
projects. Job income is down a further $16 million due to increased costs, liquidated damages and technical delays primarily for
legacy R&S projects.

In the third quarter of 2012, during the course of our annual strategic planning process, we identified deterioration in
economic conditions in the minerals markets and less than expected actual and projected income and cash flows due to lower than
expected project bookings and losses from ongoing projects acquired as part of the R&S acquisition. As a result of our interim
goodwill impairment test, we recorded a noncash goodwill impairment charge of $178 million in the third quarter of 2012.

Minerals revenue increased by $229 million and job income decreased by $8 million in 2011 compared to 2010. The
increase in revenue is primarily due to the inclusion of legacy R&S projects acquired in December 2010 as well as increased
activity on a minerals project in Australia, which commenced late in 2010. The decrease in job income is primarily due to project
loss provisions totaling $25 million recognized on three projects acquired from R&S due to increased cost estimates at completion.
These losses were partially offset by job income due to increased activity in 2011 on a minerals project in Australia.

Power and Industrial (“P&I”). P&I revenue and job income increased by $130 million and $5 million, respectively, in
2012 compared to 2011. These increases are due to new projects awarded in 2012 and increased progress on existing projects
awarded during late 2011. New projects include air emissions controls systems in Illinois and Kentucky, with existing project
growth from a coal gasification project in Mississippi and a waste-to-energy expansion project in Florida. This increase was
partially offset by reduced activity from projects completed or nearing completion during 2012.

P&I revenue and job income decreased by $110 million and $8 million, respectively, in 2011 as compared to 2010 due to
the completion of procurement, construction and fieldwork activities on various projects, including a waste-to-energy refurbishment
and other projects during 2011. These decreases were partially offset by increased progress on existing engineering projects and the
award of several new projects in 2011. New projects include a coal gasification project in Mississippi and a waste-to-energy
expansion project in Florida.

Services

Services revenue increased by $43 million in 2012 as compared to 2011. This increase is primarily driven by increases of
$167 million in our Canada product line and $121 million in our U.S. Construction product line due to several new awards and
increased activity on new projects. The increased activity in our Canada product line is primarily related to construction services
for gas plants in Northern British Columbia and fabrication modules for oil sands projects. The increase in our U.S. construction
product line is primarily associated with the construction of a base oil facility, turnaround upgrades and rebuilds. These increases
were partially offset by lower revenue of $194 million from our Building Group product line due to the completion of several large
hospital and other projects. Revenue also declined $51 million in our Industrial Services and other product lines due to the
completion of a major turnaround project in 2011.

Services job income decreased by $82 million in 2012 as compared to 2011 due to increased estimated costs to complete on
several U.S. construction fixed-price projects and the decline in our U.S. Construction business. The increase in costs are primarily
related to lower productivity and higher wage rates, which gave rise to higher direct labor costs, indirect costs and other extension-
of-time-related cost. This decline in the U.S. Construction business was partially offset by increased income from our Canadian
product line related to construction services for gas plants in Northern British Columbia and fabrication modules for oil sands
projects in Canada.

Services revenue decreased by $165 million in 2011 compared to 2010. Revenue declined by $303 million in our U.S.
Construction Group and $93 million in our Canada operations primarily as a result of completion or near completion of several
large projects. These declines were partially offset by increases in revenue of $208 million in our Building Services group due to
higher activity on several hospital projects and $35 million in our Industrial Services group from increased construction,
maintenance and services under a new multi-site contract throughout the Eastern and Gulf Coast regions of the U.S.

Services job income decreased by $48 million in 2011 compared to 2010 primarily due to the decline in U.S. Construction
Group and Canada activity resulting from completion or near completion of several projects which was partially offset by the
increased Building Group project activity on the hospital projects.

Ventures

Ventures operations consist of investments in joint ventures accounted for under the equity method of accounting, net of tax.
Ventures revenue and job income decreased by $4 million and $5 million, respectively, in 2012 as compared to 2011, due to a
decline of $10 million on the EBIC ammonia plant in Egypt related to noncash hedge accounting adjustments, write-off of deferred
losses related to the refinancing of EBIC debt, reduced productivity as a result of low gas feedstock pressure and plant closure for
turnaround maintenance. This decline was partially offset by higher revenue and job income of $6 million achieved by other
Ventures projects, primarily due to lower debt interest costs and lower maintenance costs.

Ventures revenue and job income increased by $10 million and $12 million, respectively, in 2011 as compared to 2010, due

to increased sales volume and higher ammonia prices related to the EBIC ammonia plant in Egypt.

Services Revenue by Market Sector

The Services business group provides construction management, direct hire construction and maintenance services to clients
in a number of markets. We believe customer focus, attention to highly productive delivery and a diverse market presence are the
keys to our success in delivering construction and maintenance services. Accordingly, the Services business group focuses on these
key success factors. The analysis below is supplementally provided to present the revenue generated by Services based on the
markets served, some of which are the same sectors served by our other business groups.

Total KBR Revenue

7,921

(in millions)

Hydrocarbons:

Gas Monetization

Oil & Gas

Downstream

Technology

Total Hydrocarbons

Infrastructure, Government and Power (“IGP”):

North American Government and Logistics

International Government, Defence and Support Services

Infrastructure

Minerals

Power and Industrial

Total IGP

Services

Other

(in millions)
Hydrocarbons:

Gas Monetization

Oil & Gas

Downstream

Technology

Total Hydrocarbons

Infrastructure, Government and Power (“IGP”):

North American Government and Logistics

International Government, Defence and Support Services

Infrastructure

Minerals

Power and Industrial

Total IGP

Services

Other

Year Ending December 31, 2012

Business
Group
Revenue

Services
Revenue

Total
Revenue by
Market
Sectors

3,040

483

575

202

4,300

725

360

255

192

372

1,904

1,633

— $
331
413
—
744

—

829

889

(1,633)

—

— $

3,040

814

988

202

5,044

785

360

255

192

1,201

2,793

—

7,921

Year Ending December 31, 2011

Business
Group
Revenue

Services
Revenue

Total
Revenue by
Market
Sectors

3,044

488

557

169

4,258

2,198

378

246

264

242

3,328

1,590

— $
165
377
—
542

80
—
—
—
968
1,048
(1,590)
—
— $

3,044

653

934

169

4,800

2,278

378

246

264

1,210

4,376

—

9,261

Total KBR Revenue

9,261

(in millions)
Hydrocarbons:

Gas Monetization

Oil & Gas

Downstream

Technology

Total Hydrocarbons

Infrastructure, Government and Power (“IGP”):

North American Government and Logistics

International Government, Defence and Support Services

Infrastructure

Minerals

Power and Industrial

Total IGP

Services

Other

Year Ending December 31, 2010

Business
Group
Revenue

Services
Revenue

Total
Revenue by
Market
Sectors

2,829

426

584

130

3,969

3,307

369

236

352

4,299

1,755

—
297
534
—
831

97
—
—
—
827
924
(1,755 )
—
—

2,829

723

1,118

130

4,800

3,404

369

236

1,179

5,223

—

10,099

Total KBR Revenue

10,099

Corporate, tax and other matters

Labor cost absorption income (expense) represents costs incurred by our central labor and resource groups net of the
amounts charged to the operating business units. Labor cost absorption expense was $(35) million in 2012 compared to income of
$18 million in 2011 and $12 million in 2010. The 2012 labor cost absorption expense difference of $(53) million compared to 2011
was primarily due to lower chargeable hours and utilization in several of our engineering offices as a result of delays in awards of
certain expected projects. Labor cost absorption income difference of $6 million compared to 2010 was primarily due to higher
chargeable hours and utilization in several of our engineering offices.

General and administrative expense was $222 million in 2012, $214 million in 2011 and $212 million in 2010. The increase
in 2012 was primarily due to enterprise resource planning ("ERP") project expenses, higher pension costs driven by unfavorable
changes in assumptions that impacted 2012 expense and other risk and benefit programs. The increases were partially offset by
lower information technology support costs, lower legal costs and reductions associated with other cost containment measures. The
increase in 2011 was due to higher information technology support costs, ERP project expenses and employee salary and benefits
related expenses. The increases were partially offset by lower incentive compensation in 2011 as well as a reduction in expenses
associated with legal restructuring of a foreign subsidiary completed in 2010.

Net interest expense was $7 million, $18 million and $17 million in 2012, 2011 and 2010, respectively. The 2012 reduction
in expense is primarily associated with favorable terms of our new Credit Agreement. Interest income was substantially the same in
all periods.

We had foreign currency losses of $2 million in 2012, gains of $3 million in 2011 and losses of $4 million in 2010. Foreign
currency losses in 2012 were primarily due to the fluctuating Euro and currencies with limited hedge market such as the Algerian
Dinar. Foreign currency gains in 2011 were primarily due to the weakening U.S. Dollar against most major currencies. Foreign
currency losses in 2010 were primarily due to the weakening Euro and from currencies with no hedge market such as the Algerian
Dinar. Some of these positions were not fully hedged.

The effective tax rate on pretax earnings was 29.9%, 5.6% and 32.6% for the years ended December 31, 2012, 2011 and
2010, respectively. Our U.S. statutory tax rate for all years was 35%. In the third quarter of 2012, we recorded a noncash goodwill
impairment charge of $178 million in our Minerals reporting unit, which is not deductible for U.S. taxes. Excluding the
nondeductible goodwill impairment charge and discrete items, our adjusted effective tax rate was 29.1% for year ended
December 31, 2012. The adjusted effective tax rate includes increases of 3.9% as a result of incremental income taxes on certain
undistributed foreign earnings in Australia that were previously deemed to be permanently reinvested. Our adjusted effective tax
rate excluding discrete items for 2012 was lower than our statutory rate of 35% primarily due to favorable tax rate differentials on
foreign earnings and lower tax expense on foreign income from unincorporated joint ventures. In 2012, we also recognized discrete
net tax benefits of approximately $50 million including benefits primarily related to the recognition of previously unrecognized tax
benefits related to tax positions taken in prior years due to progress in resolving transfer pricing matters with certain taxing

jurisdictions, statute expirations on certain domestic tax matters and other reductions to foreign tax exposures, tax benefits
associated with the interest on the Barracuda-Caratinga award, as well as discrete tax benefits related to deductions arising from an
unconsolidated joint venture in Australia. Provision for income taxes was $86 million for the year ended December 31, 2012.

Excluding discrete items, our effective tax rate was approximately 29.3% for the year ended December 31, 2011. The
effective tax rate for 2011, excluding discrete items, was lower than the U.S. statutory rate due to favorable tax rate differentials on
foreign earnings and lower tax expense on foreign income from unincorporated joint ventures. In 2011, we recognized discrete tax
benefits including a $69 million tax benefit related to the arbitration award against KBR associated with the Barracuda-Caratinga
project in Brazil as well as $32 million in tax benefits related to the reduction of deferred tax liabilities associated with the pending
liquidation of an unconsolidated joint venture in Australia resulting in a net effective tax rate of approximately 5.6%. In September
2011, an arbitration panel in the Barracuda-Caratinga arbitration awarded Petrobras $193 million which will be deductible for tax
purposes, and for which we are indemnified by our former parent, Halliburton. The indemnification payment from Halliburton to
KBR will be treated by KBR for tax purposes as a contribution to capital and accordingly is not taxable income. Consequently, the
arbitration ruling resulted in a tax benefit during 2011. In addition, we recognized other discrete tax benefits in 2011 totaling $34
million primarily from favorable return to accrual adjustments, I.R.S. audit adjustments and the execution of tax planning strategies.

The effective tax rate for the year ended December 31, 2010 was lower than our statutory rate primarily due to favorable
rate differentials on foreign earnings, benefits associated with income from unincorporated joint ventures and several favorable
discrete tax items including the adjustment of prior year U.S. income taxes and utilization of additional U.S. foreign tax credits
during 2010.

Net income attributable to noncontrolling interests was $58 million, $60 million and $68 million in 2012, 2011 and 2010,
respectively. The slight decrease in 2012 primarily resulted from lower earnings on projects that were completed or near
completion on our consolidated joint ventures. The decrease in 2011 compared to 2010 resulted from lower noncontrolling interests
due to the purchase of the remaining 44.94% interest in our MWKL subsidiary in 2011. These declines were partially offset by
higher earnings on certain LNG and GTL projects executed by consolidated joint ventures.

Backlog

Backlog generally represents the dollar amount of revenue we expect to realize in the future as a result of performing work
on contracts awarded to us. We generally include total expected revenue in backlog when a contract is awarded and/or the scope is
definitized. In many instances, arrangements included in backlog are complex, nonrepetitive in nature and may fluctuate depending
on estimated revenue and contract duration. Where contract duration is indefinite, projects included in backlog are limited to the
estimated amount of expected revenue within the following twelve months. Certain contracts provide maximum dollar limits, with
actual authorization to perform work under the contract agreed upon on a periodic basis with the customer. In these arrangements,
only the amounts authorized are included in backlog. For projects where we act solely in a project management capacity, we only
include our management fee revenue of each project in backlog. For certain long-term service contracts with a defined contract
term, such as those associated with privately financed projects, the amount included in backlog is limited to five years.

For our projects related to unconsolidated joint ventures, we have included in the table below our percentage ownership of
the joint venture’s estimated revenue in backlog. However, because these projects are accounted for under the equity method, only
our share of future earnings from these projects will be recorded in our revenue. Our backlog for projects related to unconsolidated
joint ventures totaled $5.8 billion at December 31, 2012 and $1.7 billion at December 31, 2011. We also consolidate joint ventures
which are majority-owned and controlled or are variable interest entities in which we are the primary beneficiary. Our backlog
included in the table below for projects related to consolidated joint ventures with noncontrolling interests includes 100% of the
backlog associated with those joint ventures and totaled $2.1 billion at December 31, 2012 and $3.4 billion at December 31, 2011.
All backlog is attributable to firm orders as of December 31, 2012 and 2011. Backlog attributable to unfunded government orders
was $236 million at December 31, 2012 and $395 million as of December 31, 2011.

Backlog

(in millions)

Hydrocarbons:

Gas Monetization

Oil & Gas

Downstream

Technology

Total Hydrocarbons

Infrastructure, Government and Power (“IGP”):

North American Government and Logistics

International Government, Defence and Support Services

Infrastructure

Minerals

Power and Industrial

Total IGP

Services

Ventures

Total backlog

December 31,

2012

2011

7,745
215
740
399
9,099

645
975
205
131
868
2,824
2,025
983
14,931

3,880

289

546

258

4,973

899

1,086

265

237

777

3,264

1,766

928

10,931

We estimate that as of December 31, 2012, 48% of our backlog will be executed within one year. As of December 31,
2012, 43% of our backlog was attributable to fixed-price contracts and 57% was attributable to cost-reimbursable contracts. For
contracts that contain both fixed-price and cost-reimbursable components, we classify the components as either fixed-price or cost-
reimbursable according to the composition of the contract except for smaller contracts where we characterize the entire contract
based on the predominant component.

Hydrocarbons backlog increased $4.1 billion due to the award of the Ichthys LNG project in Gas Monetization of $5.6
billion, as well as other Hydrocarbons awards of approximately $700 million. These awards are partially offset by $2.2 billion of
work performed on existing projects in Hydrocarbons. IGP Backlog decreased by $440 million primarily as a result of work
performed on existing projects across all IGP business units. Services backlog increased $259 million as new awards of $2.0 billion
primarily in our U.S. Construction and Canada product lines were offset by work performed of $1.7 billion on various construction
projects in the U.S. and Canada.

Liquidity and Capital Resources

Cash and equivalents totaled $1.1 billion at December 31, 2012 and $966 million at December 31, 2011, which included
$201 million and $244 million, respectively, of cash held by our joint ventures that we consolidate for accounting purposes. Joint
venture cash balances are limited to joint venture activities and are not available for use on other projects, general cash needs or
distributions to us without approval of the board of directors of the respective joint ventures. We expect to use joint venture cash
for project costs and distribution of profits.

Cash generated from operations is our primary source of operating liquidity. Our cash balances are held in numerous
locations throughout the world, the majority of which are outside of the U.S. Of the $852 million in non-joint venture cash and
equivalents held at December 31, 2012, approximately $610 million is held in foreign subsidiaries. The remaining cash is non-joint
venture domestic cash. Demands on our domestic cash have increased as a result of our strategic initiatives including business
acquisitions, share repurchases and capital expenditures. We fund these initiatives through our existing cash and investment
balances and internally generated cash. When appropriate, we may access offshore cash and equivalents. Where local regulations
limit an efficient intercompany transfer of amounts held outside of the U.S., we will continue to utilize these funds for foreign
activities primarily associated with project execution. We believe that internally generated cash flows are sufficient to support our
day-to-day business operations, both domestically and internationally, for at least the next 12 months.

We generally do not provide U.S. federal and state income taxes on the accumulated but undistributed earnings of non-
United States subsidiaries except for certain entities in Mexico and certain other joint ventures, as well as for a portion of our
earnings from our operations in Australia. Taxes are provided as necessary with respect to earnings that are considered not
permanently reinvested. Beginning in the second quarter of 2012, we provided for U.S. federal and state income taxes on 50% of
the earnings of our Australian operations during the period ending December 31, 2012. We will continue to provide for U.S.
federal and state taxes on this portion of the earnings of our Australian operations as we no longer intend to permanently reinvest
these amounts. For all other non-U.S. subsidiaries, no U.S. taxes are provided because such earnings are intended to be reinvested
indefinitely to finance foreign activities. These accumulated but undistributed foreign earnings could be subject to additional tax if

remitted, or deemed remitted, as a dividend. Determination of the amount of unrecognized deferred U.S. income tax liability is not
practicable; however, the potential foreign tax credits associated with the deferred income would be available to reduce the resulting
U.S. tax liabilities. As of December 31, 2012, foreign cash and equivalents that could be subject to additional U.S. income taxes and
withholding taxes payable to the various foreign jurisdictions if remitted, or deemed remitted, as a dividend, excluding cash held by
consolidated joint ventures, is estimated to be approximately $565 million.

Our operating cash flow can vary significantly from year to year and are affected by the mix, terms and percentage of
completion of our engineering and construction projects. We often receive cash through advanced billings to our customers on our
larger engineering and construction projects and those of our consolidated joint ventures. Joint venture cash balances are limited to
joint venture activities and are not available for general cash needs, use on other projects or distributions to us without proper
approval by the respective joint venture. As client cash advances are used in the execution of a project, they are recovered through
regular or milestone billings to the customer. To the extent our net investment in the operating assets of a project is greater than
available project cash, we may utilize other cash on hand, or availability under our Credit Agreement, to satisfy any periodic
operating cash requirements.

Engineering and construction projects generally require us to provide credit support to our customers in the form of letters of
credit, surety bonds or guarantees. Our ability to obtain new project awards in the future may be dependent on our ability to
maintain or increase our letter of credit and surety bonding capacity, which may be further dependent on the timely release of
existing letters of credit and surety bonds. As the need for credit support arises, letters of credit will be issued under our Credit
Agreement or arranged with our banks on a bilateral, syndicated or other basis. We believe we have adequate letter of credit
capacity under our existing Credit Agreement and bilateral lines, as well as adequate surety bond capacity under our existing lines
to support our operations and current backlog for the next twelve months.

Our excess cash is generally invested in either time deposits with commercial banks or money market funds governed under
rule 2a-7 of the U.S. Investment Company Act of 1940 and rated AAA by Standard & Poor’s or Aaa by Moody’s Investors Service,
respectively. As of December 31, 2012, substantially all of our excess cash was held in time deposits with commercial banks with
the primary objectives of preserving capital and maintaining liquidity.

Cash flow activities summary

Millions of dollars

Cash flows provided by operating activities

Cash flows provided by (used in) investing activities

Cash flows used in financing activities

Effect of exchange rate changes on cash

Increase (decrease) in cash and equivalents

Cash increase due to consolidation of a variable interest entity

Net increase (decrease) in cash and equivalents

Years Ended December 31,

2012

2011

2010

142

(116)

—

650
(88 )

(377 )

(5 )

180
—
180

549

(397)

(336)

(177)

(155)

Operating activities. Cash provided by operations in 2012 of $142 million resulted from our earnings, adjusted
for items to reconcile to net income, of $317 million and distributions from unconsolidated affiliates of $102 million
(net) partially offset by working capital uses related to the Gas Monetization, Services and NAGL business units.

Cash provided by operations totaled $650 million in 2011, driven primarily by strong earnings and collections of advances
and distributions from unconsolidated affiliates of $196 million. Operating cash flow was primarily driven by the timing of
working capital requirements on several large projects. Cash remitted for income taxes, net of refunds, was $201 million during
2011. In addition, we contributed $74 million to our pension plans during 2011, including a one-time contribution of $40 million
which had been previously agreed with the trustees of our international U.K. plans. Cash held by consolidated joint ventures
increased by $99 million.

Cash provided by operating activities during 2010 was primarily driven by strong overall earnings, cash cycle improvements
and active management of working capital to support project execution activities. Cash provided by operations totaled $549 million
and included $93 million representing distributions of earnings from our unconsolidated joint ventures and $116 million
representing advances from our clients. Cash held by consolidated joint ventures decreased by $91 million.

Investing activities. Cash provided by investing activities in 2012 totaled $52 million which was primarily due to proceeds
of $127 million from the sale of our interest in the 601 Jefferson building and the Clinton Drive campus facility. These proceeds
were offset by capital expenditures of $75 million associated with information technology projects and leasehold and facility
improvements.

Cash used in investing activities in 2011 totaled $88 million which was primarily due to capital expenditures of $83 million
largely related to information technology projects and leasehold improvements. Additionally, we made investments totaling $11
million in an equity method joint venture associated with the lease of our corporate headquarters and received proceeds of $6
million from the sale of an investment.

Cash used in investing activities for 2010 totaled $397 million and related to the net cash paid of $299 million for the
acquisition of R&S and Energo Engineering. Capital expenditures were $66 million in 2010. During 2010, we paid $20 million for
the exclusive right to certain technology under a 25-year licensing arrangement. We also made investments totaling $12 million in
several equity method joint ventures.

Financing activities. Cash used in financing activities in 2012 totaled $116 million and included $40 million for the
repurchase of common stock, $37 million for dividend payments to common shareholders, $36 million for distributions to
noncontrolling interests and $14 million for principal payments on other long-term borrowings consisting primarily of non-recourse
debt of the Fasttrax VIE and computer software purchases financed in 2010. The uses of cash were partially offset by $11 million
of tax benefits associated with stock exercises and proceeds from the exercise of stock options.

Cash used in financing activities for the year ended December 31, 2011 totaled $377 million and included $178 million of
payments to acquire the noncontrolling interest in MWKL, $118 million of payments to repurchase 4 million shares of our common
stock, $63 million related to distributions to owners of noncontrolling interests in several of our consolidated joint ventures, $30
million related to dividend payments to our shareholders and $15 million of payments on debt related to the Fasttrax VIE as well as
the payment of financed computer software purchased in 2010. These payments were partially offset by a return of cash of $17
million used to collateralize standby letters of credit.

Cash used in financing activities for the year ended December 31, 2010 totaled $336 million and included $233 million of
payments to repurchase approximately 10 million shares of our common stock, $91 million related to distributions to noncontrolling
interests of several of our consolidated joint ventures and $32 million related to dividend payments to shareholders. These
payments were partially offset by return of cash used to collateralize standby letters of credit of $28 million.

Future sources of cash. Future sources of cash include cash flows from operations, including cash advances from our

clients, cash derived from working capital management and advances under our Credit Agreement.

Future uses of cash. Future uses of cash will primarily relate to working capital requirements, capital expenditures and
acquisitions. In addition, we will use cash to fund pension obligations, payments under operating leases, cash dividends, share
repurchases and various other obligations as they arise. Our capital expenditures will be focused primarily on information
technology, real estate, facilities and equipment. See “Off balance sheet arrangements - commitments and other contractual
obligations” below for a schedule of contractual obligations and other long-term liabilities that will require the use of cash.

Credit Agreement

On December 2, 2011, we entered into a $1 billion, five-year unsecured revolving credit agreement (the “Credit
Agreement”) with a syndicate of international banks. The Credit Agreement expires in December 2016 and may be used for
working capital, the issuance of letters of credit and other general corporate purposes. Amounts drawn under the Credit Agreement
will bear interest at variable rates, per annum, based either on (i) the London interbank offered rate (“LIBOR”) plus an applicable
margin of 1.50% to 1.75%, or (ii) a base rate plus an applicable margin of 0.50% to 0.75%, with the base rate equal to the highest of
(a) reference bank’s publicly announced base rate, (b) the Federal Funds Rate plus 0.5%, or (c) LIBOR plus 1%. The amount of the
applicable margin to be applied will be determined by the Company’s ratio of consolidated debt to consolidated EBITDA for the
prior four fiscal quarters, as defined in the Credit Agreement. The Credit Agreement provides for fees on letters of credit issued
under the Credit Agreement at a rate equal to the applicable margin for LIBOR-based loans, except for performance letters of
credit, which are priced at 50% of such applicable margin. KBR pays an issuance fee of 0.15% of the face amount of a letter of
credit. KBR also pays a commitment fee of 0.25%, per annum, on any unused portion of the commitment under the Credit
Agreement. As of December 31, 2012, there were $217 million in letters of credit and no advances outstanding.

The Credit Agreement contains customary covenants which include financial covenants requiring maintenance of a ratio of
consolidated debt to consolidated EBITDA not greater than 3.5 to 1 and a minimum consolidated net worth of $2 billion plus 50%
of consolidated net income for each quarter beginning December 31, 2011 and 100% of any increase in shareholders’ equity
attributable to the sale of equity interests. The noncash goodwill impairment of $178 million related to our Minerals reporting unit
did not have a material impact on the financial covenants in our credit agreements.

The Credit Agreement contains a number of other covenants restricting, among other things, our ability to incur additional
liens and indebtedness, enter into asset sales, repurchase our equity shares and make certain types of investments. Our subsidiaries
are restricted from incurring indebtedness, except if such indebtedness relates to purchase money obligations, capitalized leases,
refinancing or renewals secured by liens upon or in property acquired, constructed or improved in an aggregate principal amount
not to exceed $200 million at any time outstanding. Additionally, our subsidiaries may incur unsecured indebtedness not to exceed
$200 million in aggregate outstanding principal amount at any time. We are also permitted to repurchase our equity shares,
provided that no such repurchases shall be made from proceeds borrowed under the Credit Agreement, and that the aggregate
purchase price and dividends paid after December 2, 2011, does not to exceed the Distribution Cap (equal to the sum of $750

million plus the lesser of (1) $400 million and (2) the amount received by us in connection with the arbitration and subsequent
litigation of the PEMEX contracts as discussed in Note 10 to our consolidated financial statements). At December 31, 2012, the
remaining availability under the Distribution Cap was approximately $659 million.

Currently, we do not believe we have any significant exposure to the ongoing European debt crisis through our banking
relationships. Although we maintain banking relationships with several U.K. and continental European banks, very few banks are
located in the more economically distressed nations within the European Union, such as Greece, Ireland, Italy, Portugal or Spain.

Nonrecourse Project Finance Debt

Fasttrax Limited, a joint venture in which we indirectly own a 50% equity interest with an unrelated partner, was awarded a
contract in 2001 with the U.K. MoD to provide a fleet of 92 heavy equipment transporters (“HETs”) to the British Army. Under the
terms of the arrangement, Fasttrax Limited operates and maintains the HET fleet for a term of 22 years. The purchase of the HETs
by the joint venture was financed through a series of bonds secured by the assets of Fasttrax Limited totaling approximately
£84.9 million and are non-recourse to KBR and its partner including £12.2 million which was replaced when the shareholders
funded combined equity and subordinated debt of approximately £12.2 million.

The guaranteed secured bonds were issued in two classes consisting of Class A 3.5% Index Linked Bonds in the amount of
£56 million and Class B 5.9% Fixed Rate Bonds in the amount of £16.7 million. Payments on both classes of bonds commenced in
March 2005 and are due in semi-annual installments over the term of the bonds which end in 2021. Subordinated notes payable to
our 50% partner initially bear interest at 11.25% increasing to 16% over the term of the note through 2025. Payments on the
subordinated debt commenced in March 2006 and are due in semi-annual installments over the term of the note.

The combined principal installments for both classes of bonds and subordinated notes, including inflation adjusted bond
indexation, are included in the commitments and contractual obligations table in the following section. The secured bonds are an
obligation of Fasttrax Limited and will never be a debt obligation of KBR because they are non-recourse to the joint venture
partners. Accordingly, in the event of a default on the term loan, the lenders may only look to the resources of Fasttrax Limited for
repayment. For additional information, see Note 8 of our consolidated financial statements. See our "Commitments and other
contractual obligations" table for the scheduled payments.

Off-Balance Sheet Arrangements

Letters of credit, surety bonds and guarantees. In connection with certain projects, we are required to provide letters of
credit, surety bonds or guarantees to our customers. Letters of credit are provided to certain customers and counter-parties in the
ordinary course of business as credit support for contractual performance guarantees, advanced payments received from customers
and future funding commitments. We have approximately $2.5 billion in committed and uncommitted lines of credit to support the
issuance of letters of credit and as of December 31, 2012, and we have utilized $765 million of our present capacity under lines of
credit. Surety bonds are also posted under the terms of certain contracts to guarantee our performance. The letters of credit
outstanding included $217 million issued under our Credit Agreement and $548 million issued under uncommitted bank lines at
December 31, 2012. Of the total letters of credit outstanding, $277 million relate to our joint venture operations and $9 million of
the letters of credit have terms that could entitle a bank to require additional cash collateralization on demand. As the need arises,
future projects will be supported by letters of credit issued under our Credit Agreement or other lines of credit arranged on a
bilateral, syndicated or other basis. We believe we have adequate letter of credit capacity under our Credit Agreement and bilateral
lines of credit to support our operations for the next twelve months.

Commitments and other contractual obligations. The following table summarizes our significant contractual obligations

and other long-term liabilities as of December 31, 2012:

2013

2014

2015

2016

2017

Payments Due

Millions of dollars

Operating leases

Purchase obligations(a)

Pension funding obligation (b)

Nonrecourse project finance debt

Total (c)

95
28
25
10
158

128

109

—

Thereafter
429
—
108
42
579

—

Total

797

213

1,152

(a)

(b)

(c)

The purchase obligations disclosed above do not include purchase obligations that we enter into with vendors in the
normal course of business that support existing contracting arrangements with our customers. The purchase obligations
with our vendors can span several years depending on the duration of the projects. In general, the costs associated with
those purchase obligations are expensed to correspond with the revenue earned on the related projects.
Included in our pension obligations are payments related to our agreement with the trustees of our international plan. The
agreement calls for minimum contributions of £13.3 million in 2013; £12.5 million in 2014-2019; £10.6 million in 2020
and £10 million in 2021-2023. The foreign funding obligations were converted to U.S. dollars using the conversion rate
as of December 31, 2012. We are in discussions with the Trustees of our U.K. pension plan concerning the Plan's
triennial valuation. At present, it is uncertain how the results of these discussions will impact our future funding
obligations.
Not included in the total are uncertain tax positions recorded pursuant to ASC 740 - Income Taxes which totaled $95
million as of December 31, 2012. The ultimate timing of when these obligations will be settled cannot be determined
with reasonable assurance and have been excluded from the table above. Refer to Note 11 in our consolidated financial
statements.

Other factors affecting liquidity

Government claims. Included in receivables in our consolidated balance sheets are claims for costs incurred under various
government contracts totaling $219 million at December 31, 2012, of which $104 million is included in “Accounts receivable” and
$115 million is included in “Unbilled receivables on uncompleted contracts.” These claims relate to contracts where our costs have
exceeded the customer’s funded value of the task order. The $104 million of claims included in Accounts receivable results
primarily from de-obligated funding on certain task orders that were also subject to Form 1s relating to certain DCAA audit issues
discussed above. We believe such disputed costs will be resolved in our favor at which time the customer will be required to
obligate funds from appropriations for the year in which resolution occurs. The remaining claims balance of $115 million primarily
represents costs for which incremental funding is pending in the normal course of business. The claims outstanding at
December 31, 2012 are considered to be probable of collection and have been previously recognized as revenue.

Liquidated damages. Many of our engineering and construction contracts have milestone due dates that must be met or we
may be subject to penalties for liquidated damages if claims are asserted and we were responsible for the delays. These generally
relate to specified activities that must be met within a project by a set contractual date or achievement of a specified level of output
or throughput of a plant we construct. Each contract defines the conditions under which a customer may make a claim for
liquidated damages. However, in many instances, liquidated damages are not asserted by the customer, but the potential to do so is
used in negotiating claims and closing out the contract.

Based upon our evaluation of our performance and other legal analysis, we have not accrued for possible liquidated damages
related to several projects totaling $2 million at December 31, 2012 and $11 million at December 31, 2011, (including amounts
related to our share of unconsolidated subsidiaries), that we could incur based upon completing the projects as currently forecasted.

Goodwill Impairment Review

We perform our annual goodwill impairment review as of October 1 of each year and also perform interim impairment
reviews if events occur or circumstances change that indicate it is likely that the fair value of a reporting unit is below its carrying
amount. Our 2011 annual goodwill impairment review, performed as of October 1, 2011, did not indicate an impairment of
goodwill for any of our reporting units. In the third quarter of 2012, during the course of our annual strategic planning process, we
determined that both the actual and expected income and cash flows for our Minerals reporting unit were substantially lower than
previous forecasts due to losses from ongoing projects acquired as part of the acquisition of R&S. We also identified deterioration
in economic conditions in the minerals markets and less than expected actual and projected income and cash flows for the Minerals
reporting unit, which is part of our IGP segment. This resulted in a reduction of our forecasts of the sales, operating income and
cash flows expected in 2013 and beyond. Therefore, we performed an interim goodwill impairment test during the third quarter of
2012.

The first step in performing a goodwill impairment test is to identify potential impairment by comparing the estimated fair
value of the reporting unit to its carrying value. The result of the first step of our goodwill impairment test indicated the carrying
value of our Minerals reporting unit exceeded its fair value. Therefore, we performed the second step of the goodwill impairment
test in order to measure the amount of the potential impairment loss. The second step of the goodwill impairment test compares the
implied fair value of the reporting unit's goodwill to the carrying value of that goodwill. We determined the implied fair value of
the goodwill in the same manner as we use in determining the amount of goodwill to be recognized in a business combination.
Applying this methodology, we assigned the fair value of the Minerals reporting unit estimated in step one to all the assets and
liabilities of the reporting unit. The implied fair value of the Minerals reporting unit's goodwill is the excess of the fair value of the
reporting unit over the amounts assigned to its assets and liabilities. As a result of our interim goodwill impairment test, we
recorded a noncash goodwill impairment charge in our IGP segment of $178 million in the third quarter of 2012. Due to the
impairment, the Minerals reporting unit goodwill decreased from its December 31, 2011 balance of $263 million to $85 million at
September 30, 2012. The impact of this goodwill impairment resulted in a reduction of our IGP segment's goodwill by $178
million from the carrying value of $403 million at December 31, 2011. We will continue to monitor the recoverability of our
goodwill.

For purposes of our interim impairment test, the fair value of the Minerals reporting unit was determined using a
combination of two methods; one based on market earnings multiples (the market approach), and a discounted cash flow model
with estimates of cash flows based on internal forecasts of revenues and expenses over a 10 year period plus a terminal value period
(the income approach). The market approach estimates fair value by applying earnings and revenue market multiples to the
reporting unit's operating performance for the trailing twelve-month period. The income approach estimates fair value by
discounting the reporting unit's estimated future cash flows using a weighted-average cost of capital that reflects current market
conditions and the risk profile of the business unit.

To arrive at the Minerals reporting unit's future cash flows, we used estimates of economic and market assumptions,
including growth rates in revenues, costs and estimates of future expected changes in operating margins, tax rates and cash
expenditures. Other significant estimates and assumptions include terminal value growth rates, future estimates of capital
expenditures and changes in future working capital requirements. Under the income approach, we applied a risk-adjusted discount
rate of 16% to the future cash flows from the Minerals reporting unit. In addition to the earnings multiples and the discount rate,
certain other judgments and estimates are used to prepare the goodwill impairment test. If market conditions change compared to
those used in our market approach, or if actual future results of operations fall below the projections used in the income approach,
our goodwill could become further impaired in the future.

Transactions with Former Parent

In connection with our initial public offering in November 2006 and the separation of our business from Halliburton, we
entered into various agreements, including, among others, a master separation agreement, transition services agreements and a tax
sharing agreement. Pursuant to our master separation agreement, we agreed to indemnify Halliburton for, among other matters,
past, present and future liabilities related to our business and operations. We agreed to indemnify Halliburton for liabilities under
various outstanding and certain additional credit support instruments relating to our businesses and for liabilities under litigation
matters related to our business. Halliburton agreed to indemnify us for, among other things, liabilities unrelated to our business, for
certain other agreed matters relating to the investigation of FCPA and related corruption allegations and the Barracuda-Caratinga
project and for other litigation matters related to Halliburton’s business. See Note 10. Under the transition services agreements,
Halliburton provided various interim corporate support services to us and we provided various interim corporate support services to
Halliburton. The tax sharing agreement provides for certain allocations of U.S. income tax liabilities and other agreements between
us and Halliburton with respect to tax matters.

As of December 31, 2012, “Due to former parent, net” was $49 million and comprised primarily of estimated amounts owed
to Halliburton under the tax sharing agreement for income taxes expected to be owed to the IRS or other tax authorities. Our
estimate of amounts due to Halliburton under the tax sharing agreement relates to income tax adjustments paid by Halliburton
subsequent to our separation that were directly attributable to us, primarily for the years from 2001 through 2006. Some or all of
these amounts may change as a result of our pending tax disputes with Halliburton described below.

During the fourth quarter of 2011, Halliburton provided notice and demanded payment for amounts significantly greater
than our accrued liability that it alleges are owed by us under the tax sharing agreement for various other tax-related transactions
pertaining to periods prior to our separation from Halliburton. We believe that the amount in the demand is invalid based on our
assessment of Halliburton’s methodology for computing the claim. Based on advice from internal and external legal counsel, we do
not believe that Halliburton has a legal entitlement to payment of the amount in the demand. However, although we believe we
have appropriately accrued for amounts potentially owed to Halliburton based on our interpretation of the tax sharing agreement,
there may be changes to the amounts ultimately paid to or received from Halliburton under the tax sharing agreement upon final
settlement. On July 3, 2012, KBR requested an arbitration panel be appointed to resolve certain intercompany issues arising under
the master separation agreement in effect between the companies before issues in dispute under the tax sharing agreement were
submitted to the designated “accounting referee” as provided for under the terms of the tax sharing agreement. We believe these
intercompany issues were settled and released as a result of our separation from Halliburton in 2007. On July 10, 2012, Halliburton
filed a complaint in Texas State Court seeking to compel resolution of all issues, including intercompany issues believed by KBR to
be governed by the master separation agreement, under the tax sharing agreement. In October 2012, the Court denied Halliburton's

request, and we moved forward with the selection of arbitrators to decide the intercompany issues. We are set for an arbitration
hearing in May 2013. The remaining tax-related issues in dispute will be resolved by the "accounting referee" as provided for
under the terms of the tax sharing agreement.

As of December 31, 2012, included in “Other assets” is an income tax receivable of approximately $22 million related to a
foreign tax credit generated as a result of a final settlement we paid to a foreign taxing authority in 2011 for a disputed tax matter
that arose prior to our separation from Halliburton. In order to claim the tax credit, we requested, and Halliburton agreed to and did
file an amended U.S. Federal tax return for the period in which the disputed tax liability arose. However, Halliburton notified us
that it does not intend to remit to us the refund received or to be received by Halliburton as a result of the amended return. KBR
disputes Halliburton’s position on this matter and believes it has legal entitlement to the $22 million refund. We intend to
vigorously pursue collection of this amount and certain other unrecorded counterclaims.

As discussed above under “Barracuda-Caratinga Project Arbitration,” we have recorded an indemnification receivable due
from Halliburton of approximately $219 million, including interest, associated with our estimated liability in the bolts matter which
is included in “Other current assets” as of December 31, 2012. In January 2013, Halliburton paid $219 million to the claimant and
the matter is considered concluded. We believe the arbitration award payable to Petrobras will be deductible for tax purposes when
paid and the indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not
taxable. In 2011 and 2012, we recorded discrete tax benefits of $71 million and $8 million, respectively. At December 31, 2012
the deferred tax balance is $79 million. We have reviewed this matter in light of the direct payment by Halliburton to Barracuda &
Caratinga Leasing Company B.V. ("BCLC") and its public announcement that they have recorded a tax benefit related to this
transaction. Based on advice from outside legal counsel, we have determined that it is more likely than not that we are the proper
taxpayer to recognize this benefit although the underlying uncertainties with respect to the tax treatment of the transaction may
ultimately lead to alternate outcomes.

Halliburton indemnities. Halliburton has agreed to indemnify us and certain of our greater than 50%-owned subsidiaries for
fines or other monetary penalties or direct monetary damages, including disgorgement, as a result of claims made or assessed
against us by U.S. and certain foreign governmental authorities or a settlement thereof, relating to investigations under the FCPA or
analogous applicable foreign statutes related investigations with respect to the construction and subsequent expansion by TSKJ of a
natural gas liquefaction complex in Nigeria. Halliburton has also agreed to indemnify us for out-of-pocket cash costs and expenses,
or cash settlement or cash arbitration awards in lieu thereof, we may incur as a result of the replacement of certain subsea flow-line
bolts installed in connection with the Barracuda-Caratinga project. As discussed under the heading “Barracuda-Caratinga Project
Arbitration,” we have recorded an indemnification receivable due from Halliburton of approximately $219 million, including
interest, associated with our estimated liability in the bolts matter which is included in “Other current assets” as of December 31,
2012. In January 2013, Halliburton paid $219 million to the claimant and the matter is considered concluded. See Note 10 to our
consolidated financial statements for further discussion.

Financial Instruments Market Risk

We invest excess cash and equivalents in short-term securities, primarily time deposits, which carry a fixed rate of return for

a given duration of time. Additionally, a substantial portion of our cash balances are maintained in foreign countries.

We have foreign currency exchange rate risk resulting from our international operations. We do not comprehensively hedge
the exposure to currency rate changes; however, we selectively manage these exposures through the use of derivative instruments to
mitigate our market risk from these exposures. The objective of our risk management program is to protect our cash flows related
to sales or purchases of goods and services from market fluctuations in currency rates. We do not use derivative instruments for
speculative trading purposes. We generally utilize currency options and forward exchange contracts to hedge foreign currency
transactions entered into in the ordinary course of business. As of December 31, 2012, we had forward foreign exchange contracts
of up to 33 months in duration to exchange major world currencies. The total gross notional amount of these contracts at
December 31, 2012, 2011 and 2010 was $517 million, $352 million and $403 million, respectively. These contracts had fair values
of $(1) million, $5 million and $6 million at December 31, 2012, 2011 and 2010, respectively.

Transactions with Joint Ventures

We perform many of our projects through incorporated and unincorporated joint ventures. In addition to participating as a
joint venture partner, we often provide engineering, procurement, construction, operations or maintenance services to the joint
venture as a subcontractor. Where we provide services to a joint venture that we control and therefore consolidate for financial
reporting purposes, we eliminate intercompany revenues and expenses on such transactions. In situations where we account for our
interest in the joint venture under the equity method of accounting, we do not eliminate any portion of our revenues or expenses.
We recognize the profit on our services provided to joint ventures that we consolidate and joint ventures that we record under the
equity method of accounting primarily using the percentage-of-completion method.

Recent Accounting Pronouncements

Information related to new accounting standards is described in Note 18 to the consolidated financial statements.

U.S. Government Matters

Award Fees

In accordance with the provisions of the LogCAP III contract, we recognized revenue on our services rendered on a task
order basis based on either a cost-plus-fixed-fee or cost-plus-base-fee and award fee arrangement. The fees were determined as a
percentage rate applied to a negotiated estimate of the total costs for each task order.

In 2010, we received award fees of $94 million for the period of performance from May 2008 through May 2010 for task
orders in Iraq and Afghanistan which we recorded as an increase to revenue. In 2011, we were awarded and recognized revenue of
$41 million for award fees for the periods of performance from March 2010 through February 2011 on task orders in Iraq. No
award fee pools are available for periods of performance subsequent to February 2011.

In August of 2010, we executed a contract modification to the LogCAP III contract on the base life support task order in
Iraq that resulted in an increase to our base fee on costs incurred and an increase in the maximum award fee on negotiated costs for
the period of performance from September 2010 through February 2011. During the first quarter of 2011, we finalized negotiations
with our customer and converted the task order from cost-plus-base-fee and award fee to cost-plus-fixed-fee for the period of
performance beginning in March 2011. We recognize revenues for the fixed-fee component on the basis of proportionate
performance as services are performed.

Government Compliance Matters

The negotiation, administration and settlement of our contracts with the U.S. government, consisting primarily of DoD
contracts, are subject to audit by the Defense Contract Audit Agency (“DCAA”), which serves in an advisory role to the Defense
Contract Management Agency (“DCMA”), which is responsible for the administration of our contracts. The scope of these audits
include, among other things, the allowability, allocability and reasonableness of incurred costs, approval of annual overhead rates,
compliance with the Federal Acquisition Regulation (“FAR”) and Cost Accounting Standards (“CAS”), compliance with certain
unique contract clauses and audits of certain aspects of our internal control systems. Issues identified during these audits are
typically discussed and reviewed with us, and certain matters are included in audit reports issued by the DCAA, with its
recommendations to our customer’s Administrative Contracting Officer (“ACO”). We attempt to resolve all issues identified in
audit reports by working directly with the DCAA and the ACO. When agreement cannot be reached, the DCAA may issue a Form
1, “Notice of Contract Costs Suspended and/or Disapproved,” which recommends withholding the previously paid amounts or it
may issue an advisory report to the ACO. KBR is permitted to respond to these actions and provide additional support. At
December 31, 2012, we have open Form 1s from the DCAA recommending suspension of payments totaling approximately $333
million associated with our contract costs incurred in prior years, of which $140 million has been withheld from our current
billings. As a consequence, for certain of these matters, we have withheld $57 million from our subcontractors under the payment
terms of those contracts. In addition, we have outstanding demand letters received from our customer requesting that we remit a
total of $98 million of disapproved costs for which we do not believe we have a legal obligation to pay. We continue to work with
our ACOs, the DCAA and our subcontractors to resolve these issues. However, for certain of these matters, we have filed claims
with the Armed Services Board of Contract Appeals (“ASBCA”) or the United States Court of Federal Claims (“U.S. COFC”).

KBR excludes from billings to the U.S. government costs that are potentially unallowable, expressly unallowable, or
mutually agreed to be unallowable, or not allocable to government contracts pursuant to applicable regulations. Revenue recorded
for government contract work is reduced at the time we identify and estimate potentially refundable costs related to issues that may
be categorized as disputed or unallowable as a result of cost overruns or the audit process. Our estimates of potentially unallowable
costs are based upon, among other things, our internal analysis of the facts and circumstances, terms of the contracts and the
applicable provisions of the FAR and CAS, quality of supporting documentation for costs incurred and subcontract terms as
applicable. From time to time, we engage outside counsel to advise us on certain matters in determining whether certain costs are
allowable. We also review our analysis and findings with the ACO as appropriate. In some cases, we may not reach agreement
with the DCAA or the ACO regarding potentially unallowable costs which may result in our filing of claims in various courts such
as the ASBCA or the U.S. COFC. We only include amounts in revenue related to disputed and potentially unallowable costs when
we determine it is probable that such costs will result in the collection of revenue. We generally do not recognize additional
revenue for disputed or potentially unallowable costs for which revenue has been previously reduced until we reach agreement with
the DCAA and/or the ACO that such costs are allowable.

Certain issues raised as a result of contract audits and other investigations are discussed below.

Private Security. In 2007, we received a Form 1 from the Department of the Army ("Army") informing us of their intent to
adjust payments under the LogCAP III contract associated with the cost incurred for the years 2003 through 2006 by certain of our
subcontractors to provide security to their employees. Based on that notice, the Army withheld its initial assessment of $20 million.
The Army based its initial assessment on one subcontract wherein, based on communications with the subcontractor, the Army
estimated 6% of the total subcontract costs related to the private security. We subsequently received Form 1s from the DCAA
disapproving an additional $83 million of costs alleged to have been incurred by us and our subcontractors to provide security
during the same periods. Since that time, the Army withheld an additional $25 million in payments from us bringing the total
payments withheld to $45 million as of December 31, 2012 out of the Form 1s issued to date of $103 million.

The Army indicated that they believe our LogCAP III contract prohibits us and our subcontractors from billing costs of
privately armed security. We believe that, while the LogCAP III contract anticipates that the Army will provide force protection to
KBR employees, it does not prohibit us or any of our subcontractors from using private security services to provide force protection
to KBR or subcontractor personnel. In addition, a significant portion of our subcontracts are competitively bid fixed price
subcontracts. As a result, we do not receive details of the subcontractors’ cost estimate nor are we legally entitled to it. Further, we
have not paid our subcontractors any additional compensation for security services. Accordingly, we believe that we are entitled to
reimbursement by the Army for the cost of services provided by us or our subcontractors, even if they incurred costs for private
force protection services. Therefore, we do not agree with the Army’s position that such costs are unallowable and that they are
entitled to withhold amounts incurred for such costs.

We have provided at the Army’s request information that addresses the use of armed security either directly or indirectly
charged to LogCAP III. In 2007, we filed a complaint in the ASBCA to recover $44 million of the amounts withheld from us. In
2009, KBR and the Army agreed to stay the case pending further discussions with the U.S. Department of Justice ("DOJ") as
discussed further below. The ASBCA denied the Army's latest request to stay the proceedings. In April 2012, the ASBCA ruled,
as requested by KBR, that our contract with the Army does not prohibit the use of private security contractors by either KBR or its
subcontractors. However, our motion to dismiss was denied on grounds that potential fact issues remain related to the
reasonableness of the private security costs charged to the contract. Because of continuing delays in getting documents from the
U.S. government attorneys during the discovery process, the hearing date has passed and all claims have been consolidated for
hearing. The three private security-related appeals currently pending before the ASBCA now have been consolidated for a single,
four-week hearing starting April 1, 2013. These appeals potentially involve the alleged use of private security contractors (“PSCs”)
by both KBR and up to 33 of its LOGCAP III subcontractors. We believe these sums were properly billed under our contract with
the Army. At this time, we believe the likelihood that a loss related to this matter has been incurred is remote. We have not
adjusted our revenues or accrued any amounts related to this matter.

Containers. In June 2005, the DCAA recommended withholding certain costs associated with providing containerized
housing for soldiers and supporting civilian personnel in Iraq. The DCMA agreed that the costs be withheld pending receipt of
additional explanation or documentation to support the subcontract costs. During the first quarter of 2011, we received a Form 1
from the DCAA disapproving $25 million in costs related to containerized housing that had previously been deemed allowable. As
of December 31, 2012, $51 million of costs have been suspended under Form 1s of which $26 million have been withheld from us
by our customer. We have withheld $30 million from our subcontractor related to this matter. In April 2008, we filed a
counterclaim in arbitration against our LogCAP III subcontractor, First Kuwaiti Trading Company, to recover the $51 million we
paid to the subcontractor for containerized housing as further described under the caption First Kuwaiti Trading Company
arbitration below. During the first quarter of 2011, we filed a complaint before the ASBCA to contest the Form 1s and to recover
the amounts withheld from us by our customer. That complaint was dismissed without prejudice in January 2013. We are free to
re-file the complaint in the future. We believe that the costs incurred associated with providing containerized housing are
reasonable, and we intend to vigorously defend ourselves in this matter. We do not believe that we face a risk of significant loss
from any disallowance of these costs in excess of the amounts we have withheld from subcontractors and the loss accruals we have
recorded. At this time, we believe that the likelihood that we have incurred a loss related to this matter is remote. This matter is
also the subject of a separate claim filed by the DOJ for alleged violation of the False Claims Act as discussed further below under
the heading “Investigations, Qui Tams and Litigation.”

Dining facilities. In 2006, the DCAA raised questions regarding our billings and price reasonableness of costs related to
dining facilities in Iraq. We responded to the DCMA that our costs are reasonable. As of December 31, 2012, we have outstanding
Form 1s from the DCAA disapproving $106 million in costs related to these dining facilities until such time we provide
documentation to support the price reasonableness of the rates negotiated with our subcontractor and demonstrate that the amounts
billed were in accordance with the contract terms. We believe the prices obtained for these services were reasonable and intend to
vigorously defend ourselves on this matter. We filed claims in the U.S. COFC or ASBCA to recover $55 million of the $59 million
withheld from us by the customer. In April 2012, the U.S. COFC ruled that KBR's negotiated price for certain DFAC services were
not reasonable and that we are entitled to $12 million of the total $41 million withheld from us by our customer related to one of our
subcontractors, Tamimi. As a result of this ruling, we recognized a noncash, pre-tax charge of $28 million as a reduction to revenue
related to the disallowed portion of the questioned costs in the second quarter of 2012. We appealed the U.S. COFC ruling. Prior
to the U.S. COFC ruling, Tamimi filed for arbitration against us in 2009 to recover the payments we withheld from Tamimi pending
the resolution of Form 1s with our customer. In December 2010, the arbitration panel ruled that our subcontract terms were not
sufficient to hold retention from Tamimi for price reasonableness matters and awarded the subcontractor $38 million including
interest and certain legal costs. We paid the award to Tamimi during the third quarter of 2011. We do not believe we have the
ability to recover the disallowed portion of the questioned costs previously paid to Tamimi. With respect to remaining questions
raised regarding billing in accordance with contract terms, as of December 31, 2012, we believe it is reasonably possible that we
could incur losses in excess of the amount accrued for possible subcontractor costs billed to the customer that were possibly not in
accordance with contract terms. However, we do not believe we face a risk of significant loss from any disallowance of these costs
in excess of amounts withheld from subcontractors. As of December 31, 2012, we had withheld $17 million in payments from
several of our subcontractors pending the resolution of these remaining matters with our customer.

In March 2011, the DOJ filed a counterclaim in the U.S. COFC alleging KBR employees accepted bribes from Tamimi in
exchange for awarding a master agreement for DFAC services to Tamimi. The DOJ seeks disgorgement of all funds paid to KBR
under the master agreement as well as all award fees paid to KBR under the related task orders. Trial in the U.S. COFC took place
during the fourth quarter of 2011. In conjunction with the April 2012 ruling on the Tamimi matter discussed above, the U.S. COFC
issued a judgment in favor of KBR on the common law fraud counterclaim ruling that the fraud allegations brought by the DOJ
were without merit. The DOJ has filed a notice of appeal. Briefing is scheduled to be completed in the first quarter of 2013.

In August 2011, another DFAC subcontractor, Gulf Catering Company, filed for arbitration in the London Court of
International Arbitration to recover $11 million for payments we have withheld from them pending resolution of outstanding Form
1s with our customer. The hearing was held in November 2012 in London and we expect a decision in the second quarter of 2013.
As noted above, we have claims pending in the U.S. COFC to recover these amounts from the U.S. government.

Transportation costs. In 2007, the DCAA raised a question about our compliance with the provisions of the Fly America
Act. During the first quarter of 2011, we received a Form 1 from the DCAA totaling $6 million for alleged violations of the Fly
America Act in 2004. Subject to certain exceptions, the Fly America Act requires Federal employees and others performing U.S.
government-financed foreign air travel to travel by U.S. flag air carriers. There are times when we transported personnel in
connection with our services for the U.S. military where we may not have been in compliance with the Fly America Act and its
interpretations through the Federal Acquisition Regulations and the Comptroller General. Included in our December 31, 2012
and 2011 accompanying balance sheets is an accrued estimate of the cost incurred for these potentially noncompliant flights. The
DCAA may consider additional flights to be noncompliant resulting in potentially larger amounts of disallowed costs than the
amount we have accrued. At this time, we cannot estimate a range of reasonably possible losses that may have been incurred, if
any, in excess of the amount accrued. We will continue to work with our customer to resolve this matter.

In the first quarter of 2011, we received a Form 1 from the DCAA disapproving certain transportation costs totaling $27
million associated with replacing employees who were deployed in Iraq and Afghanistan for less than 179 days. The DCAA claims
these replacement costs violate the terms of the LogCAP III contract which expressly disallow certain costs associated with the
contractor rotation of employees who have deployed less than 179 days including costs for transportation, lodging, meals,
orientation and various forms of per diem allowances. We disagree with the DCAA’s interpretation and application of the contract
terms as it was applied to circumstances outside of our control including sickness, death, termination for cause or resignation and
that such costs should be allowable. We do not believe we face a risk of significant loss from any disallowance of these costs in
excess of the loss accruals we have recorded.

Construction services. From February 2009 through September 2010, we received Form 1s from the DCAA disapproving
$25 million in costs related to work performed under our CONCAP III contract with the U.S. Navy to provide emergency
construction services primarily to government facilities damaged by Hurricanes Katrina and Wilma. The DCAA claims the costs
billed to the U.S. Navy primarily related to subcontract costs that were either inappropriately bid, included unallowable profit
markup or were unreasonable. In February 2012, the Contracting Officer rendered a Contracting Officer Final Determination
(“COFD”) allowing $10 million and disallowing $15 million of direct costs. We filed an appeal with the ASBCA in June 2012. As
of December 31, 2012, the U.S. Navy has withheld $10 million from us. We believe we undertook adequate and reasonable steps to
ensure that proper bidding procedures were followed and the amounts billed to the customer were reasonable and not in violation of
the FAR. As of December 31, 2012, we have accrued our estimate of probable loss related to this matter; however, it is possible we
could incur additional losses.

Investigations, Qui Tams and Litigation

The following matters relate to ongoing litigation or investigations involving U.S. government contracts.

McBride Qui Tam suit. In September 2006, we became aware of a qui tam action filed against us in the U.S. District Court
in the District of Columbia by a former employee alleging various wrongdoings in the form of overbillings to our customer on the
LogCAP III contract. This case was originally filed pending the government’s decision whether or not to participate in the suit. In
June 2006, the government formally declined to participate. The principal allegations are that our compensation for the provision of
Morale, Welfare and Recreation (“MWR”) facilities under LogCAP III is based on the volume of usage of those facilities and that
we deliberately overstated that usage. In accordance with the contract, we charged our customer based on actual cost, not based on
the number of users. It was also alleged that, during the period from November 2004 into mid-December 2004, we continued to bill
the customer for lunches, although the dining facility was closed and not serving lunches. There are also allegations regarding
housing containers and our provision of services to our employees and contractors. On July 5, 2007, the court granted our motion to
dismiss the qui tam claims and to compel arbitration of employment claims including a claim that the plaintiff was unlawfully
discharged. The majority of the plaintiff’s claims were dismissed but the plaintiff was allowed to pursue limited claims pending
discovery and future motions. Substantially all employment claims were sent to arbitration under the Company’s dispute resolution
program and were subsequently resolved in our favor. In January 2009, the Relator filed an amended complaint which is pending a
ruling on a discovery matter before further motions can be filed. On September 17, 2012, the Relator filed an objection to the
Magistrate's ruling, essentially appealing the ruling to the U.S. District Court. The motion remained pending for several years. On
November 19, 2012, the U.S. District Court affirmed and adopted the prior ruling, limiting the Relator's claims to our sites and
dates previously claimed. We are now moving forward to complete the remaining depositions and thereafter file our motion for
summary judgment. No trial date has been set, pending resolution of dispositive motions. We believe the Relator's claim is without
merit and that the likelihood that a loss has been incurred is remote. As of December 31, 2012, no amounts have been accrued.

First Kuwaiti Trading Company arbitration. In April 2008, First Kuwaiti Trading Company ("FKTC" or "First Kuwaiti"),
one of our LogCAP III subcontractors, filed for arbitration of a subcontract under which KBR had leased vehicles related to work
performed on our LogCAP III contract. The FKTC arbitration is conducted under the rules of the London Court on International
Arbitration and the venue is in the District of Columbia. First Kuwaiti alleged that we did not return or pay rent for many of the
vehicles and seeks damages in the amount of $134 million. We filed a counterclaim to recover amounts which may ultimately be
determined due to the government for the $51 million in suspended costs as discussed in the preceding section of this footnote titled
“Containers.” To date, arbitration hearings for four subcontracts have taken place primarily related to claims involving unpaid rents
and damages on lost or unreturned vehicles. The arbitration panel has awarded $16 million to FKTC for claims involving unpaid
rents and damages on lost or unreturned vehicles, repair costs on certain vehicles, damages suffered as a result of late vehicle
returns and interest thereon, net of maintenance, storage and security costs awarded to KBR. In addition, we have stipulated that we
owe FKTC $26 million in connection with five other subcontracts. No payments are expected to occur until all claims are arbitrated
and awards finalized. The final hearing on FKTC's claims was heard before the arbitration panel in January 2013, and there is one
more claim that will be submitted to the arbitration panel for decision without the need for a hearing. We believe any damages
ultimately awarded to First Kuwaiti will be billable under the LogCAP III contract. Accordingly, we have accrued amounts payable
and a related unbilled receivable for the amounts awarded to First Kuwaiti pursuant to the terms of the contract.

Electrocution litigation. During 2008, a lawsuit was filed against KBR in Pittsburgh, PA, in the Allegheny County
Common Pleas Court alleging that the Company was responsible for an electrical incident which resulted in the death of a soldier.
This incident occurred at the Radwaniyah Palace Complex. It is alleged in the suit that the electrocution incident was caused by
improper electrical maintenance or other electrical work. KBR denies that its conduct was the cause of the event and denies legal
responsibility. Plaintiffs are claiming unspecified damages for personal injury, death and loss of consortium by the parents. On
July 13, 2012, the Court granted our motions to dismiss, concluding that the case is barred by the Political Question Doctrine and
preempted by the Combatant Activities Exception to the Federal Tort Claims Act. The plaintiffs filed their notice of appeal with
the Third Circuit Court of Appeals in the Western District of Pennsylvania, and filed their first brief October 12, 2012. We filed
our brief on November 30, 2012. The Appellants filed their reply brief on December 20, 2012. Oral argument is expected in the
first half of 2013.

Burn Pit litigation. From November 2008 through February 2011, KBR was served with over 50 lawsuits in various states
alleging exposure to toxic materials resulting from the operation of burn pits in Iraq or Afghanistan in connection with services
provided by KBR under the LogCAP III contract. Each lawsuit has multiple named plaintiffs collectively representing
approximately 250 individual plaintiffs. The lawsuits primarily allege negligence, willful and wanton conduct, battery, intentional
infliction of emotional harm, personal injury and failure to warn of dangerous and toxic exposures which has resulted in alleged
illnesses for contractors and soldiers living and working in the bases where the pits are operated. The plaintiffs are claiming
unspecified damages. All of the pending cases were removed to Federal Court and have been consolidated for multi-district
litigation treatment before the U.S. Federal District Court in Baltimore, Maryland. In December 2010, the Court stayed virtually all
discovery proceedings pending a decision from the Fourth Circuit Court of Appeals on three other cases involving the Political
Question Doctrine and other jurisdictional issues. In May 2012, the Court denied plaintiffs' request for jurisdictional discovery. In
June 2012, KBR filed a renewed motion to dismiss which was heard in July 2012 and we expect a ruling in the first half of 2013.
Due to the inherent uncertainties of litigation and because the litigation is at a preliminary stage, we cannot at this time accurately
predict the ultimate outcome nor can we reliably estimate a range of possible loss, if any, related to this matter. Accordingly, as of
December 31, 2012, no amounts have been accrued.

Sodium Dichromate litigation. From December 2008 through September 2009, five cases were filed in various Federal
District Courts against KBR by national guardsmen and other military personnel alleging exposure to sodium dichromate at the
Qarmat Ali Water Treatment Plant in Iraq in 2003. After dismissals for lack of jurisdiction, the majority of the cases were re-filed
and consolidated into two cases, with one pending in the U.S. District Court for the Southern District of Texas and one pending in
the U.S. District Court for the District of Oregon. A new, single plaintiff case was filed on November 30, 2012 in the District of
Oregon Eugene Division. Collectively, the suits represent approximately 170 individual plaintiffs all of which are current and
former national guardsmen or British soldiers who claim they were exposed to sodium dichromate while providing security services
or escorting KBR employees who were working at the water treatment plant, claim that the defendants knew or should have known
that the potentially toxic substance existed and posed a health hazard, and claim that the defendants negligently failed to protect the
plaintiffs from exposure. The plaintiffs are claiming unspecified damages. The U.S. Army Corps of Engineers (“USACE”) was
contractually obligated to provide a benign site free of war and environmental hazards before KBR's commencement of work on the
site. KBR notified the USACE within two days after discovering the potential sodium dichromate issue and took effective
measures to remediate the site. KBR services provided to the USACE were under the direction and control of the military and
therefore, KBR believes it has adequate defenses to these claims. KBR also has asserted the Political Question Doctrine and
government contractor defenses. Additionally, the U.S. government and other studies on the effects of exposure to the sodium
dichromate contamination at the water treatment plant have found no long term harm to the soldiers.

On August 16, 2012, the court in the case pending in the U.S. District Court for the Southern District of Texas Court denied
KBR's motion to dismiss plaintiffs' claims. August 29, 2012, the court certified its order for immediate appeal under 28 U.S.C. §
1292(b) to the United States Court of Appeals for the Fifth Circuit, and stayed proceedings in the District Court pending the appeal.
On November 28, 2012, the Fifth Circuit granted KBR permission to appeal, and the appeal is underway.

In the Oregon case, the Court denied KBR's motion to dismiss, and thereafter denied our request to certify the ruling for
immediate appeal to the Ninth Circuit Court of Appeals. On October 9, 2012, the case proceeded to trial on the merits and resulted
in an adverse jury verdict against KBR. On November 2, 2012, a jury in the U.S. District Court for the District of Oregon issued a
verdict in favor of the plaintiffs on their claims, and awarded them approximately $10 million in actual damages and $75 million in
punitive damages. The potential financial impact is unknown until a final judgment is entered by the U.S. District Court for the
District of Oregon, which may differ from the jury verdict. We filed post-verdict motions asking the court to overrule the verdict or
order a new trial. The court has set a hearing for these motions in late February 2013. We have also requested that the court allow
us to appeal many legal issues to the Ninth Circuit Court of Appeals before additional trials are held. Following the final judgment,
our actions may include appealing the decision, seeking to enforce our rights under the Restore Iraqi Oil contract ("RIO contract")
with the U.S. Army, including seeking reimbursement for all incurred costs for which we are entitled pursuant to the contract under
the Federal Acquisition Regulations. The timing of the final judgment and our ensuing actions are unknown at this time, and a jury
verdict is not a final judgment in the case. Therefore, as of December 31, 2012, no amounts have been accrued.

During the period of time since the first litigation was filed against us, we have incurred legal defense costs that we believe
are reimbursable under the related customer contract. We have billed for these costs and we have filed claims to recover the
associated costs incurred to date. On November 16, 2012, we filed a suit against the U.S. government in the U.S. COFC for
denying indemnity in the sodium dichromate cases. The RIO contract required KBR personnel to begin work in Iraq as soon as the
invasion began in March 2003. Due to KBR's inability to procure adequate insurance coverage for this work, the Secretary of the
Army approved the inclusion of an indemnification provision in the RIO Contract pursuant to Public Law 85-804. The claim is for
more than $15 million in legal fees KBR has incurred in defending these cases and for any judgment that is issued against KBR in
the litigation. We are awaiting the government's response. On December 21, 2012, we also sent the USACE RIO Contracting
Officer a certified claim for $23 million in legal costs associated with all of the sodium dichromate cases. If this claim is denied,
the claim will be consolidated with the existing U.S. COFC case.

Convoy Ambush Litigation. In April 2004, a fuel convoy in route from Camp Anaconda to Baghdad International Airport
for the U.S. Army under our LogCAP III contract was ambushed, resulting in deaths and severe injuries to truck drivers hired by
KBR. In 2005, survivors of the drivers killed and those that were injured in the convoy filed suit in state court in Houston, Texas,
against KBR and several of its affiliates, claiming KBR deliberately intended that the drivers in the convoy would be attacked and
wounded or killed. The suit also alleges KBR committed fraud in its hiring practices by failing to disclose the dangers associated
with working in the Iraq combat zone. The case was removed to U.S. Federal District Court in Houston, Texas. After numerous
motions and rulings in the trial court and appeals to U.S. Fifth Circuit Court of Appeals, in January 2012, the appellate Court
granted KBR's appeal on dispositive motions and dismissed the claims of all remaining plaintiffs on the grounds that their claims
are banned by the exclusive remedy provisions of the Defense Base Act. Prior to the dismissal of the claims against KBR by the
appellate Court, KBR settled the claims of one of the plaintiffs. The remaining plaintiffs sought a rehearing of the dismissal by the
Fifth Circuit which was denied in April 2012. We believe the cost of settling with one of the plaintiffs is reimbursable under the
related customer contract. We intend to bill for these costs, and if necessary, file claims with either the U.S. COFC or ASBCA to
recover the associated revenues recognized to date. In July 2012, the plaintiffs filed a petition for a writ of certiorari in the U.S.
Supreme Court. In October 2012, the plaintiffs were denied their petition for a writ of certiorari by the U.S. Supreme Court. We
consider this matter concluded.

DOJ False Claims Act complaint - Private Security. In April 2010, the DOJ filed a complaint in the U.S. District Court in
the District of Columbia alleging certain violations of the False Claims Act related to the use of private security firms. We believed
these sums were properly billed under our contract with the Army and that the use of private security was not prohibited under the
LogCAP III contract. After basic discovery from the DOJ, on November 14, 2012, the U.S. government filed a voluntary Motion to
Dismiss Without Prejudice, seeking Court permission to end this litigation against us. On November 15, 2012, the Court granted
the motion. Because this dismissal was filed without prejudice, the suit could be refiled, although we believe this outcome is highly
unlikely. We consider this matter concluded.

DOJ False Claims Act complaint - Containers. In November 2012, the DOJ filed a complaint in the U.S. District Court for
the Central District of Illinois in Rock Island, IL, related to our settlement of delay claims by our subcontractor, FKTC, in
connection with FKTC's provision of living trailers for the bed down mission in Iraq in 2003-2004. The DOJ alleges that KBR
knew that FKTC had submitted inflated costs; that KBR did not verify the costs; that FKTC had contractually assumed the risk for
the costs which KBR submitted to the government; that KBR concealed information about FKTC's costs from the government; that
KBR claimed that an adequate price analysis had been done when in fact one had not been done; and that KBR submitted false
claims for reimbursement to the government in connection with FKTC's services during the bed down mission. Our contractual
dispute with the Army over this settlement has been ongoing since 2005. We believe these sums were properly billed under our
contract with the Army and are not prohibited under the LogCAP III contract, and we strongly contend that no fraud was
committed. Our responsive pleadings are due March 11, 2013. We intend to seek transfer of the case to the Eastern District of
Virginia, move to dismiss the complaint, and seek as speedy a trial as possible.

Legal Proceedings

Foreign Corrupt Practices Act (“FCPA”) investigations

In February 2009, KBR LLC, entered a guilty plea to violations of the FCPA in the United States District Court, Southern
District of Texas, Houston Division (the “Court”), related to the Bonny Island investigation. The plea agreement reached with the
DOJ resolved all criminal charges in the DOJ’s investigation and called for the payment of a criminal penalty of $402 million, of
which Halliburton was obligated to pay $382 million under the terms of the Master Separation Agreement (“MSA”), while we were
obligated to pay $20 million. In addition, we settled a civil enforcement action by the SEC which called for Halliburton and KBR,
jointly and severally, to make payments totaling $177 million, which was paid by Halliburton pursuant to the indemnification under
the MSA. We also agreed to a period of organizational probation, during which we retained a monitor who assessed our
compliance with the plea agreement and evaluated our FCPA compliance program over a three year period that ended on
February 17, 2012. At the end of the three year period the monitor certified that KBR’s current anti-corruption compliance program
is appropriately designed and implemented to ensure compliance with the FCPA and other applicable anti-corruption laws.

In February 2011, M.W. Kellogg Limited (“MWKL”) reached a settlement with the U.K. Serious Fraud Office (“SFO”) in
which the SFO accepted that MWKL was not party to any unlawful conduct and assessed a civil penalty of approximately $11
million including interest and reimbursement of certain costs of the investigation, which was paid during the first quarter of 2011.
The settlement terms included a full release of all claims against MWKL, its current and former parent companies, subsidiaries and
other related parties including their respective current or former officers, directors and employees with respect to the Bonny Island
project. Due to the indemnity from Halliburton under the MSA, we received approximately $6 million from Halliburton in the
second quarter of 2011.

With the settlement of the DOJ, SEC, SFO and other investigations, all known investigations in the Bonny Island project
have been concluded. We are not aware of any other corruption allegations against us by governmental authorities in foreign
jurisdictions.

Commercial Agent Fees

Prior to separation, it was identified by our former parent in performing its investigation of anti-corruption activities that
certain of these agents may have engaged in activities that were in violation of anti-corruption laws at that time and the terms of
their agent agreements with us. Accordingly, we ceased the receipt of services from and payment of fees to these agents. In
September 2010, we executed a final settlement agreement with one of our agents in question after the agent was reviewed and
approved under our policies on business conduct. Under the terms of the settlement agreement, the agent had, among other things,
confirmed their understanding of and compliance with KBR’s policies on business conduct and represented that they have complied
with anti-corruption laws as they relate to prior services provided to KBR. We negotiated final payment for fees to this agent on
several projects in our Hydrocarbons segment resulting in an overall reduction of estimated project costs of approximately $60
million in 2010. We released the remaining agent fee accruals in 2011 on the Bonny Island project which resulted in an increase of
$4 million to operating income.

Barracuda-Caratinga Project Arbitration

In June 2000, we entered into a contract with BCLC, the project owner and claimant, to develop the Barracuda and
Caratinga crude oilfields, which are located off the coast of Brazil. Petrobras is a contractual representative that controls the project
owner. In November 2007, we executed a settlement agreement with the project owner to settle all outstanding project issues
except for the bolts arbitration discussed below.

At Petrobras’ direction, we replaced certain bolts located on the subsea flowlines that failed through mid-November 2005,
and we understand that additional bolts failed thereafter, which were replaced by Petrobras. These failed bolts were identified by
Petrobras when it conducted inspections of the bolts. In March 2006, Petrobras notified us they submitted this matter to arbitration
claiming $220 million plus interest for the cost of monitoring and replacing the defective stud bolts and, in addition, all of the costs
and expenses of the arbitration including the cost of attorneys’ fees. The arbitration was conducted in New York under the
guidelines of the United Nations Commission on International Trade Law (“UNCITRAL”).

In September 2011, the arbitration panel awarded the claimant approximately $193 million. The damages awarded were
based on the panel’s estimate to replace all subsea bolts, including those that did not manifest breaks, as well as legal and other
costs incurred by the claimant in the arbitration and interest thereon since the date of the award. The panel rejected our argument,
and the case law relied upon by us, that we were only liable for bolts that were discovered to be broken prior to the expiration of the
warranty period that ended on June 30, 2006. As of December 31, 2012, we have a liability of $219 million, including interest, to
Petrobras for the failed bolts which is included in “Other current liabilities.” The liability incurred by us in connection with the
arbitration is covered by an indemnity from our former parent, Halliburton. Accordingly, we have recorded an indemnification
receivable from Halliburton of $219 million pursuant to the indemnification under the master separation agreement which is
included in “Other current assets” as of December 31, 2012. We believe the arbitration award payable to Petrobras will be
deductible for tax purposes when paid and the indemnification payment will be treated by KBR for tax purposes as a contribution to
capital and accordingly is not taxable. In 2011 and 2012, we recorded a discrete tax benefit of $71 million and $8 million,
respectively. At December 31, 2012 the deferred tax balance is $79 million. We have reviewed this matter in light of the direct

payment by Halliburton to BCLC and its public announcement that they have recorded a tax benefit related to this transaction.
Based on advice from outside legal counsel, we have determined that it is more likely than not that we are the proper taxpayer to
recognize this benefit although the underlying uncertainties with respect to the tax treatment of the transaction may ultimately lead
to alternate outcomes. See Note 16 ("Transactions with Former Parent") to our consolidated financial statements for additional
information.

PEMEX Arbitration

In 1997 and 1998, we entered into three contracts with PEMEX, the project owner, to build offshore platforms, pipelines
and related structures in the Bay of Campeche, offshore Mexico. The three contracts were known as Engineering, Procurement and
Construction (“EPC”) 1, EPC 22 and EPC 28. All three projects encountered significant schedule delays and increased costs due to
problems with design work, late delivery and defects in equipment, increases in scope and other changes. PEMEX took possession
of the offshore facilities of EPC 1 in March 2004 after having achieved oil production but prior to our completion of our scope of
work pursuant to the contract.

We filed for arbitration with the International Chamber of Commerce (“ICC”) in 2004 claiming recovery of damages of
approximately $323 million for the EPC 1 project. PEMEX subsequently filed counterclaims totaling $157 million. In December
2009, the ICC ruled in our favor, and we were awarded a total of approximately $351 million including legal and administrative
recovery fees as well as interest. PEMEX was awarded approximately $6 million on counterclaims, plus interest on a portion of
that sum. In connection with this award, we recognized a gain of $117 million net of tax in 2009. The arbitration award is legally
binding and on November 2, 2010, we received a judgment in our favor in the U.S. District Court for the Southern District of New
York to recognize the award in the U.S. of approximately $356 million plus Mexican value added tax and interest thereon until
paid. PEMEX initiated an appeal to the U.S. Court of Appeals for the Second Circuit and asked for a stay of the enforcement of the
judgment while on appeal. The stay was granted, but PEMEX was required to post collateral of $395 million with the court
registry. On February 16, 2012, the Second Circuit issued an order remanding the case to the District Court to consider if the
decision of the Collegiate Court in Mexico, described below, would have affected the trial court’s ruling.

After remand to the trial court, both parties filed briefs and hearings were conducted in May, July and September 2012 at
which time the matter was put on informal stay and KBR was ordered to file suit in Mexican courts in order to determine if such
remedies were, in fact, available. As requested by the trial court in New York, we filed suit in Mexico on November 6, 2012 in the
Tax and Administrative Court. On December 3, 2012, the Mexican Tax and Administrative Court decided not to admit the lawsuit,
and the suit could not proceed. This result indicates that we do not have a remedy in Mexico where we can fully and fairly present
our claims. The District Court was informed of the outcome in the Mexican Tax and Administrative Court. We now have a hearing
set in Federal District Court in New York in April 2013.

Following the Second Circuit's order remanding the case to the District Court, PEMEX filed a motion seeking release of the
collateral posted with the court registry and on January 17, 2013, the District Court granted PEMEX's motion. The District Court
ruled that such bonds are intended to secure judgments until an appeal is final and since a determination is yet to be made on the
mandate from the Second Circuit, there was no longer a justification for holding the collateral. We believe the ICC Award was
proper and enforceable in U.S courts or courts of other countries in which PEMEX has assets. However, an unfavorable ruling by
the U.S trial court or courts in other jurisdictions could have a material adverse impact to our results of operations.

PEMEX attempted to nullify the award in Mexico which was rejected by the Mexican trial court in June 2010. PEMEX then
filed an “amparo” action on the basis that its constitutional rights had been violated which was denied by the Mexican court in
October 2010. PEMEX subsequently appealed the adverse decision with the Collegiate Court in Mexico on the grounds that the
arbitration tribunal did not have jurisdiction and that the award violated the public order of Mexico. Although these arguments
were presented in the initial nullification and amparo action, and were rejected in both cases, in September 2011, the Collegiate
Court in Mexico that PEMEX by unilaterally administratively rescinding the contract in 2004, deprived the arbitration panel of
jurisdiction thereby nullifying the arbitration award. The Collegiate Court ruled that PEMEX, by administratively rescinding the
contract in 2004, deprived the arbitration panel of jurisdiction thereby nullifying the arbitration award. The Collegiate Court's
decision is contrary to the ruling received from the ICC as well as all other Mexican courts which have denied PEMEX’s repeated
attempts to nullify the arbitration award. We also believe the Collegiate Court's decision is contrary to Mexican law governing
contract arbitration. However, we do not expect the Collegiate Court's decision to affect the outcome of the U.S. appeal discussed
above or our ability to ultimately collect the ICC arbitration award in the U.S. due to the significant assets of PEMEX in the U.S.
The circumstances of this matter are unique and in the unlikely event we are not able to collect the arbitration award in the U.S., we
will pursue other remedies including filing a North American Free Trade Agreement (“NAFTA”) arbitration to recover the award as
an unlawful expropriation of assets by the government of Mexico and collection efforts in other jurisdictions.

We have recently instituted collection proceedings in Luxembourg on the ICC award. We have asked for seizure orders on
the assets of PEMEX with a number banks that we believe may have assets subject to seizure. We will pursue our remedies in the
U.S., Luxembourg and any other jurisdiction that we determine have assets which can be used to pay the award.

continued to classify the amount due from PEMEX as a long term receivable included in “Noncurrent unbilled receivable on
uncompleted contracts” as of December 31, 2012. No adjustments have been made to our receivable balance since recognition of
the initial award in 2009. Although we believe we will ultimately collect the award, our failure to do so could result in the write off
of the receivable amount included in "Noncurrent unbilled receivable on uncompleted contracts."

In connection with the EPC 1 project, we have approximately $80 million in outstanding performance bonds furnished to
PEMEX when the project was awarded. The bonds were written by a Mexican bond company and backed by a U.S. insurance
company which is indemnified by KBR. As a result of the ICC arbitration award in December 2009, the panel determined that
KBR had performed on the project, and we believe recovery on the bonds by PEMEX was precluded by the ICC Award. PEMEX
filed an action in Mexico in June 2010 against the Mexican bond company to collect the bonds even though the arbitration award
determined the limited amounts to be paid to PEMEX on their counterclaims. In May 2011, the Mexican trial court ruled PEMEX
could collect the bonds even though PEMEX at the time was unsuccessful in its attempts to nullify the arbitration award. The
decision was immediately appealed by the bonding company, and PEMEX was not able to call the bonds while on appeal. In
October 2011, we were officially notified that the appellate court ruled in favor of PEMEX, therefore allowing PEMEX to call the
bonds. In December 2011, we and the Mexican bond company stayed payment of the bonds by filing a direct amparo action in the
Mexican court, and we filed a bond to cover interest of approximately $23 million accruing during the pendency of our amparo
action. During the third quarter of 2012, the Collegiate Court hearing the amparo action asked the lower court to review the
proceedings. We filed a revision appeal with the Mexican Supreme Court, and in January 2013, this Court denied our amparo
action. As a result of this denial, if PEMEX were to collect the bonds and any accrued interest, the U.S. insurance company would
make payment to the Mexican bonding company. We would then be required to indemnify the U.S. insurance company. In the
event the bonds were called, we would pursue collection of any sums paid in the enforcement action in the U.S. District Court for
the Southern District of New York, the courts of Luxembourg, or by the filing of a NAFTA arbitration to recover the bonds as an
unlawful expropriation of assets by the government of Mexico. We have not recorded any amounts related to the contingent
payment of the performance bonds.

FAO Litigation

In April 2001, our subsidiary, MWKL, entered into lump-sum contracts with Fina Antwerp Olefins ("FAO"), a joint venture
between ExxonMobil and Total, to perform EPC services for FAO’s revamp and expansion of an existing olefins plant in Belgium.
The contracts had an initial value of approximately €113 million. Upon execution of the contracts, MWKL was confronted with a
multitude of changes and issues on the project resulting in significant cost overruns and schedule delays. The project was
completed in October 2003. In 2005, after unsuccessful attempts to engage FAO in negotiations to settle MWKL’s outstanding
claims, MWKL filed suit against FAO in the Commercial Court of Antwerp, Belgium, seeking to recover amounts for rejected
change requests, disruption, schedule delays and other items. MWKL sought the appointment of a court expert to determine the
technical aspects of the disputes between the parties upon which the judge could rely for allocating liability and determining the
final amount of MWKL’s claim against FAO. FAO filed a counterclaim in 2006 claiming recovery of additional costs for various
matters including, among others, project management, temporary offices, security, financing costs, deficient work items and
disruption of activities, some of which we believe is either barred by the language in the contract or has not been adequately
supported. On December 10, 2012, the dispute was settled out of court and FAO paid $39 million to MWKL and agreed to cease
pursuing their counterclaims. We recorded additional revenue of $20 million in 2012 related to the $39 million FAO claim
settlement, of which $19 million was previously recorded. Our portion of job income from the FAO settlement was $14 million.
We have an obligation to our former noncontrolling interest partner of $14 million associated with the settlement received. This
obligation is included in "Other current liabilities" in the December 31, 2012 consolidated balance sheet. We consider this matter
concluded.

Item 7A. Quantitative and Qualitative Discussion about Market Risk

Information relating to market risk is included in “Item 7. Management’s Discussion and Analysis of Financial Condition
and Results of Operations” under the caption “Financial Instruments Market Risk” and Note 14 of our consolidated financial
statements and the information discussed therein is incorporated by reference into this Item 7A.

Item 8. Financial Statements and Supplementary Data

Report of Independent Registered Public Accounting Firm

Consolidated Statements of Income for years ended December 31, 2012, 2011, and 2010

Consolidated Statements of Comprehensive Income for the years ended December 31, 2012, 2011, and 2010

Consolidated Balance Sheets at December 31, 2012 and 2011

Consolidated Statements of Shareholders’ Equity for the years ended December 31, 2012, 2011, and 2010

Consolidated Statements of Cash Flows for the years ended December 31, 2012, 2011, and 2010

Notes to Consolidated Financial Statements

The related financial statement schedules are included under Part IV, Item 15 of this annual report.

Page No.

Report of Independent Registered Public Accounting Firm

The Board of Directors and Stockholders
KBR, Inc.:

We have audited the accompanying consolidated balance sheets of KBR, Inc. and subsidiaries as of December 31, 2012 and 2011,
and the related consolidated statements of income, comprehensive income, shareholders’ equity, and cash flows for each of the
years in the three-year period ended December 31, 2012. These consolidated financial statements are the responsibility of the
Company’s management. Our responsibility is to express an opinion on these consolidated financial statements based on our
audits.

We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States).
Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements
are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in
the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by
management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable
basis for our opinion.

In our opinion, the consolidated financial statements referred to above present fairly, in all material respects, the financial position
of KBR, Inc. and subsidiaries as of December 31, 2012 and 2011, and the results of their operations and their cash flows for each of
the years in the three-year period ended December 31, 2012, in conformity with U.S. generally accepted accounting principles.

We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), KBR,
Inc.’s internal control over financial reporting as of December 31, 2012, based on criteria established in Internal Control -
Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO), and our report
dated February 20, 2013 expressed an unqualified opinion on the effectiveness of the Company’s internal control over financial
reporting.

/s/ KPMG LLP

Houston, Texas
February 20, 2013

KBR, Inc.
Consolidated Statements of Income
(In millions, except for per share data)

Revenue:

Services

Equity in earnings of unconsolidated affiliates, net

Total revenue
Operating costs and expenses:

Cost of services

General and administrative

Impairment of goodwill and long-lived assets

Gain on disposition of assets, net

Total operating costs and expenses

Operating income

Interest expense, net

Foreign currency gains (losses), net

Other non-operating expense

Income before income taxes and noncontrolling interests

Provision for income taxes

Net income

Net income attributable to noncontrolling interests

Net income attributable to KBR

Net income attributable to KBR per share:
Basic

Diluted

Basic weighted average common shares outstanding

Diluted weighted average common shares outstanding

Cash dividends declared per share

Years ended December 31,

2012

2011

2010

7,770

151

7,921

7,252

222

180

(32)

7,622

299

(7)

(2)

288

(86)

202

(58)

9,103
158
9,261

8,463
214
—
(3)

8,674
587
(18)

3
—
572
(32)
540
(60)

144

480

0.97

148

149

0.28

3.18
3.16
150
151
0.20

9,962

137

10,099

9,273

212

—

9,490

609
(17)
(4)
(2)
586
(191)
395
(68)
327

2.08

2.07

156

157

0.15

See accompanying notes to consolidated financial statements.

KBR, Inc.

Consolidated Statements of Comprehensive Income
(In millions)

Net income

Other comprehensive income (loss), net of tax:

Net cumulative translation adjustments (“CTA”):

Cumulative translation adjustments, net of tax

Reclassification adjustment for CTA included in net income

Net cumulative translation adjustment, net of tax of $(8), $(1) and $(3)

Pension liability adjustments, net of tax:

Pension liability adjustments, net of tax

Reclassification adjustment for pension liability losses included in net income

Net pension liability adjustments, net of taxes of $(14), $(32) and $4

Unrealized gains (losses) on derivatives:

Unrealized holding gains (losses) on derivatives, net of tax

Reclassification adjustments for losses included in net income

Net unrealized gain (loss) on derivatives, net of taxes of $1, $(1) and $(1)

Other comprehensive income (loss), net of tax

Comprehensive income

Less: Comprehensive income attributable to noncontrolling interests

Comprehensive income attributable to KBR

Years ended December 31,

2012

2011

2010

202

540

395

(11)

(7)

(18)

(77)

(50)

(62)

140

(58)

(17)

(2)

(19)

(110)

21
(89)

(5)

2
(3)

(111)

429
(59)

370

(2)

(1)

—

424

(72)

352

See accompanying notes to consolidated financial statements.

KBR, Inc.
Consolidated Balance Sheets
(In millions, except share data)

Assets

Current assets:
Cash and equivalents
Receivables:

Accounts receivable, net of allowance for bad debts of $15 and $24
Unbilled receivables on uncompleted contracts

Total receivables
Current deferred income tax asset
Other current assets
Total current assets
Property, plant, and equipment, net of accumulated depreciation of $356 and $364 (including net PPE of
$72 and $75 owned by a variable interest entity – see Note 15)
Goodwill
Intangible assets, net
Equity in and advances to related companies
Noncurrent deferred tax asset
Noncurrent unbilled receivables on uncompleted contracts
Other noncurrent assets
Total assets

Liabilities and Shareholders’ Equity

Current liabilities:
Accounts payable
Due to former parent, net
Advance billings on uncompleted contracts
Reserve for estimated losses on uncompleted contracts
Employee compensation and benefits
Current non-recourse project-finance debt of a variable interest entity (Note 15)
Other current liabilities
Total current liabilities
Noncurrent employee compensation and benefits
Noncurrent non-recourse project-finance debt of a variable interest entity (Note 15)
Other noncurrent liabilities
Noncurrent income tax payable
Noncurrent deferred tax liability
Total liabilities
KBR Shareholders’ equity:
Preferred stock, $0.001 par value, 50,000,000 shares authorized, 0 shares issued and outstanding

Common stock, $0.001 par value, 300,000,000 shares authorized, 173,218,898 and 172,367,045 shares
issued, and 147,584,764 and 148,143,420 shares outstanding

Paid-in capital in excess of par ("PIC")
Accumulated other comprehensive loss ("AOCL")
Retained earnings
Treasury stock, 25,634,134 shares and 24,223,625 shares, at cost
Total KBR shareholders’ equity
Noncontrolling interests ("NCI")
Total shareholders’ equity
Total liabilities and shareholders’ equity

See accompanying notes to consolidated financial statements.

December 31,

2012

2011

1,053

966

1,196
704
1,900
251
464
3,668

390
779
99
217
203
294
117
5,767

756
49
536
56
242
10
628
2,277
511
84
217
90
77
3,256

1,200
454
1,654
297
518
3,435

384
951
113
190
128
313
152
5,666

761
53
618
22
226
10
587
2,277
470
88
177
141
71
3,224

—

—
2,049
(610)
1,709
(606)
2,542
(31)
2,511
5,767

—
2,005
(548)
1,607
(569)
2,495
(53)
2,442
5,666

KBR, Inc.
Consolidated Statements of Shareholders’ Equity
(In millions)

Balance at January 1,

Deferred tax and foreign currency adjustments to PIC

Share-based compensation

Common stock issued upon exercise of stock options

Post-closing adjustment related to acquisition of former NCI partner

Tax benefit increase related to share-based plans

Dividends declared to shareholders

Adjustments pursuant to an agreement with former parent

Repurchases of common stock

Issuance of ESPP shares

Distributions to noncontrolling interests

Investments from noncontrolling interests

Acquisition of noncontrolling interests

Consolidation of Fasttrax Limited

Other noncontrolling interests activity

Comprehensive income

Balance at December 31,

December 31,

2012

2011

2010

2,442

2,204

2,296

—

(42)

—

(40)

(36)

—

140

—

(5)

(30)

—

(118)

(63)

—

(7)

429

2,511

2,442

—

(23)

(8)

(233)

(108)

(181)

(4)

(1)

424

2,204

See accompanying notes to consolidated financial statements.

KBR, Inc.
Consolidated Statements of Cash Flows
(In millions)

Cash flows from operating activities:

Net income

Adjustments to reconcile net income to net cash provided by operating activities:

Years ended December 31,

2012

2011

2010

202

540

395

Depreciation and amortization

Equity in earnings of unconsolidated affiliates

Deferred income tax (benefit) expense

Gain on disposition of assets, net

Impairment of goodwill and long-lived assets

Other

Changes in operating assets and liabilities:

Receivables

Unbilled receivables on uncompleted contracts

Accounts payable

Advance billings on uncompleted contracts

Accrued employee compensation and benefits

Reserve for loss on uncompleted contracts

Collection (repayment) of advances from (to) unconsolidated affiliates, net

Distributions of earnings from unconsolidated affiliates

Other, net

Total cash flows provided by operating activities

Cash flows from investing activities:

Acquisition or disposition of businesses, net of cash acquired

Capital expenditures

Proceeds from sale of assets and investments

(Investment in) / return of capital from equity method joint ventures

Investment in licensing arrangement

Total cash flows provided by (used in) investing activities

Cash flows from financing activities:

Acquisition of noncontrolling interest

Payments to reacquire common stock

Distributions to noncontrolling interests, net

Payments of dividends to shareholders

Net proceeds from issuance of stock

Excess tax benefits from share-based compensation

Payments on short-term and long-term borrowings

Return of cash collateral on letters of credit, net

Total cash flows used in financing activities

Effect of exchange rate changes on cash

Increase (decrease) in cash and equivalents

Cash increase due to consolidation of a variable interest entity

Cash and equivalents at beginning of period

Cash and equivalents at end of period

(151)

(32)

180

(9)

(238)

(14)

(93)

(8)

(6)

108

142

(3)

(75)

127
3
—
52

—
(40)

(36)

(37)

7
4
(14)

—
(116)

9
87
—
966
1,053

(158)

(173)

(3)

—

265

(32)

(110)

(4)

182

(51)

650

—

(83)

(11)

—

(88)

(178)

(118)

(63)

(30)

(15)

(377)

(5)

180

—

786

966

(137)

—

(181)

222

(177)

116

(13)

(16)

127

549

(299)

(66)

—

(12)

(20)

(397)

—

(233)

(91)

(32)

—

(13)

(336)

(177)

941

786

KBR, Inc.
Consolidated Statements of Cash Flows - Continued
(In millions)

Years ended December 31,

2012

2011

2010

Supplemental disclosure of cash flow information:

Cash paid for interest

Cash paid for income taxes (net of refunds)

Noncash operating activities

Other assets change for Barracuda arbitration and FCPA matters (Note 10)

Other liabilities change for Barracuda arbitration and FCPA matters (Note 10) $

(22) $

201

185
(185 ) $

130

(130)

Noncash investing activities

Purchase of computer software

Noncash financing activities

Obligation to former noncontrolling interest partner in MWKL (Note 3)

— $

—

(19)

—

180

See accompanying notes to consolidated financial statements.

KBR, Inc.
Notes to Consolidated Financial Statements

Note 1. Description of Company and Significant Accounting Policies

KBR, Inc., a Delaware corporation, was formed on March 21, 2006. KBR, Inc. and its subsidiaries (collectively, “KBR”) is
a global engineering, construction and services company supporting the energy, hydrocarbons, government services, minerals, civil
infrastructure, power, industrial and commercial markets. Headquartered in Houston, Texas, we offer a wide range of services
through our Hydrocarbons; Infrastructure, Government and Power (“IGP”); Services; and Other business segments. See Note 5 for
additional financial information about our business segments.

Principles of consolidation

Our consolidated financial statements include the financial position, results of operations and cash flows of KBR and our
majority-owned, controlled subsidiaries and variable interest entities where we are the primary beneficiary (see Note 15). The
equity method is used to account for investments in affiliates in which we have the ability to exert significant influence over the
affiliates’ operating and financial policies. The cost method is used when we do not have the ability to exert significant influence.
All intercompany accounts and transactions are eliminated in consolidation.

Use of estimates

The preparation of financial statements in conformity with accounting principles generally accepted in the United States
requires us to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses and related
disclosure of contingent assets and liabilities. We believe the most significant estimates and judgments are associated with revenue
recognition on engineering and construction contracts and government contracts, recognition of estimated losses on uncompleted
contracts, recoverability assessments that must be periodically performed with respect to goodwill and intangible asset balances and
deferred tax assets, estimation of pension obligations, assessment of variable interest entities as well as the determination of
liabilities related to contingencies. If the underlying estimates and assumptions upon which the financial statements are based
change in the future, actual amounts may differ from those included in the accompanying consolidated financial statements.

Certain prior year amounts have been reclassified to conform to current year presentation on the consolidated statement of

comprehensive income, consolidated balance sheets and the consolidated statements of cash flows.

Engineering and construction contracts

Revenue from contracts to provide construction, engineering, design or similar services is reported on the percentage-of-
completion method of accounting. Progress is generally measured based upon man-hours, costs incurred or physical progress,
depending on the type of job. All known or anticipated losses on contracts are provided for in the period they become evident.
Claims and change orders that are in the process of negotiation with customers for additional work or changes in the scope of work
are included in contract value when collection is deemed probable and the value can be reliably estimated. Our contracts often
require us to pay liquidated damages should we not meet certain performance requirements, including completion of the project
within a scheduled time. We generally include an estimate of liquidated damages in contract costs when it is deemed probable that
they will be paid.

Our revenue includes revenue from services provided to our unconsolidated affiliates or joint ventures, the equity in the

earnings of unconsolidated affiliates or joint ventures and gains and losses on disposal of our interest in joint ventures.

Government contracts

Most of the services provided to the United States government are governed by cost-reimbursable contracts. Generally,
these contracts may contain base fees (a fixed profit percentage applied to our actual costs to complete the work), fixed fees and
award fees (a variable profit percentage applied to definitized costs, which is subject to our customer’s discretion and tied to the
specific performance measures defined in the contract, such as adherence to schedule, health and safety, quality of work,
responsiveness, cost performance and business management).

Revenue is recorded at the time services are performed, and such revenues include base fees, actual direct project costs
incurred and an allocation of indirect costs. Indirect costs are applied using rates approved by our government customers. The
general, administrative and overhead cost reimbursement rates are estimated periodically in accordance with government contract
accounting regulations and may change based on actual costs incurred or based upon the volume of work performed. Revenue is
reduced for our estimate of costs that either are in dispute with our customer or have been identified as potentially unallowable
pursuant to the terms of the contract or the federal acquisition regulations.

Accounting for multiple deliverables contracts

For contracts containing multiple deliverables, we analyze each activity within the contract to ensure that we adhere to the
separation guidelines for revenue arrangements with multiple deliverables in accordance with Financial Accounting Standards
Board ("FASB") Accounting Standards Codification (“ASC”) 605 - Revenue Recognition.

Accounting for pre-contract costs

Pre-contract costs incurred in anticipation of a specific contract award are deferred only if the costs can be directly
associated with a specific anticipated contract and their recoverability from that contract is probable. Pre-contract costs related to
unsuccessful bids are written off no later than the period we are informed that we are not awarded the specific contract. Costs
related to one-time activities such as introducing a new product or service, conducting business in a new territory, conducting
business with a new class of customer or commencing new operations are expensed when incurred.

Legal expenses

We expense legal costs in the period in which such costs are incurred.

Cash and equivalents

We consider all highly liquid investments with an original maturity of three months or less to be cash equivalents. Cash and
equivalents include cash related to contracts in progress as well as cash held by our joint ventures that we consolidate for
accounting purposes. Joint venture cash balances are limited to joint venture activities and are not available for other projects,
general cash needs or distribution to us without approval of the board of directors of the respective joint ventures. Cash held by our
joint ventures that we consolidate for accounting purposes totaled approximately $201 million at December 31, 2012 and $244
million at December 31, 2011. We expect to use the cash on these projects to pay project costs.

Restricted cash primarily consists of amounts held in deposit with certain banks to collateralize standby letters of credit as
well as amounts held in deposit with certain banks to establish foreign operations. Our restricted cash is included in “Other current
assets” and “Other assets” on our consolidated financial statements. Our restricted cash balances were $2 million at December 31,
2012 and $5 million at December 31, 2011.

Allowance for bad debts

We establish an allowance for bad debts through a review of several factors including historical collection experience,

current aging status of the customer accounts, financial condition of our customers and whether the receivables involve retentions.

Goodwill and other intangibles

Goodwill represents the excess of cost over the fair market value of net assets acquired in business combinations and, in
accordance with ASC 350 Intangibles - Goodwill and Other, we are required to test goodwill for impairment on an annual basis,
and more frequently when negative conditions or other triggering events arise. We test goodwill for impairment annually as of
October 1. Our operations are grouped into four segments: Hydrocarbons, IGP, Services and Other. Within those segments we
operate 11 business units which are also our operating segments as defined by ASC 280 - Segment Reporting and are reporting
units as defined by ASC 350. In accordance with ASC 350, we conduct our goodwill impairment testing at the reporting unit level
which consists of the 11 business and reporting units and our Allstates reporting unit. The reporting units include Gas
Monetization, Oil & Gas, Downstream, Technology, North American Government & Logistics ("NAGL"), International
Government, Defence and Support Services ("IGDSS"), Power & Industrial ("P&I"), Infrastructure, Minerals, Services, Ventures
and the Allstates staffing business.

Our October 1, 2012 annual impairment test for goodwill was a quantitative analysis using a two-step process that involves
comparing the estimated fair value of each reporting unit to its carrying value, including goodwill. If the fair value of a reporting
unit exceeds its carrying value, the goodwill of the reporting unit is not considered impaired; therefore, the second step of the
impairment test is unnecessary. If the carrying value of a reporting unit exceeds its fair value, we perform the second step of the
goodwill impairment test to measure the amount of goodwill impairment loss to be recorded, as necessary. The second step
compares the implied fair value of the reporting unit's goodwill to the carrying value of that goodwill. We determine the implied
fair value of the goodwill in the same manner as determining the amount of goodwill to be recognized in a business combination.
See Note 6 regarding our interim and annual impairment tests.

Consistent with prior years, the fair values of reporting units in 2012 were determined using a combination of two methods,
one utilizing market earnings multiples of peer companies identified for each reporting unit (the market approach), and the other
derived from discounted cash flow models with estimated cash flows based on internal forecasts of revenues and expenses over a
ten year period plus a terminal value (the income approach).

The market approach estimates fair value by applying earnings and revenue market multiples to a reporting unit’s operating
performance for the trailing twelve-month period. The income approach estimates fair value by discounting each reporting unit’s
estimated future cash flows using a weighted-average cost of capital that reflects current market conditions and the risk profile of
the reporting unit. To arrive at our future cash flows, we use estimates of economic and market assumptions, including growth rates
in revenues, costs, estimates of future expected changes in operating margins, tax rates and cash expenditures. We believe these
two approaches are appropriate valuation techniques and we generally weight the two resulting values equally as an estimate of a
reporting unit's fair value for the purposes of our impairment testing. However, we may weigh one value more heavily than the
other when conditions merit doing so. Other significant estimates and assumptions include terminal value growth rates, future
estimates of capital expenditures and changes in future working capital requirements. The fair value derived from the weighting of
these two methods provides appropriate valuations that, in the aggregate, reasonably reconcile to our market capitalization, taking
into account observable control premiums.

Given our use of judgments and estimates in the performance of our goodwill impairment test, if market conditions change
compared to those used in our market approach, or if actual future results of operations fall below the projections used in the
income approach, our goodwill could become impaired in the future.

Impairment of long-lived assets

When events or changes in circumstances indicate that long-lived assets other than goodwill may be impaired, an evaluation
is performed to determine if the asset is impaired and to measure the amount of the impairment, if necessary. For an asset classified
as held for use, the estimated future undiscounted cash flow associated with the asset is compared to the asset’s carrying amount to
determine if a write-down to fair value is required. When an asset is classified as held for sale, we cease depreciation or
amortization and adjust the asset’s book value to the lower of its carrying amount or fair value less cost to sell.

We evaluate equity method investments for impairment when events or changes in circumstances indicate that the carrying
value of such investments may have experienced an other-than-temporary decline in value. When evidence of loss in value has
occurred, we compare the estimated fair value of the investment to its carrying value to determine whether an impairment has
occurred. We assess the fair value of our equity method investments using commonly accepted techniques, and may use more than
one method, including, but not limited to, recent third party comparable sales, internally developed discounted cash flow analysis
and analysis from outside advisors. If the estimated fair value is less than the carrying value and we consider the decline in value to
be other than temporary, the excess of the carrying value over the estimated fair value is recognized in the financial statements as an
impairment.

Pensions

Our pension benefit obligations and expenses are calculated using actuarial models and methods, in accordance with ASC
715 - Compensation - Retirement Benefits. Two of the more critical assumptions and estimates used in the actuarial calculations are
the discount rate for determining the current value of benefit obligations and the expected rate of return on plan assets. Other
assumptions and estimates used in determining benefit obligations and plan expenses include demographic factors such as
retirement age and mortality, which are evaluated periodically and updated accordingly to reflect our actual experience.

The actuarial assumptions used in determining our pension benefits may differ materially from actual results due to
changing market and economic conditions, higher or lower withdrawal rates and longer or shorter life spans of participants. While
we believe that the assumptions used are appropriate, differences in actual experience or changes in assumptions may materially
affect our financial position or results of operations. Our actuarial estimates of pension benefit expense and expected pension
returns of plan assets are discussed further in Note 17 in the accompanying financial statements.

Income taxes

Deferred tax assets and liabilities are recognized for the expected future tax consequences of events that have been
recognized in the financial statements or tax returns. A current tax asset or liability is recognized for the estimated taxes refundable
or payable on tax returns for the current year. A deferred tax asset or liability is recognized for the estimated future tax effects
attributable to temporary differences between the financial reporting basis and the income tax basis of assets and liabilities. The
measurement of current and deferred tax assets and liabilities is based on provisions of the enacted tax law, and the effects of
potential future changes in tax laws or rates are not considered until enacted.

of deferred tax liabilities, projected future taxable income and available tax planning strategies in making this assessment.
Additionally, we use forecasts of certain tax elements such as taxable income and foreign tax credit utilization in making this
assessment of realization. Given the inherent uncertainty involved with the use of such assumptions, there can be significant
variation between anticipated and actual results.

We have operations in numerous countries other than the United States. Consequently, we are subject to the jurisdiction of
a significant number of taxing authorities. The income earned in these various jurisdictions is taxed on differing bases, including
income actually earned, income deemed earned and revenue-based tax withholding. The final determination of our tax liabilities
involves the interpretation of local tax laws, tax treaties and related authorities in each jurisdiction. Changes in the operating
environment, including changes in tax law and currency/repatriation controls, could impact the determination of our tax liabilities
for a tax year.

Income tax positions must meet a more-likely-than-not recognition threshold to be recognized. Income tax positions that
previously failed to meet the more-likely-than-not threshold are recognized in the financial reporting period in which that threshold
is met. Previously recognized tax positions that no longer meet the more-likely-than-not threshold are derecognized in the financial
reporting period in which that threshold is no longer met. The company recognizes potential interest and penalties related to
unrecognized tax benefits in income tax expense.

Tax filings of our subsidiaries, unconsolidated affiliates and related entities are routinely examined by tax authorities in the
normal course of business. These examinations may result in assessments of additional taxes, which we work to resolve with the
tax authorities and through the judicial process. Predicting the outcome of disputed assessments involves some uncertainty.
Factors such as the availability of settlement procedures, willingness of tax authorities to negotiate and the operation and
impartiality of judicial systems vary across the different tax jurisdictions and may significantly influence the ultimate outcome. We
review the facts for each assessment, and then utilize assumptions and estimates to determine the most likely outcome and provide
taxes, interest and penalties as needed based on this outcome.

Derivative instruments

At times, we enter into derivative financial transactions to hedge existing or projected exposures to changing foreign
currency exchange rates. We do not enter into derivative transactions for speculative or trading purposes. We recognize all
derivatives at fair value on the balance sheet. Derivatives that are not accounted for as hedges under ASC 815 - Derivatives and
Hedging, are adjusted to fair value and such changes are reflected through the results of operations. If the derivative is designated
as a hedge, depending on the nature of the hedge, changes in the fair value of derivatives are either offset against the change in fair
value of the hedged assets, liabilities or firm commitments through earnings or recognized in other comprehensive income until the
hedged item is recognized in earnings.

The ineffective portion of a derivative’s change in fair value is recognized in earnings. Recognized gains or losses on
derivatives entered into to manage foreign exchange risk are included in foreign currency gains and losses in the consolidated
statements of income.

Concentration of credit risk

We have revenues and receivables from transactions with individual external customers that amount to 10% or more of our
revenues. A significant percentage of service revenue is generated from transactions with Chevron Corporation (“Chevron”), which
is derived primarily from our Hydrocarbons segment, and from transactions with the United States government, which is derived
from our IGP segment. No other customers represented 10% or more of consolidated revenues in any of the periods presented. In
addition, our receivables are generally not collateralized. The following tables present summarized data related to our transactions
with Chevron and the U.S. government.

Revenues from major customers:

Millions of dollars

Chevron revenue

U.S. government revenue

Percentages of revenues and accounts receivable from major customers:

Millions of dollars, except percentage amounts

Chevron revenues percentage

U.S. government revenue percentage

Chevron receivables percentage

U.S. government receivables percentage

Noncontrolling interest

Years ended December 31,

2012

2011

2010

2,302
690

2,047

2,219

1,783

3,277

Years ended December 31,

2012

2011

2010

29%

10%

22%

24%

26%

18%

32%

11%

33%

Noncontrolling interest in consolidated subsidiaries in our consolidated balance sheets principally represents noncontrolling
shareholders’ proportionate share of the equity in our consolidated subsidiaries. Noncontrolling interest in consolidated subsidiaries
is adjusted each period to reflect the noncontrolling shareholders’ allocation of income or the absorption of losses by noncontrolling
shareholders on certain majority-owned, controlled investments.

Foreign currency translation

We determine the functional currency of our foreign entities based upon the currency of the primary environment in which
they operate. Where the functional currency is not the U.S. dollar, translation of assets and liabilities to U.S. dollars is based on
exchange rates at the balance sheet date. Translation of revenue and expenses to U.S. dollars is based on the average rate during the
period. Translation gains or losses, net of income tax effects, are reported as a component of accumulated other comprehensive
loss. Gains or losses from foreign currency transactions are included in results of operations, with the exception of intercompany
foreign transactions that are of a long-term investment nature, which are recorded in “Other comprehensive income” on our
consolidated balance sheets.

Variable Interest Entities

The majority of our joint ventures are variable interest entities ("VIEs"). We account for VIEs in accordance with ASC 810 -
Consolidation which requires the consolidation of VIEs in which a company has both the power to direct the activities of the VIE
that most significantly impact the VIE’s economic performance and the obligation to absorb losses or the right to receive the
benefits from the VIE that could potentially be significant to the VIE. If a reporting enterprise meets these conditions, then it has a
controlling financial interest and is the primary beneficiary of the VIE. An unconsolidated VIE is accounted for under the equity
method of accounting.

We assess all newly created entities and those with which we become involved to determine whether such entities are VIEs
and, if so, whether or not we are their primary beneficiary. Most of the entities we assess are incorporated or unincorporated joint
ventures formed by us and our partner(s) for the purpose of executing a project or program for a customer and are generally
dissolved upon completion of the project or program. Many of our long-term energy-related construction projects in our
Hydrocarbons business group are executed through such joint ventures. Typically, these joint ventures are funded by advances
from the project owner, and accordingly, require little or no equity investment by the joint venture partners but may require
subordinated financial support from the joint venture partners such as letters of credit, performance and financial guarantees or
obligations to fund losses incurred by the joint venture. Other joint ventures, such as privately financed initiatives in our Ventures
business unit, generally require the partners to invest equity and take an ownership position in an entity that manages and operates
an asset post construction.

As required by ASC 810-10, we perform a qualitative assessment to determine whether we are the primary beneficiary once
an entity is identified as a VIE. Thereafter, we continue to re-evaluate whether we are the primary beneficiary of the VIE in
accordance with ASC 810-10. A qualitative assessment begins with an understanding of the nature of the risks in the entity as well
as the nature of the entity’s activities including terms of the contracts entered into by the entity, ownership interests issued by the
entity and how they were marketed and the parties involved in the design of the entity. We then identify all of the variable interests
held by parties involved with the VIE including, among other things, equity investments, subordinated debt financing, letters of
credit, financial and performance guarantees and contracted service providers. Once we identify the variable interests, we
determine those activities which are most significant to the economic performance of the entity and which variable interest holder
has the power to direct those activities. Though infrequent, some of our assessments reveal no primary beneficiary because the
power to direct the most significant activities that impact the economic performance is held equally by two or more variable interest
holders who are required to provide their consent prior to the execution of their decisions. Most of the VIEs with which we are
involved have relatively few variable interests and are primarily related to our equity investment, significant service contracts and
other subordinated financial support.

Share-based compensation

We apply the fair value recognition provisions of ASC 718-10 for share-based payments to account for and report equity-
based compensation. ASC 718-10 requires equity-based compensation expense to be measured based on the grant-date fair value of
the award. For performance-based awards, compensation expense is measured based on the grant-date fair value of the award and
the fair value of that award is remeasured subsequently at each reporting date through the settlement date. Changes in fair value
during the requisite service period or the vesting period are recognized as compensation cost on a straight line basis over that
period. See Note 13 for detailed information on share-based compensation and incentive plans.

Additional Balance Sheet Information

Included in “Other current assets” on our consolidated balance sheets are “Advances to subcontractors” and included in
“Other current liabilities” on our consolidated balance sheets are "Income taxes payable" and “Retainage payables to
subcontractors.” Our “Advances to subcontractors”, "Income taxes payable" and “Retainage payables to subcontractors” for the
years ended December 31, 2012 and 2011 are presented below:

Millions of dollars

Advances to subcontractors

Income taxes payable

Retainage payables to subcontractors

Note 2. Income per Share

December 31,

2012

2011

37
116
136

167

202

Basic income per share is based upon the weighted average number of common shares outstanding during the period.
Dilutive income per share includes additional common shares that would have been outstanding if potential common shares with a
dilutive effect had been issued using the treasury stock method. A reconciliation of the number of shares used for the basic and
diluted income per share calculations is as follows:

Millions of Shares

Basic weighted average common shares outstanding

Stock options and restricted shares

Diluted weighted average common shares outstanding

Years ended December 31,

2012

2011

2010

148

149

150
1
151

156

157

For purposes of applying the two-class method in computing earnings per share, net earnings allocated to participating
securities was approximately $1 million, a negligible amount per share, for the fiscal year 2012, $2 million, or $0.02 per share, for
fiscal year 2011 and $2 million, or $0.01 per share, for fiscal year 2010. The diluted earnings per share calculation did not include
1.3 million, 0.5 million and 1.1 million antidilutive weighted average shares for the years ended December 31, 2012, 2011 and
2010, respectively.

Note 3. Business Combinations and Other Transactions

Business Combinations

ENI Holdings, Inc.(the “Roberts & Schaefer Company”). On December 21, 2010, we completed the acquisition of 100%
of the outstanding common shares of ENI Holdings, Inc. (“ENI”). ENI is the parent to the Roberts & Schaefer Company (“R&S”),
a privately held EPC services company for material handling and processing systems. Headquartered in Chicago, Illinois, R&S
provides services and associated processing infrastructure to customers in the mining and minerals, power, industrial, refining,
aggregates, precious and base metals industries. R&S and its acquired divisions have been integrated into our Minerals reporting
unit.

The purchase price was $280 million plus estimated working capital of $17 million which included cash acquired of $8
million. The total net cash paid at closing of $289 million is subject to an escrowed holdback. As of December 31, 2012, the
remaining escrowed holdback was $25 million and primarily related to security for indemnification obligations. On December 6,
2012, ENI Holdings, LLC filed a lawsuit in Delaware Chancery Court alleging KBR is wrongfully withholding the escrowed
holdback. On January 25, 2013, we filed an answer denying the wrongful withholding allegation. In addition we filed a
counterclaim for indemnity and fraud under the terms of the Stock Purchase Agreement.

The acquisition generated goodwill of approximately $250 million, which is not deductible for income tax purposes.
Goodwill was recognized primarily as a result of acquiring an assembled workforce, expertise and capabilities in the material
handling and processing systems market, cost saving opportunities and other synergies. During 2011, we recorded an increase to
goodwill of approximately $4 million primarily associated with additional purchase consideration payable to the seller, based upon
our estimates of post-closing working capital adjustments and final valuation of acquired intangible assets. In the third quarter of
2012, during the course of our annual strategic planning process, we determined that both the actual and expected income and cash
flows for our Minerals reporting unit were substantially lower than previous forecasts due to lower than expected project bookings
and losses from ongoing projects acquired as part of the acquisition of R&S. We also identified a deterioration in economic
conditions in the minerals markets and less than expected actual and projected income and cash flows for the Minerals reporting
unit, which reduced forecasts of the sales, operating income and cash flows expected in 2013 and beyond. As a result of these
triggering events, we performed an interim goodwill impairment test on our Minerals reporting unit. As a result of our interim
goodwill impairment test, we recorded a noncash goodwill impairment charge in our Minerals reporting unit for $178 million. See
Note 6 for details regarding the impairment of our Minerals reporting unit.

Of the total purchase price on this acquisition, $56 million was allocated to customer relationships, trade names and other
intangibles. Customer relationships represent existing contracts and the underlying customer relationships and backlog are
amortized on a straight-line basis over the period in which the economic benefits are expected to be realized. Tradename
intangibles include the Roberts & Schaefer and Soros brands which are amortized on a straight-lined basis over an estimated useful
life of 8 - 10 years.

Other Transactions

M.W. Kellogg Limited (“MWKL”). On December 31, 2010, we obtained control of the remaining 44.94% interest in our
MWKL subsidiary located in the U.K for approximately £107 million subject to certain post-closing adjustments. The acquisition
was recorded as an equity transaction that reduced noncontrolling interests, accumulated other comprehensive income and
additional paid-in capital by $180 million. We recognized direct transaction costs associated with the acquisition of approximately
$1 million as a direct charge to additional paid in capital. The initial purchase price of $164 million was paid on January 5, 2011.
During the third quarter of 2011, we settled various post-closing adjustments that resulted in a decrease to “Paid-in capital in excess
of par” of approximately $5 million. We also agreed to pay the former noncontrolling interest 44.94% of future proceeds collected
on certain receivables owed to MWKL and the former noncontrolling interest agreed to indemnify us for 44.94% of certain MWKL
liabilities to be settled and paid in the future. As of December 31, 2012, we have liabilities of approximately $14 million classified
on our consolidated balance sheet as “Other current liabilities” reflecting our accrual of 44.94% of proceeds from certain
receivables owed to the former noncontrolling interest partner in MWKL. See Note 10 for additional information about obligations
due to the former noncontrolling interest partner in MWKL.

LNG Joint Venture. On January 5, 2011, we sold our 50% interest in a joint venture to our joint venture partner for
approximately $22 million. The joint venture was formed to execute an EPC contract for construction of an LNG plant in
Indonesia. We recognized a gain on the sale of our interest of approximately $8 million which is included in “Equity in earnings of
unconsolidated affiliates, net” in our consolidated income statement.

Note 4. Percentage-of-Completion Contracts

Revenue from contracts to provide construction, engineering, design or similar services is reported on the percentage-of-
completion method of accounting using measurements of progress toward completion appropriate for the work performed.
Commonly used measurements are costs incurred, man-hours and physical progress.

Billing practices for these projects are governed by the contract terms of each project based upon costs incurred,
achievement of milestones or pre-agreed schedules. Billings do not necessarily correlate with revenue recognized using the
percentage-of-completion method of accounting. Billings in excess of recognized revenue are recorded in “Advance billings on
uncompleted contracts.” When billings are less than recognized revenue, the difference is recorded in “Unbilled receivables on
uncompleted contracts.” With the exception of claims and change orders that we are in the process of negotiating with customers,
unbilled receivables are usually billed during normal billing processes following achievement of the contractual requirements.

Recording of profits and losses on percentage-of-completion contracts requires an estimate of the total profit or loss over the
life of each contract. This estimate requires consideration of contract value, change orders and claims reduced by costs incurred
and estimated costs to complete. Anticipated losses on contracts are recorded in full in the period they become evident. We
generally do not delay income recognition until projects have reached a specified percentage of completion. Generally, profits are
recorded from the commencement date of the contract based upon the total estimated contract profit multiplied by the current
percentage complete for the contract.

Unapproved change orders and claims

When calculating the amount of total profit or loss on a long-term contract, we include unapproved change orders and
claims in contract value only when it is probable that they will result in additional revenue and the amount can be reliably
estimated. Including unapproved change orders and claims in this calculation increases the operating income (or reduces the
operating loss) that would otherwise be recorded without consideration of these items.

When recording the revenue and the associated unbilled receivable for claims and unapproved change orders, we only
accrue an amount equal to the costs incurred and include no profit element. The amounts of unapproved change orders and claims
included in determining the profit or loss on contracts and recorded in current and noncurrent unbilled receivables on uncompleted
contracts are as follows:

Millions of dollars

Claims

Unapproved change orders

December 31,

2012

2011

126

As of December 31, 2012, claims and unapproved change orders related to several projects. Included in the table above are
claims associated with the reimbursable portion of an EPC contract to construct an LNG facility for which we have recognized
additional contract revenue totaling $107 million. The claims on this project represent incremental subcontractor costs that we are
legally entitled to recover from the customer under the terms of the EPC contract. See Note 9 for a discussion of U.S. government
claims, which are not included in the table above.

For our unconsolidated subsidiaries, our share of claims and unapproved change orders was $3 million and $43 million,

respectively, as of December 31, 2012.

Liquidated damages

Many of our engineering and construction contracts have milestone due dates that if not met could subject us to penalties for
liquidated damages if claims are asserted and we were responsible for the delays. These generally relate to specified activities that
must be completed within a project by a set contractual date or achievement of a specified level of output or throughput of a plant
we construct. Each contract defines the conditions under which a customer may make a claim for liquidated damages. However, in
some instances, liquidated damages are not asserted by the customer, but the potential to do so is used in negotiating claims and
closing out the contract.

Note 5. Business Segment Information

We provide a wide range of services and the management of our business is heavily focused on major projects within each
of our reportable segments. At any given time, a relatively few number of projects and joint ventures represent a substantial part of
our operations. Our equity in earnings and losses of unconsolidated affiliates that are accounted for using the equity method of
accounting is included in revenue of the applicable segment.

The following is a description of our reportable segments:

Hydrocarbons. Our Hydrocarbons business segment provides services ranging from prefeasibility studies to designing
through construction and commissioning of process facilities in remote locations and developed areas around the world. We are
involved in hydrocarbon processing which includes constructing liquefied natural gas (“LNG”) plants in several countries. Our
global teams of engineers also provide process technology and project delivery for projects in the biofuel, carbon capture, oil and
gas, olefins and petrochemical markets. The Hydrocarbons business segment includes the Gas Monetization, Oil & Gas,
Downstream and Technology business units.

Our Gas Monetization business unit designs and constructs facilities that enable our customers to monetize their natural gas
resources. We design and build LNG and gas-to-liquids (“GTL”) facilities that allow for the economical development and
transportation of resources from locations across the globe. Additionally, we make significant contributions in advancing gas
processing development, equipment design and innovative construction methods. Our Oil & Gas business unit delivers onshore and
offshore oil and natural gas production facilities which include platforms, floating production and subsea facilities and pipelines.
We also provide specialty consulting services which include field development studies and planning, structural integrity
management and proprietary designs for ship and semi-submersible hulls. Our Downstream business unit provides a complete
range of engineering, procurement, construction and construction services (“EPC-CS”) services, as well as program and project
management, consulting, front-end engineering and design (“FEED”) for refineries, petrochemical and other plants. Our
Technology business unit provides expertise related to differentiated process technologies for the coal monetization, petrochemical,
refining and syngas markets.

Infrastructure, Government & Power. Our IGP business segment serves the Infrastructure, Government & Power
industries delivering effective solutions to defense and governmental agencies worldwide, providing base operations, facilities
management, border security, engineering, procurement and construction (“EPC”) services and logistics support. We also provide
project management, construction management, design and support services for an array of complex infrastructure initiatives
including aviation, road, rail, maritime, water, wastewater, building and pipeline projects. For the industrial manufacturing and
process markets, we provide a full range of EPC services to a variety of heavy industrial and advanced manufacturing markets,
frequently employing our clients’ proprietary knowledge and technologies in strategically critical projects. For the power market,
we use our full-scope EPC expertise to execute projects which play a distinctive role in increasing the world’s power generation
capacity from multiple fuel sources and in enhancing the efficiency and environmental compliance of existing power facilities. The
IGP business segment includes NAGL, IGDSS, Infrastructure, Minerals and the P&I business units.

Services. Our Services segment delivers full-scope construction, construction management, fabrication, operations/
maintenance, commissioning/startup and turnaround expertise to customers worldwide in a variety of markets including oil and gas,
petrochemicals and hydrocarbon processing, power, alternate energy, pulp and paper, industrial and manufacturing and consumer
product industries. Specifically, Services is organized around four major product lines: U.S. Construction, Industrial Services,
Building Group and Canada. Our U.S. Construction product line delivers direct hire construction, construction management for
construction only projects to a variety of markets and works closely with the Hydrocarbons group, Minerals and P&I business units
to provide construction execution support on all domestic EPC projects. Our Industrial Services product line is a diversified
maintenance organization operating on a global basis providing maintenance, on-call construction, turnaround and specialty
services to a variety of markets. This product line works with all of our other operating units to identify potential for pull through
opportunities and to identify upcoming EPC projects at one of the 90 plus locations where we have embedded KBR personnel. Our
Building Group product line provides general commercial contractor services to education, food and beverage, manufacturing,
health care, hospitality and entertainment, life science and technology and mixed-use building clients. Our Canada product line is a
diversified construction and fabrication operation providing direct hire construction, module assembly, fabrication and maintenance
services to our Canadian customers. This product line serves a number of markets including oil and gas customers operating in the
oil sands, pulp and paper, mining and industrial markets.

Certain of our business units meet the definition of operating segments contained in ASC 280 - Segment Reporting, but
individually do not meet the quantitative thresholds as a reportable segment, nor do they share a majority of the aggregation criteria
with another operating segment. These operating segments are reported on a combined basis as “Other” and include our Ventures
and Allstates business units as well as corporate expenses not included in the operating segments’ results. Our segment information
has been prepared in accordance with ASC 280 - Segment Reporting.

Our reportable segments follow the same accounting policies as those described in Note 1 (Significant Accounting Policies).
Our equity in pretax earnings and losses of unconsolidated affiliates that are accounted for using the equity method of accounting is
included in revenue and operating income of the applicable segment.

Reportable segment performance is evaluated by our chief operating decision maker using operating segment income which
is defined as operating segment revenue less the cost of services and segment overhead directly attributable to the operating
segment. Reportable segment income excludes certain cost of services and general and administrative expenses directly attributable
to the operating segment that is managed and reported at the corporate level and corporate general and administrative expenses. We
believe this is the most accurate measure of the ongoing profitability of our operating segments.

Labor cost absorption in the following table represents income or expense generated by our central service labor and
resource groups for amounts charged to the operating segments. Additionally in the following table, depreciation and amortization
associated with corporate assets are allocated to our operating segments for determining operating income or loss.

The tables below present information on our reportable segments.

Operations by Reportable Segment

Millions of dollars
Revenue:

Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total revenue

Segment operating income (loss):
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Segment operating income

Unallocated amounts:

Labor cost absorption income (expense)

Corporate general and administrative expense

Total operating income

Capital Expenditures:
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total

Equity in earnings of unconsolidated affiliates, net:
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total

Depreciation and amortization:
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total

Years ended December 31,

2012

2011

2010

4,300

3,969

4,299

1,755

10,099

4,258
3,328
1,590
85
9,261

408
266
58
51
783

1,904

1,633

7,921

601

(104)

(16)

556

(35)

(222)

400

272

102

809

(212)

609

137

18
(214)

299

587

151

—
3
3
77
83

32
67
26
33
158

2
14
9
46
71

Within KBR, not all assets are associated with specific segments. Those assets specific to segments include receivables,
inventories, certain identified property, plant and equipment and equity in and advances to related companies and goodwill. The
remaining assets, such as cash and the remaining property, plant and equipment, are considered to be shared among the segments
and are therefore reported in "Other."

Balance Sheet Information by Reportable Segment

Millions of dollars
Total assets:

Hydrocarbons

Infrastructure, Government and Power

Services

Other (a)

Total assets

Goodwill:
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total

Equity in/advances to related companies:
Hydrocarbons

Infrastructure, Government and Power

Services

Other

Total

(a) Includes intercompany obligations.

December 31,

2012

2011

3,311 $
2,551
1,020
(1,115)
5,767 $

2,836

2,827

604

(601)

5,666

255 $
225
287
12
779 $

39 $
(76)
54
200
217 $

249

403

287

951

(51)

196

190

Revenue by country is determined based on the location of services provided. Long-lived assets by country are determined

based on the location of tangible assets.

Selected Geographic Information

Millions of dollars
Revenue:

United States

Asia Pacific (includes Australia)

Africa

Europe

Other Middle East

Iraq

Canada

Other Countries

Total

Millions of dollars
Property, Plant & Equipment:

United States

United Kingdom

Other Countries

Total

Years ended December 31,

2012

2011

2010

2,127
1,940
1,625
648
571
445
431
134
7,921

1,994

1,439

2,113

587

707

1,969

299

153

2,082

1,030

2,094

585

995

2,891

310

112

9,261

10,099

December 31,

2012

2011

238

390

225

384

Note 6. Goodwill and Intangible Assets

Goodwill

The table below summarizes our goodwill by segment.

Millions of dollars

Hydrocarbons

IGP

Services

Other

Total

Balance at December 31, 2010

249

399

287

R&S purchase price adjustment

Balance at December 31, 2011

Other additions

Impairment of Minerals

—

249

—

Balance at December 31, 2012

255

403

—

(178)

225

—

287

—

287

12
—
12
—
—
12

947

951

(178)

779

Goodwill Impairment Review

We perform our annual goodwill impairment test as of October 1 of each year and also perform interim impairment reviews
if events occur or circumstances change that indicate it is likely that the fair value of a reporting unit is below its carrying value. In
the third quarter of 2012, during the course of our annual strategic planning process, we determined that both the actual and
expected income and cash flows for our Minerals reporting unit were substantially lower than previous forecasts due to losses from
ongoing projects acquired as part of the acquisition of R&S. We also identified a deterioration in economic conditions in the
minerals markets and less than expected actual and projected income and cash flows for the Minerals reporting unit, which reduced
forecasts of the sales, operating income and cash flows expected in 2013 and beyond. As a result of these triggering events, we
performed an interim goodwill impairment test on our Minerals reporting unit during the third quarter of 2012.

The first step in performing a goodwill impairment test is to identify potential impairment by comparing the estimated fair
value of the reporting unit to its carrying value. The result of the first step of our goodwill impairment test indicated the carrying
value of our Minerals reporting unit exceeded its fair value. Therefore, we performed the second step of the goodwill impairment
test in order to measure the amount of the potential impairment loss. The second step of the goodwill impairment test compares the
implied fair value of the reporting unit's goodwill to the carrying value of that goodwill. We determine the implied fair value of
goodwill in the same manner as we use in determining the amount of goodwill to be recognized in a business combination.
Applying this methodology, we assigned the fair value of the Minerals reporting unit estimated in step one to all the assets and
liabilities of the reporting unit. The implied fair value of the Minerals reporting unit's goodwill is the excess of the fair value of the
reporting unit over the amounts assigned to its assets and liabilities. Our goodwill impairment is a nonrecurring fair value
measurement that required significant unobservable inputs (Level 3 fair value measurements) in the calculation. As a result of our
interim goodwill impairment test, we recorded a noncash goodwill impairment charge in our Minerals reporting unit, which is part
of our IGP segment, for $178 million. Due to this impairment, goodwill for the reporting unit decreased from its December 31,
2011 balance of $263 million to $85 million at December 31, 2012.

Consistent with prior years, the fair values of reporting units in 2012 were determined using a combination of two methods,
one utilizing market earnings multiples (the market approach) and the other derived from discounted cash flow models with
estimated cash flows based on internal forecasts of revenues and expenses over a ten year period plus a terminal value period (the
income approach). To arrive at the Minerals reporting unit's future cash flows, we use estimates of economic and market
assumptions, including growth rates in revenues, costs and estimates of future expected changes in operating margins, tax rates and
cash expenditures. Other significant estimates and assumptions include terminal value growth rates, future estimates of capital
expenditures and changes in future working capital requirements. The market approach estimates fair value by applying earnings
and revenue market multiples to the reporting unit's operating performance for the trailing twelve-month period. The income
approach estimates fair value by discounting the reporting unit's estimated future cash flows using a weighted-average cost of
capital that reflects current market conditions and the risk profile of the business unit. Under the income approach, we applied a
risk-adjusted discount rate of 16% to the future cash flows from the Minerals reporting unit. In addition to the earnings multiples
and the discount rates, certain other judgments and estimates are used to prepare the goodwill impairment test. If market conditions
change compared to those used in our market approach, or if actual future results of operations fall below the projections used in the
income approach, our goodwill could become further impaired in the future.

Intangible Assets

Intangible assets are comprised of customer relationships, contracts, backlog, trade name licensing agreements and

other. The cost and accumulated amortization of our intangible assets were as follows:

Millions of dollars

Intangibles not subject to amortization

Intangibles subject to amortization

Total intangibles

Accumulated amortization of intangibles

Net intangibles

December 31,

2012

2011

192

203

(104)

191

202

(89)

113

Intangibles subject to amortization are amortized over their estimated useful lives of up to 25 years. These intangible assets
are tested annually for impairment or more often if events or circumstances change that would create a triggering event. We
performed an undiscounted cash flow analysis due to a triggering event identified in the Minerals reporting unit during our annual
strategic planning process in the third quarter of 2012. No impairment of the intangibles was identified. Our intangibles
amortization expense for the years ended December 31, 2012, 2011 and 2010 is presented below:

Millions of dollars

2010

2011

2012

Our expected intangibles amortization expense in the next five years is presented below:

Millions of dollars

2013

2014

2015

2016

2017

Intangibles
amortization expense

Expected future
intangibles
amortization expense

Note 7. Property, Plant and Equipment

Other than those assets that have been written down to their fair values due to impairment, property, plant and equipment are
reported at cost less accumulated depreciation, which is generally provided on the straight-line method over the estimated useful
lives of the assets. Accelerated depreciation methods are also used for tax purposes, wherever permitted. Upon sale or retirement of
an asset, the related costs and accumulated depreciation are removed from the accounts and any gain or loss is recognized.

Property, plant and equipment are composed of the following:

Millions of dollars

Land

Buildings and property improvements

Equipment and other

Total

Less accumulated depreciation

Net property, plant and equipment

Estimated
Useful
Lives in Years

December 31,

2012

2011

N/A $

5-44

3-25

19
210
517
746
(356)

390

244

473

748

(364)

384

Note 8. Debt and Other Credit Facilities

Credit Agreement

The Credit Agreement contains customary covenants which include financial covenants requiring maintenance of a ratio of
consolidated debt to consolidated EBITDA not greater than 3.5 to 1 and a minimum consolidated net worth of $2 billion plus 50%
of consolidated net income for each quarter beginning December 31, 2011, and 100% of any increase in shareholders’ equity
attributable to the sale of equity interests. The noncash goodwill impairment of $178 million related to our Minerals reporting unit
did not have a material impact on the financial covenants in our credit agreements.

Letters of credit, surety bonds and guarantees

In connection with certain projects, we are required to provide letters of credit, surety bonds or guarantees to our customers.
Letters of credit are provided to certain customers and counter-parties in the ordinary course of business as credit support for
contractual performance guarantees, advanced payments received from customers and future funding commitments. We have
approximately $2.5 billion in committed and uncommitted lines of credit to support the issuance of letters of credit and as of
December 31, 2012, we have utilized $765 million of our present capacity under lines of credit. Surety bonds are also posted under
the terms of certain contracts to guarantee our performance. The letters of credit outstanding included $217 million issued under
our Credit Agreement and $548 million issued under uncommitted bank lines at December 31, 2012. Of the total letters of credit
outstanding, $277 million relate to our joint venture operations and $9 million of the letters of credit have terms that could entitle a
bank to require additional cash collateralization on demand. As the need arises, future projects will be supported by letters of credit
issued under our Credit Agreement or other lines of credit arranged on a bilateral, syndicated or other basis. We believe we have
adequate letter of credit capacity under our Credit Agreement and bilateral lines of credit to support our operations for the next
twelve months.

Nonrecourse Project Finance Debt

Fasttrax Limited, a joint venture in which we indirectly own a 50% equity interest with an unrelated partner, was awarded a
contract in 2001 with the U.K. Ministry of Defence (“MoD”) to provide a fleet of 92 heavy equipment transporters (“HETs”) to the
British Army. Under the terms of the arrangement, Fasttrax Limited operates and maintains the HET fleet for a term of 22 years.
The purchase of the HETs by the joint venture was financed through a series of bonds secured by the assets of Fasttrax Limited
totaling approximately £84.9 million and are non-recourse to KBR and its partner including £12.2 million which was replaced when
the shareholders funded combined equity and subordinated debt of approximately £12.2 million. The secured bonds are an
obligation of Fasttrax Limited and will never be a debt obligation of KBR because they are non-recourse to the joint venture
partners. Accordingly, in the event of a default on the term loan, the lenders may only look to the resources of Fasttrax Limited for
repayment.

Consolidated amount of non-recourse project-finance debt of a VIE

Millions of dollars

Current non-recourse project-finance debt of a VIE consolidated by KBR

Noncurrent non-recourse project-finance debt of a VIE consolidated by KBR

Total non-recourse project-finance debt of a VIE consolidated by KBR

December 31, 2012

The guaranteed secured bonds were issued in two classes consisting of Class A 3.5% Index Linked Bonds in the amount of
£56 million and Class B 5.9% Fixed Rate Bonds in the amount of £16.7 million. Principal payments on both classes of bonds
commenced in March 2005 and are due in semi-annual installments over the term of the bonds which mature in 2021. Subordinated
notes payable to the 50% partner initially bear interest at 11.25% increasing to 16% over the term of the notes through 2025.
Payments on the subordinated debt commenced in March 2006 and are due in semi-annual installments over the term of the notes.

The following table summarizes the combined principal installments for both classes of bonds and subordinated notes,

including inflation adjusted bond indexation over the next five years and beyond as of December 31, 2012:

Millions of dollars

2013

2014

2015

2016

2017

Beyond 2017

Note 9. U.S. Government Matters

Debt Payments

We provide substantial work under our government contracts to the United States Department of Defense (“DoD”) and other
governmental agencies. These contracts include our worldwide United States Army logistics contracts, known as LogCAP III and
IV.

Given the demands of working in Iraq and elsewhere for the U.S. government, we have disagreements and have experienced
performance issues with the various government customers for which we work. When performance issues arise under any of our
government contracts, the government retains the right to pursue remedies, which could include termination, under any affected
contract. If any contract were so terminated, our ability to secure future contracts could be adversely affected, although we would
receive payment for amounts owed for our allowable costs under cost-reimbursable contracts. Other remedies that could be sought

by our government customers for any improper activities or performance issues include sanctions such as forfeiture of profits,
suspension of payments, fines and suspensions or debarment from doing business with the government. Further, the negative
publicity that could arise from disagreements with our customers or sanctions as a result thereof could have an adverse effect on our
reputation in the industry, reduce our ability to compete for new contracts and may also have a material adverse effect on our
business, financial condition, results of operations and cash flow.

We have experienced and expect to be a party to various claims against us by employees, third parties, soldiers,
subcontractors and others that have arisen out of our work in Iraq such as claims for wrongful termination, personal injury claims
by third parties and army personnel, and subcontractor claims. While we believe we conduct our operations safely, the
environments in which we operate often lead to these types of claims. We believe the vast majority of these claims are governed by
the Defense Base Act or precluded by other defenses. We have a dispute resolution program under which most employment claims
are subject to binding arbitration. However, as a result of amendments to the Department of Defense Appropriations Act of 2010,
certain types of employee claims cannot be compelled to binding arbitration. An unfavorable resolution or disposition of these
matters could have a material adverse effect on our business, results of operations, financial condition and cash flow.

Award Fees

Government Compliance Matters

we determine it is probable that such costs will result in the collection of revenue. We generally do not recognize additional
revenue for disputed or potentially unallowable costs for which revenue has been previously reduced until we reach agreement with
the DCAA and/or the ACO that such costs are allowable.

Certain issues raised as a result of contract audits and other investigations are discussed below.

We have provided at the Army’s request information that addresses the use of armed security either directly or indirectly
charged to LogCAP III. In 2007, we filed a complaint in the ASBCA to recover $44 million of the amounts withheld from us. In
2009, KBR and the Army agreed to stay the case pending further discussions with the U.S. Department of Justice ("DOJ") as
discussed further below. The ASBCA denied the Army's latest request to stay the proceedings. In April 2012, the ASBCA ruled,
as requested by KBR, that our contract with the Army does not prohibit the use of private security contractors by either KBR or its
subcontractors. However, our motion to dismiss was denied on grounds that potential fact issues remain related to the
reasonableness of the private security costs charged to the contract. Because of continuing delays in getting documents from the
U.S. government attorneys during the discovery process, the hearing date has passed and all claims have been consolidated for
hearing. The three private security-related appeals currently pending before the ASBCA now have been consolidated for a single,
four-week hearing starting April 1, 2013. These appeals potentially involve the alleged use of private security contractors by both
KBR and up to 33 of its LOGCAP III subcontractors. We believe these sums were properly billed under our contract with the
Army. At this time, we believe the likelihood that a loss related to this matter has been incurred is remote. We have not adjusted
our revenues or accrued any amounts related to this matter.

to the U.S. COFC ruling, Tamimi filed for arbitration against us in 2009 to recover the payments we withheld from Tamimi pending
the resolution of Form 1s with our customer. In December 2010, the arbitration panel ruled that our subcontract terms were not
sufficient to hold retention from Tamimi for price reasonableness matters and awarded the subcontractor $38 million including
interest and certain legal costs. We paid the award to Tamimi during the third quarter of 2011. We do not believe we have the
ability to recover the disallowed portion of the questioned costs previously paid to Tamimi. With respect to remaining questions
raised regarding billing in accordance with contract terms, as of December 31, 2012, we believe it is reasonably possible that we
could incur losses in excess of the amount accrued for possible subcontractor costs billed to the customer that were possibly not in
accordance with contract terms. However, we do not believe we face a risk of significant loss from any disallowance of these costs
in excess of amounts withheld from subcontractors. As of December 31, 2012, we had withheld $17 million in payments from
several of our subcontractors pending the resolution of these remaining matters with our customer.

Investigations, Qui Tams and Litigation

The following matters relate to ongoing litigation or investigations involving U.S. government contracts.

housing containers and our provision of services to our employees and contractors. On July 5, 2007, the court granted our motion to
dismiss the qui tam claims and to compel arbitration of employment claims including a claim that the plaintiff was unlawfully
discharged. The majority of the plaintiff’s claims were dismissed but the plaintiff was allowed to pursue limited claims pending
discovery and future motions. Substantially all employment claims were sent to arbitration under the Company’s dispute resolution
program and were subsequently resolved in our favor. In January 2009, the Relator filed an amended complaint which is pending a
ruling on a discovery matter before further motions can be filed. On September 17, 2012, the Relator filed an objection to the
Magistrate's ruling, essentially appealing the ruling to the U.S. District Court. The motion remained pending for several years. On
November 19, 2012, the U.S. District Court affirmed and adopted the prior ruling, limiting the Relator's claims to our sites and
dates previously claimed. We are now moving forward to complete the remaining depositions and thereafter file our motion for
summary judgment. No trial date has been set, pending resolution of dispositive motions. We believe the Relator's claim is without
merit and that the likelihood that a loss has been incurred is remote. As of December 31, 2012, no amounts have been accrued.

measures to remediate the site. KBR services provided to the USACE were under the direction and control of the military and
therefore, KBR believes it has adequate defenses to these claims. KBR also has asserted the Political Question Doctrine and
government contractor defenses. Additionally, the U.S. government and other studies on the effects of exposure to the sodium
dichromate contamination at the water treatment plant have found no long term harm to the soldiers.

contract with the Army and are not prohibited under the LogCAP III contract, and we strongly contend that no fraud was
committed. Our responsive pleadings are due March 11, 2013. We intend to seek transfer of the case to the Eastern District of
Virginia, move to dismiss the complaint, and seek as speedy a trial as possible.

Other Matters

Claims. Included in receivables in our consolidated balance sheets are claims for costs incurred under various government
contracts totaling $219 million at December 31, 2012, of which $104 million is included in “Accounts receivable” and $115 million
is included in “Unbilled receivables on uncompleted contracts.” These claims relate to contracts where our costs have exceeded the
customer’s funded value of the task order. The $104 million of claims included in Accounts receivable results primarily from de-
obligated funding on certain task orders that were also subject to Form 1s relating to certain DCAA audit issues discussed above.
We believe such disputed costs will be resolved in our favor at which time the customer will be required to obligate funds from
appropriations for the year in which resolution occurs. The remaining claims balance of $115 million primarily represents costs for
which incremental funding is pending in the normal course of business. The claims outstanding at December 31, 2012 are
considered to be probable of collection and have been previously recognized as revenue.

Note 10. Other Commitments and Contingencies

Foreign Corrupt Practices Act (“FCPA”) investigations

Commercial Agent Fees

Barracuda-Caratinga Project Arbitration

In June 2000, we entered into a contract with Barracuda & Caratinga Leasing Company B.V. ("BCLC"), the project owner
and claimant, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. Petrobras is a
contractual representative that controls the project owner. In November 2007, we executed a settlement agreement with the project
owner to settle all outstanding project issues except for the bolts arbitration discussed below.

claiming $220 million plus interest for the cost of monitoring and replacing the defective stud bolts and, in addition, all of the costs
and expenses of the arbitration including the cost of attorneys’ fees. The arbitration was conducted in New York under the
guidelines of the United Nations Commission on International Trade Law (“UNCITRAL”).

In September 2011, the arbitration panel awarded the claimant approximately $193 million. The damages awarded were
based on the panel’s estimate to replace all subsea bolts, including those that did not manifest breaks, as well as legal and other
costs incurred by the claimant in the arbitration and interest thereon since the date of the award. The panel rejected our argument,
and the case law relied upon by us, that we were only liable for bolts that were discovered to be broken prior to the expiration of the
warranty period that ended on June 30, 2006. As of December 31, 2012, we have a liability of $219 million, including interest, to
Petrobras for the failed bolts which is included in “Other current liabilities.” The liability incurred by us in connection with the
arbitration is covered by an indemnity from our former parent, Halliburton. Accordingly, we have recorded an indemnification
receivable from Halliburton of $219 million pursuant to the indemnification under the master separation agreement which is
included in “Other current assets” as of December 31, 2012. We believe the arbitration award payable to Petrobras will be
deductible for tax purposes when paid and the indemnification payment will be treated by KBR for tax purposes as a contribution to
capital and accordingly is not taxable. In 2011 and 2012, we recorded discrete tax benefits of $71 million and $8 million,
respectively. At December 31, 2012 the deferred tax balance is $79 million. We have reviewed this matter in light of the direct
payment by Halliburton to BCLC and its public announcement that they have recorded a tax benefit related to this transaction.
Based on advice from outside legal counsel, we have determined that it is more likely than not that we are the proper taxpayer to
recognize this benefit although the underlying uncertainties with respect to the tax treatment of the transaction may ultimately lead
to alternate outcomes. See Note 16 ("Transactions with Former Parent") to our consolidated financial statements for additional
information.

PEMEX Arbitration

During 2008, we were successful in litigating and collecting on valid international arbitration awards against PEMEX on the
EPC 22 and EPC 28 projects. Additionally, PEMEX has sufficient assets in the U.S. which we believe we will be able to attach as a
result of the recognition of the ICC arbitration award in the U.S. Although it is possible we could resolve and collect the amounts
due from PEMEX in the next 12 months, we believe the timing of the collection of the award is uncertain and therefore, we have
continued to classify the amount due from PEMEX as a long term receivable included in “Noncurrent unbilled receivable on
uncompleted contracts” as of December 31, 2012. No adjustments have been made to our receivable balance since recognition of
the initial award in 2009. Although we believe we will ultimately collect the award, our failure to do so could result in the write off
of the receivable amount included in "Noncurrent unbilled receivable on uncompleted contracts."

FAO Litigation

Environmental

We are subject to numerous environmental, legal and regulatory requirements related to our operations worldwide. In the
United States, these laws and regulations include, among others: the Comprehensive Environmental Response, Compensation and
Liability Act; the Resources Conservation and Recovery Act; the Clean Air Act; the Federal Water Pollution Control Act; and the
Toxic Substances Control Act. In addition to federal and state laws and regulations, other countries where we do business often
have numerous environmental regulatory requirements by which we must abide in the normal course of our operations. These
requirements apply to our business segments where we perform construction and industrial maintenance services or operate and
maintain facilities.

We continue to monitor conditions at sites we own or owned and until further information is available, we are only able to
estimate a possible range of remediation costs. These locations were primarily utilized for manufacturing or fabrication work and
are no longer in operation. The use of these facilities created various environmental issues including deposits of metals, volatile and
semi-volatile compounds and hydrocarbons impacting surface and subsurface soils and groundwater. The range of remediation
costs could change depending on our ongoing site analysis and the timing and techniques used to implement remediation activities.
We do not expect costs related to environmental matters will have a material adverse effect on our consolidated financial position or
results of operations. Based on the information presently available to us, we have accrued approximately $6 million for the
assessment and remediation costs associated with all environmental matters, which represents the low end of the range of estimated
possible costs that could be as much as $11 million.

Leases

We are obligated under operating leases, principally for the use of land, offices, equipment, field facilities and warehouses.
We recognize minimum rental expenses over the term of the lease. When a lease contains a fixed escalation of the minimum rent or
rent holidays, we recognize the related rent expense on a straight-line basis over the lease term and record the difference between
the recognized rental expense and the amounts payable under the lease as deferred lease credits. We have certain leases for office
space where we receive allowances for leasehold improvements. We capitalize these leasehold improvements as property, plant
and equipment and deferred lease credits. Leasehold improvements are amortized over the shorter of their economic useful lives or
the lease term. Total rent expense was $149 million, $145 million and $165 million in 2012, 2011 and 2010, respectively.

Future total rental payments on noncancelable operating leases are as follows:

Millions of dollars

2013

2014

2015

2016

2017

Beyond 2017

Future rental
payments

429

601 Jefferson Building Lease. In November 2012, the joint venture in which we hold a 50% interest sold the 601 Jefferson
building in which we lease office space in Houston, Texas. We will continue to lease the building from the new owner under the
same lease agreement and terms, except for the elimination of an early termination and contraction option, for which we were paid
an $11 million modification fee. This lease incentive will be amortized over the remaining term of the lease, which runs through
June 30, 2030 and includes renewal options for three consecutive additional periods from 5 to 10 years each at prevailing market
rates. Annual base rent for the leased office space escalates ratably over the lease term from $10 million to $13 million.

500 Jefferson Building Lease. The term of the lease runs through June 30, 2030 and includes renewal options for three
consecutive additional periods from 5 to 10 years each at prevailing market rates. Annual base rent for the leased office space
escalates ratably over the lease term from $2 million to $4 million. For a small fee we have agreed to change our early termination
option date for all or a portion of the leased premises from 2022 to 2026.

Other

As of December 31, 2012, we had no commitment to provide funds to our privately financed projects compared to $17

million as of December 31, 2011. Commitments to fund these projects were supported by letters of credit as discussed in Note 8.

Note 11. Income Taxes

The components of the (provision)/benefit for income taxes are as follows:

Millions of dollars

Current income taxes:

Federal

Foreign

State

Total current

Deferred income taxes:

Federal

Foreign

State

Total deferred

Provision for income taxes

Years ended December 31,

2012

2011

2010

(19 ) $

(130)

(68)

(42)

(18)

(86) $

(183)

(3)

(205)

110
62
1
173
(32 ) $

(56)

(118)

(3)

(177)

(15)

—

(14)

(191)

The United States and foreign components of income from continuing operations before income taxes and noncontrolling

interests were as follows:

Millions of dollars
United States

Foreign

Total

Years ended December 31,

2012

2011

2010

(366) $

654

288

12
560
572

105

481

586

The reconciliations between the actual provision for income taxes on continuing operations and that computed by applying
the United States statutory rate to income from continuing operations before income taxes and noncontrolling interests are as
follows:

U.S. statutory federal rate

Rate differentials on foreign earnings

Non-deductible goodwill impairment

State and local income taxes

Foreign, federal and state tax adjustments

Barracuda arbitration award indemnification

Tax benefit from Australian joint venture losses

Taxes on unremitted Australian earnings

Valuation allowance

Uncertain tax position changes

Taxes on unconsolidated affiliates

Taxes on unincorporated joint ventures

U.K. tax rate change

Other permanent items, net
Total effective tax rate on pretax earnings

Years ended December 31,

2012

2011

2010

35.0%

(7.9)

21.6

0.2

(2.9)

(2.8)

(3.2)

3.9

3.4

(9.9)

(3.2)

(5.0)

3.5

(2.8)

29.9%

35.0%

(3.8)
—
0.4
(5.4)

(12.1)

(5.6)
—
(1.4)

(1.8)
—
(1.8)

1.2
0.9
5.6%

35.0%

(2.9)

—

0.2

(2.5)

—

0.2

4.1

—

(2.6)

0.5

0.6

32.6%

additional tax if remitted, or deemed remitted, as a dividend. Determination of the amount of unrecognized deferred U.S. income
tax liability is not practicable; however, the potential foreign tax credit associated with the deferred income would be available to
reduce the resulting U.S. tax liabilities.

KBR is subject to a tax sharing agreement primarily covering periods prior to the April 2007 separation from Halliburton.
The tax sharing agreement provides, in part, that KBR will be responsible for any audit settlements directly attributable to its
business activity for periods prior to its separation from our former parent. As of December 31, 2012, we have recorded a $49
million payable to our former parent for tax related items under the tax sharing agreement. See Note 16 for further discussion
related to our transactions with our former parent.

The primary components of our deferred tax assets and liabilities and the related valuation allowances are as follows:

Millions of dollars

Gross deferred tax assets:

Depreciation and amortization

Employee compensation and benefits

Construction contract accounting

Foreign tax credit carryforwards

Loss carryforwards

Insurance accruals

Allowance for bad debt

Accrued liabilities

Barracuda arbitration award indemnification

Other

Total

Gross deferred tax liabilities:

Construction contract accounting

Intangibles

Depreciation and amortization

Other

Total

Valuation Allowances:

Loss carryforwards

Net deferred income tax asset

Years ended December 31,

2012

2011

13 $
185
125
24
74
29
9
69
79
26
633 $

(140) $

(47)

(38)

(39)

183

131

—

558

(92)

(40)

(27)

(48)

(264) $

(207)

(36)

333 $

(25)

326

At December 31, 2012, we had foreign net operating loss carryforwards of approximately $292 million of which $165
million will expire by 2022 and $127 million can be carried forward indefinitely. We also had foreign tax credit carryforwards of
$24 million that may be carried forward to 2022.

For the year ended December 31, 2012, our valuation allowance increased to $36 million from $25 million primarily as a
result of increases of net operating losses in jurisdictions other than our primary countries of operations where we are not likely to
utilize the deferred tax asset, partially offset by reductions in our valuation allowances in Australia and Canada.

KBR is the parent of a group of domestic companies that are members of a U.S. consolidated federal income tax return. We
also file income tax returns in various states and foreign jurisdictions. With few exceptions, we are no longer subject to examination
by tax authorities for U.S. federal or state and local income tax for years before 2006, or for non-U.S. income tax for years before
1998.

We account for uncertain tax positions in accordance with guidance in ASC 740 which prescribes the minimum recognition
threshold a tax position taken or expected to be taken in a tax return is required to meet before being recognized in the financial
statements. A reconciliation of the beginning and ending amount of uncertain tax positions is as follows:

Millions of dollars

Balance at January 1

Increases in tax positions for current year

Increases in tax positions for prior years

Decreases in tax positions for prior years

Reductions in tax positions for audit settlements

Reductions in tax positions for statute expirations

Other
Balance at December 31

2012

2011

2010

120

(25)

(11)

(9)

95
37
11
(5)

(7)

(11)

—
120

—

(9)

—

(1)

The total amount of uncertain tax positions that, if recognized, would affect our effective tax rate was approximately $81
million as of December 31, 2012. The difference between this amount and the amounts reflected in the tabular reconciliation above
relates primarily to deferred U.S. federal and non-U.S. income tax benefits on uncertain tax positions related to U.S. federal and
non-U.S. income taxes. In the next twelve months, it is reasonably possible that our uncertain tax positions could change by
approximately $17 million due to the expirations of the statute of limitations.

We recognize interest and penalties related to uncertain tax positions within the provision for income taxes in our
consolidated statement of income. Our accrual for interest and penalties was $11 million for the year ended December 31, 2012 and
$20 million for the year ended December 31, 2011. During the year ended December 31, 2012, 2011 and 2010, we recognized $(6)
million, $4 million and $10 million, respectively in net interest and penalties charges (benefit) related to uncertain tax positions.

As of December 31, 2012, a portion of the uncertain tax positions and accrued interest and penalties were expected to be
settled for cash within one year and therefore that portion is classified as current income tax payables with the remaining balance of
uncertain tax positions and related accrued interest and penalties classified as noncurrent income tax payables.

Note 12. Shareholders’ Equity

The following tables summarize our activity in shareholders’ equity:

Millions of dollars

Total

PIC

Retained
Earnings

Treasury
Stock

AOCL

NCI

Balance at December 31, 2009

2,296

2,103

854

(225) $

(444) $

Share-based compensation

Common stock issued upon exercise of stock options

Dividends declared to shareholders
Adjustment pursuant to an agreement with former
parent

Repurchases of common stock

Issuance of ESPP shares

Distributions to noncontrolling interests

Investments by noncontrolling interests

Acquisition of noncontrolling interests

Consolidation of Fasttrax Limited

Other noncontrolling interests activity

Net income

Other comprehensive income, net of tax

(23)

(8)

(233)

(108)

(181)

(4)

(1)

395

—

(8)

—

(136)

—

(23)

—

(1)

—

327

—

Balance at December 31, 2010

2,204

1,981

1,157

Share-based compensation

Common stock issued upon exercise of stock options

Post-closing adjustment related to acquisition of
former NCI partner

Tax benefit increase related to share-based plans

Dividends declared to shareholders

Repurchases of common stock

Issuance of ESPP shares

Distributions to noncontrolling interests

Other noncontrolling interests activity

Net income

Other comprehensive loss, net of tax

(5)

(30)

(118)

(63)

(7)

540

(111)

(5)

—

(30)

—

480

—

—
(233)

4
—
—
—
—
—
—
—
(454) $

—
—

—

(118)

—

(108)

(26)

(4)

(1)

—

(19)

—

(438) $

(42)

—

(110)

—

(63)

(7)

(1)

Balance at December 31, 2011

2,442

2,005

1,607

(569) $

(548) $

(53)

Deferred tax and foreign currency adjustments (a)

Share-based compensation

Common stock issued upon exercise of stock options

Tax benefit increase related to share-based plans

Dividends declared to shareholders

Repurchases of common stock

Issuance of ESPP shares

Distributions to noncontrolling interests

Net income

Other comprehensive income, net of tax (a)

(42)

(40)

(36)

202

(62)

—

(42)

—

144

—

(40)

—

(62)

—

(36)

—

Balance at December 31, 2012

2,511

2,049

1,709

(606) $

(610) $

(31)

(a) During the third quarter of 2012, we recorded out-of-period adjustments in our deferred tax accounts, most of which
relate to years before 2010. These adjustments are not material to 2012 or the periods to which they relate. The out-of-
period adjustments were $3 million to our current period tax expense and $9 million to our equity accounts. The
adjustments recorded to our equity accounts were $16 million to PIC and $(7) million to AOCL.

Accumulated other comprehensive loss, net of tax

Millions of dollars

Accumulated CTA, net of tax of $27, $19 and $18

Accumulated pension liability adjustments, net of tax of $203, $189 and $157

Accumulated unrealized losses on derivatives, net of tax of $0, $1 and $0
Total accumulated other comprehensive loss

December 31,

2012

2011

2010

(88) $

(70) $

(521)

(1)

(471 )

(7 )

(610) $

(548) $

(52)

(382)

(4)

(438)

Accumulated comprehensive loss for years ended December 31, 2012, 2011 and 2010 include approximately $18 million,

$16 million and $14 million for the amortization of actuarial loss, net of taxes.

Shares of common stock

Millions of shares and dollars

Balance at December 31, 2010

Common stock issued

Balance at December 31, 2011

Common stock issued

Balance at December 31, 2012

Shares of treasury stock

Millions of shares and dollars

Balance at December 31, 2010

Treasury stock acquired, net of ESPP shares issued

Balance at December 31, 2011

Treasury stock acquired, net of ESPP shares issued

Balance at December 31, 2012

Dividends

171.4

1.0

172.4

0.8

173.2

Amount

20.3
3.9
24.2
1.4
25.6

454

115

569

606

We declared dividends totaling $42 million in 2012 and $30 million in 2011. As of December 31, 2012, we had accrued

dividends payable of $12 million.

Note 13. Share-based Compensation and Incentive Plans

Stock Plans

In 2012, 2011 and 2010 share-based compensation awards were granted to employees under KBR share-based

compensation plans.

KBR Stock and Incentive Plan (Amended May 2012)

In November 2006, KBR established the KBR Stock and Incentive Plan ("KBR Stock Plan"), which provides for the grant

of any or all of the following types of share-based compensation listed below:

•
•
•
•
•
•

stock options, including incentive stock options and nonqualified stock options;
stock appreciation rights, in tandem with stock options or freestanding;
restricted stock;
restricted stock units;
cash performance awards; and
stock value equivalent awards.

In May 2012, the KBR Stock Plan was amended to add 2 million shares of our common stock available for issuance under
the KBR Stock Plan. Additionally, this amendment increased the sublimit under the Stock Plan in the form of restricted stock
awards, restricted stock unit awards or pursuant to performance awards by 2 million. Under the terms of the KBR Stock Plan, 12
million shares of common stock have been reserved for issuance to employees and non-employee directors. The plan specifies that
no more than 5.5 million shares can be awarded as restricted stock or restricted stock units or pursuant to cash performance awards.
At December 31, 2012, approximately 5.4 million shares were available for future grants under the KBR Stock Plan, of which
approximately 2.6 million shares remained available for restricted stock awards or restricted stock unit awards.

KBR Stock Options

Under KBR’s Stock Plan, effective as of the closing date of the KBR initial public offering, stock options are granted with
an exercise price not less than the fair market value of the common stock on the date of the grant and a term no greater than 10
years. The term and vesting periods are established at the discretion of the Compensation Committee at the time of each grant. We
amortize the fair value of the stock options over the vesting period on a straight-line basis. Options are granted from shares
authorized by our Board of Directors. Total number of stock options granted and the assumptions used to determine the fair value
of granted options were as follows:

KBR stock options assumptions summary

Granted stock options (millions of shares)

Weighted average expected term (in years)
Weighted average grant-date fair value per share

KBR stock options range assumptions summary

Expected volatility range

Expected dividend yield range

Risk-free interest rate range

Years ended December 31,

2012

2011

0.8
6.3

0.6

6.2

14.93 $

16.78

Years ended December 31,

2012

Range

2011

Range

Start

End

Start

End

41.41%

0.57%

0.86%

53.10%

0.80%

1.48%

44.01%

0.52%

1.22%

53.17%

0.79%

2.76%

For KBR stock options granted in 2012, 2011 and 2010, the fair value of options at the date of grant was estimated using the
Black-Scholes-Merton option pricing model. The expected volatility of KBR options granted in each year is based upon a blended
rate that uses the historical and implied volatility of common stock for KBR and selected peers. The expected term of KBR options
granted in each year is based upon the average of the life of the option and the vesting period of the option. The simplified estimate
of expected term is utilized as we lack sufficient history to estimate an expected term for KBR options. The estimated dividend
yield is based upon KBR’s annualized dividend rate divided by the market price of KBR’s stock on the option grant date. The risk-
free interest rate is based upon the yield of U.S. government issued treasury bills or notes on the option grant date.

The following table presents stock options granted, exercised, forfeited and expired under KBR share-based compensation

plans for the year ended December 31, 2012.

KBR stock options activity summary

Outstanding at December 31, 2011

Number of Shares

2,900,199

Weighted
Average
Exercise Price
per Share
19.75

Weighted
Average
Remaining
Contractual
Term (years)

Aggregate
Intrinsic Value
(in millions)
28.58

6.75 $

Granted

Exercised

Forfeited

Expired

Outstanding at December 31, 2012

Exercisable at December 31, 2012

782,243

(497,596)

(129,191)

(42,137)

3,013,518

1,750,243

34.26

10.48

31.93

21.60

24.00

17.62

6.86 $

5.54 $

24.76

22.73

The total intrinsic values of options exercised for the years ended December 31, 2012, 2011 and 2010 were $9 million, $10
million and $4 million, respectively. As of December 31, 2012, there was $12 million of unrecognized compensation cost, net of
estimated forfeitures, related to non-vested KBR stock options, expected to be recognized over a weighted average period of
approximately 1.88 years. Stock option compensation expense was $8 million in 2012, $7 million in 2011 and $5 million in 2010.
Total income tax benefit recognized in net income for share-based compensation arrangements was $3 million in 2012 and $2
million in 2011 and 2010.

KBR Restricted stock

Restricted shares issued under the KBR’s Stock Plan are restricted as to sale or disposition. These restrictions lapse
periodically over an extended period of time not exceeding 10 years. Restrictions may also lapse for early retirement and other
conditions in accordance with our established policies. Upon termination of employment, shares on which restrictions have not
lapsed must be returned to us, resulting in restricted stock forfeitures. The fair market value of the stock on the date of grant is
amortized and ratably charged to income over the period during which the restrictions lapse on a straight-line basis. For awards
with performance conditions, an evaluation is made each quarter as to the likelihood of meeting the performance criteria. Share-
based compensation is then adjusted to reflect the number of shares expected to vest and the cumulative vesting period met to date.

The following table presents the restricted stock awards and restricted stock units granted, vested and forfeited during 2012

under KBR’s Stock Plan.

Restricted stock activity summary

Nonvested shares at December 31, 2011

Granted

Vested

Forfeited

Nonvested shares at December 31, 2012

Weighted
Average
Grant-Date
Fair Value per
Share

Number of
Shares

833,498
280,247
(370,991)

(77,724)
665,030

24.95

33.13

25.26

28.36

27.83

The weighted average grant-date fair value per share of restricted KBR shares granted to employees during 2012, 2011 and
2010 were $33.13, $35.16 and $21.28, respectively. Restricted stock compensation expense was $8 million for 2012 and $12
million for 2011 and 2010. Total income tax benefit recognized in net income for share-based compensation arrangements was $3
million in 2012 and $4 million in both 2011 and 2010. As of December 31, 2012, there was $13 million of unrecognized
compensation cost, net of estimated forfeitures, related to KBR’s nonvested restricted stock and restricted stock units, which is
expected to be recognized over a weighted average period of 3.3 years. The total fair value of shares vested was $12 million in
2012, $16 million in 2011 and $13 million in 2010 based on the weighted-average fair value on the vesting date. The total fair
value of shares vested was $9 million in 2012, $11 million in 2011 and $12 million in 2010 based on the weighted-average fair
value on the date of grant.

KBR Cash Performance Based Award Units (“Cash Performance Awards”)

Under KBR’s Stock Plan, for Cash Performance Awards granted in the year 2012 and 2011 performance is based 100% on
average Total Shareholder Return (“TSR”), as compared to the average TSR of KBR’s peers. For Cash Performance Awards
granted in the year 2010, performance is based 75% on average TSR, as compared to the average TSR of KBR’s peers, and 25% on
KBR’s Return on Capital (“ROC”). The cash performance award units may only be paid in cash. In accordance with the provisions
of ASC 718-10, the TSR portion of the performance award units are classified as liability awards and remeasured at the end of each

100

reporting period at fair value until settlement. The fair value approach uses the Monte Carlo valuation method which analyzes the
companies comprising KBR’s peer group, considering volatility, interest rate, stock beta and TSR through the grant date. The ROC
calculation is based on the company’s weighted average net income from continuing operations plus (interest expense x (1-
effective tax rate)), divided by average monthly capital from continuing operations. The ROC portion of the Cash Performance
Award is also classified as a liability award and remeasured at the end of each reporting period based on our estimate of the amount
to be paid at the end of the vesting period.

Under KBR’s Stock Plan, in 2012, we granted 29 million performance based award units (“Cash Performance Awards”)
with a three-year performance period from January 1, 2012 to December 31, 2014. In 2011, we granted 28 million Cash
Performance Awards with a three-year performance period from January 1, 2011 to December 31, 2013. In 2010, we granted
25.2 million Cash Performance Awards with a performance period from January 1, 2010 to December 31, 2012. At December 31,
2012, Cash Performance Awards forfeited, net of previous plan payout, totaled $8 million in 2012, $6 million in 2011 and 2010. At
December 31, 2012, the outstanding balance for Cash Performance Awards is 67.4 million units. No Cash Performance Awards
will vest until such earned Cash Performance Awards, if any, are paid, subject to approval of the performance results by the Board
of Directors Compensation Committee.

Cost for the Cash Performance Awards is accrued over the requisite service period. For the years ended December 31,
2012, 2011 and 2010, we recognized $18 million, $34 million and $26 million, respectively, in expense for the Cash Performance
Awards. The expense associated with these Cash Performance Awards is included in cost of services and general and
administrative expense in our consolidated statements of income. The liability for awards included in “Employee compensation and
benefits” on the consolidated balance sheet were $48 million at December 31, 2012 of which $32 million will become due within
one year, and $52 million at December 31, 2011.

KBR Employee Stock Purchase Plan (“ESPP”)

Under the KBR ESPP, eligible employees may withhold up to 10% of their earnings, subject to some limitations, to
purchase shares of KBR’s common stock. Unless KBR’s Board of Directors shall determine otherwise, each six-month offering
period commences at the beginning of February and August of each year. Employees who participate in the ESPP will receive a
5% discount on the stock price at the end of each six-month purchase period. During 2012 and 2011, our employees purchased
approximately 138,000 and 105,000 shares, respectively, through the KBR ESPP. These shares were reissued from our treasury
share account.

Share-based compensation

The grant-date fair value of employee share options is estimated using option-pricing models. If an award is modified after
the grant date, incremental compensation cost is recognized immediately before the modification. Share-based compensation
expense consists of $10 million recorded to cost of services on the consolidated income statement, while the remaining $6 million is
recorded to general and administrative expenses on the consolidated income statement. The benefits of tax deductions in excess of
the compensation cost recognized for the options (excess tax benefits) are classified as additional paid-in-capital, and cash retained
as a result of these excess tax benefits is presented in the statement of cash flows as financing cash inflows.

Share-based compensation summary table

Millions of dollars

Share-based compensation

Total income tax benefit recognized in net income for share-based compensation
arrangements

Incremental compensation cost

Tax benefit increase (decrease) related to share-based plans

Years ended December 31

2012

2011

2010

6
1
4

—

Incremental compensation cost resulted from modifications of previously granted share-based awards which allowed certain
employees to retain their awards after leaving the company. Excess tax benefits realized from the exercise of share-based
compensation awards has been recognized as paid-in capital in excess of par.

Note 14. Financial Instruments and Risk Management

Foreign currency risk. Techniques in managing foreign currency risk include, but are not limited to, foreign currency
investing and the use of currency derivative instruments. We selectively manage significant exposures to potential foreign
exchange losses considering current market conditions, future operating activities and the associated cost in relation to the
perceived risk of loss. The purpose of our foreign currency risk management activities is to protect us from the risk that the
eventual U.S. dollar cash flow resulting from the sale and purchase of products and services in foreign currencies will be adversely
affected by changes in exchange rates.

We manage our foreign currency exposure through the use of currency derivative instruments as it relates to the major
currencies, which are generally the currencies of the countries in which we do the majority of our international business. These

101

instruments generally have an expiration date of two years or less. Forward exchange contracts, which are commitments to buy or
sell a specified amount of a foreign currency at a specified price and time, are generally used to manage identifiable foreign
currency commitments. Forward exchange contracts and foreign exchange option contracts, which convey the right, but not the
obligation to sell or buy a specified amount of foreign currency at a specified price, are generally used to manage exposures related
to assets and liabilities denominated in a foreign currency. None of the forward or option contracts are exchange traded. While
derivative instruments are subject to fluctuations in value, the fluctuations are generally offset by the value of the underlying
exposures. The use of some contracts may limit our ability to benefit from favorable fluctuations in foreign exchange rates.

Foreign currency contracts are not utilized to manage exposures in some currencies due primarily to the lack of available
markets or cost considerations (non-traded currencies). We attempt to manage our working capital position to minimize foreign
currency commitments in non-traded currencies and recognize that pricing for the services and products offered in these countries
should cover the cost of exchange rate devaluations. We have historically incurred transaction losses in non-traded currencies.

Assets, liabilities and forecasted cash flow denominated in foreign currencies. We use the derivative instruments
described above to manage the foreign currency exposures related to specific assets and liabilities, that are denominated in foreign
currencies; however, we have not elected to account for these instruments as hedges for accounting purposes. Additionally, we use
the derivative instruments described above to manage forecasted cash flow denominated in foreign currencies generally related to
long-term engineering and construction projects. We designate these contracts related to engineering and construction projects as
cash flow hedges. The ineffective portion of these hedges is included in operating income in the accompanying consolidated
statements of income. During 2012, 2011 and 2010 no hedge ineffectiveness was recognized. Unrealized gains and losses include
amounts attributable to cash flow hedges placed by our consolidated and unconsolidated subsidiaries and are included in other
comprehensive income in the accompanying consolidated balance sheets. We had $1 million in unrealized gains, no unrealized
gains and $2 million in unrealized net losses on these cash flow hedges as of December 31, 2012, 2011 and 2010, respectively.
Changes in the timing or amount of the future cash flow being hedged could result in hedges becoming ineffective and, as a result,
the amount of unrealized gain or loss associated with that hedge would be reclassified from other comprehensive income into
earnings. At December 31, 2012, the maximum length of time over which we are hedging our exposure to the variability in future
cash flow associated with foreign currency forecasted transactions is 33 months.

Notional amounts and fair market values. The notional amounts of open forward contracts and options held by our
consolidated subsidiaries were $517 million, $352 million and $403 million at December 31, 2012, 2011 and 2010, respectively.
The notional amounts of our foreign exchange contracts do not generally represent amounts exchanged by the parties, and thus, are
not a measure of our exposure or of the cash requirements relating to these contracts. The amounts exchanged are calculated by
reference to the notional amounts and by other terms of the derivatives, such as exchange rates. These contract assets (liabilities)
had a fair value of $(1) million and $5 million at December 31, 2012 and 2011, respectively.

Credit risk. Financial instruments that potentially subject us to concentrations of credit risk are primarily cash equivalents,
investments and trade receivables. It is our practice to place our cash equivalents in time deposits and high-quality securities with
various banks, financial institutions and investment managers. We derive the majority of our revenues from engineering and
construction services to the energy industry and services provided to the United States government. There are concentrations of
receivables in the United States and the United Kingdom. We maintain an allowance for losses based upon the expected
collectability of all trade accounts receivable.

There are no significant concentrations of credit risk with any individual counterparty related to our derivative contracts.
We select counterparties based on their profitability, balance sheet and a capacity for timely payment of financial commitments
which is unlikely to be adversely affected by foreseeable events.

Interest rate risk. Certain of our unconsolidated subsidiaries and joint-ventures are exposed to interest rate risk through their
variable rate borrowings. This variable-rate exposure is managed with interest rate swaps. We had unrealized net losses on the
interest rate swaps held by our unconsolidated subsidiaries and joint-ventures of approximately $2 million, $4 million and $5
million as of December 31, 2012, 2011 and 2010, respectively.

Fair market value of financial instruments. The carrying amount of variable rate long-term debt approximates fair market
value because these instruments reflect market changes to interest rates. The carrying amount of short-term financial instruments,
cash and equivalents, receivables and accounts payable, as reflected in the consolidated balance sheets, approximates fair market
value due to the short maturities of these instruments. The currency derivative instruments are carried on the balance sheet at fair
value and are based upon third party quotes. The financial assets and liabilities measured at fair value on a recurring basis are not
material for any periods presented.

102

Note 15. Equity Method Investments and Variable Interest Entities

We conduct some of our operations through joint ventures which are in partnership, corporate, undivided interest and other
business forms and are principally accounted for using the equity method of accounting. Additionally, the majority of our joint
ventures are also variable interest entities which are further described under “Variable Interest Entities”. The following is a
description of our significant investments accounted for on the equity method of accounting that are not variable interest entities.

Equity Method Investments

MMM. MMM is a joint venture formed under a Partners Agreement related to the Mexico contract with PEMEX. The
MMM joint venture was set up under Mexican maritime law in order to hold navigation permits to operate in Mexican waters. The
scope of the business is to render services for maintenance, repair and restoration of offshore oil and gas platforms and provisions
of quartering in the territorial waters of Mexico. KBR holds a 50% interest in the MMM joint venture.

Consolidated summarized financial information for all jointly owned operations including variable interest entities that are

accounted for using the equity method of accounting is as follows:

Balance Sheets

Millions of dollars

Current assets

Noncurrent assets

Total assets

Current liabilities

Noncurrent liabilities

Member’s equity

Total liabilities and member’s equity

Statements of Operations

Millions of dollars

Revenue

Operating income

Net income

Unconsolidated VIEs

December 31,

2012

2011

3,129

4,159

7,288

2,460

4,424

404

7,288

2,151

3,828

5,979

1,111

4,468

400

5,979

Years ended December 31,

2012

2011

2010

3,442
777
363

2,638 $
666 $
314 $

2,497

617

334

The following is a summary of the significant variable interest entities in which we have a significant variable interest, but

we are not the primary beneficiary:

Unconsolidated VIEs
(in millions, except for percentages)

Aspire Defence project

Inpex LNG project

U.K. Road projects

EBIC Ammonia project

Fermoy Road project

Year ended December 31, 2012

VIE Total assets

VIE Total liabilities

Maximum
exposure to
loss

2,981

1,417

1,387

675

255

2,926
1,324
1,539
379
253

103

Unconsolidated VIEs
(in millions, except for percentages)

Aspire Defence project

U.K. Road projects

EBIC Ammonia project

Fermoy Road project

Year ended December 31, 2011

VIE Total assets

VIE Total liabilities

2,954
1,393
693
228

2,916

1,520

389

249

Aspire Defence project. In April 2006, Aspire Defence, a joint venture between us, Carillion Plc. and two financial
investors, was awarded a privately financed project contract by the U.K. MoD to upgrade and provide a range of services to the
British Army’s garrisons at Aldershot and around Salisbury Plain in the United Kingdom. In addition to a package of ongoing
services to be delivered over 35 years, the project includes a nine-year construction program to improve soldiers’ single living,
technical and administrative accommodations, along with leisure and recreational facilities. Aspire Defence manages the existing
properties and is responsible for design, refurbishment, construction and integration of new and modernized facilities. We
indirectly own a 45% interest in Aspire Defence, the project company that is the holder of the 35-year concession contract. In
addition, we own a 50% interest in each of two joint ventures that provide the construction and the related support services to
Aspire Defence. As of December 31, 2012, our performance through the construction phase is supported by $26 million in letters
of credit. Furthermore, our financial and performance guarantees are joint and several, subject to certain limitations, with our joint
venture partners. The project is funded through equity and subordinated debt provided by the project sponsors and the issuance of
publicly held senior bonds which are nonrecourse to us. The entities we hold an interest in are variable interest entities; however,
we are not the primary beneficiary of these entities. We account for our interests in each of the entities using the equity method of
accounting. Our maximum exposure to construction and operating joint venture losses is limited to the funding of any future losses
incurred by those entities under their respective contracts with the project company. As of December 31, 2012, our assets and
liabilities associated with our investment in this project, within our consolidated balance sheet, were $27 million and $1 million,
respectively. The $26 million difference between our recorded liabilities and aggregate maximum exposure to loss was primarily
related to our equity investments and other receivables in the project as of December 31, 2012.

Inpex LNG project. In January 2012, we signed an agreement to provide fixed-price and cost-reimbursable EPC services to
construct the Inpex Ichthys Onshore LNG Export Facility in Darwin, Australia (“Inpex LNG project”). The project will be
executed using two joint ventures in which we own a 30% equity interest. In 2012, revenue and job income for services provided to
our joint venture partners on this project was $130 million and $13 million, respectively. The investments are accounted for using
the equity method of accounting. At December 31, 2012, our assets and liabilities associated with our investment in this project
recorded in our condensed consolidated balance were $63 million and $20 million, respectively. The $43 million difference
between our recorded liabilities and aggregate maximum exposure to loss was related to our equity investment and other
receivables due from the entity as of December 31, 2012. The joint venture executes a project that has a lump sum component, and
we have an exposure to losses if the project exceeds the lump sum component to the extent of our ownership percentage in the joint
venture.

U.K. Road projects. We are involved in four privately financed projects, executed through joint ventures, to design, build,
operate and maintain roadways for certain government agencies in the United Kingdom. We have a 25% ownership interest in each
of these joint ventures and account for them using the equity method of accounting. The joint ventures have obtained financing
through third parties that is nonrecourse to the joint venture partners. These joint ventures are variable interest entities; however,
we are not the primary beneficiary. Our maximum exposure to loss represents our equity investments in these ventures.

EBIC Ammonia project. We have an investment in a development corporation that has an indirect interest in the Egypt Basic
Industries Corporation (“EBIC”) ammonia plant project located in Egypt. We performed the engineering, procurement and
construction (“EPC”) work for the project and completed our operations and maintenance services for the facility in the first half of
2012. We own 65% of this development corporation and consolidate it for financial reporting purposes. The development
corporation owns a 25% ownership interest in a company that consolidates the ammonia plant which is considered a variable
interest entity. The development corporation accounts for its investment in the company using the equity method of accounting.
The variable interest entity is funded through debt and equity. Indebtedness of EBIC under its debt agreement is non-recourse to us.
We are not the primary beneficiary of the variable interest entity. As of December 31, 2012, our assets and liabilities associated
with our investment in this project, within our consolidated balance sheet, were $80 million and $3 million, respectively. The $47
million difference between our recorded liabilities and aggregate maximum exposure to loss was related to our investment balance
and other receivables in the project as of December 31, 2012.

Fermoy Road project. We participate in a privately financed project executed through certain joint ventures formed to
design, build, operate and maintain a toll road in southern Ireland. The joint ventures were funded through debt and were formed
with minimal equity. These joint ventures are variable interest entities; however, we are not the primary beneficiary. We have up
to a 25% ownership interest in the project’s joint ventures, and we are accounting for these interests using the equity method of
accounting.

104

Consolidated VIEs

The following is a summary of the significant VIEs where we are the primary beneficiary:

Consolidated VIEs
(in millions, except for percentages)
Gorgon LNG project

Escravos Gas-to-Liquids project

Fasttrax Limited project

Consolidated VIEs
(in millions, except for percentages)
Gorgon LNG project

Escravos Gas-to-Liquids project

Fasttrax Limited project

Year ended December 31, 2012

VIE Total assets

VIE Total liabilities

580
267
101

620

320

105

Year ended December 31, 2011

VIE Total assets

VIE Total liabilities

546
326
103

607

381

108

Gorgon LNG project. We have a 30% ownership in an Australian joint venture which was awarded a contract by Chevron
for cost-reimbursable FEED and EPC management ("EPCm") services to construct a LNG plant. The joint venture is considered a
VIE, and, because we are the primary beneficiary, we consolidate this joint venture for financial reporting purposes.

Escravos Gas-to-Liquids (“GTL”) project. During 2005, we formed a joint venture to engineer and construct a gas
monetization facility. We own a 50% equity interest in the joint venture and determined that we are the primary beneficiary;
accordingly, we have consolidated the joint venture for financial reporting purposes. There are no consolidated assets that
collateralize the joint venture’s obligations. However, at December 31, 2012 and 2011, the joint venture had approximately $117
million and $119 million of cash, respectively, which mainly relate to advanced billings in connection with the joint venture’s
obligations under the EPC contract.

Fasttrax Limited project. In December 2001, the Fasttrax Joint Venture (the “JV”) was created to provide to the U.K. MoD
a fleet of 92 new heavy equipment transporters (“HETs”) capable of carrying a 72-ton Challenger II tank. The JV owns, operates
and maintains the HET fleet and provides heavy equipment transportation services to the British Army. The purchase of the assets
was completed in 2004, and the operating and service contracts related to the assets extend through 2023. The JV’s entity structure
includes a parent entity and its 100%-owned subsidiary, Fasttrax Ltd (the “SPV”). KBR and its partner own each 50% of the parent
entity, which is considered a variable interest entity. We determined that we are the primary beneficiary of this project entity
because we control the activities that most significantly impact economic performance of the entity. Therefore, we consolidate this
VIE.

The JV’s purchase of the assets was funded through the issuance of several series guaranteed secured bonds totaling
approximately £84.9 million issued by the SPV including £12.2 million which was replaced in 2005 when the shareholders funded
combined equity and subordinated debt of approximately £12.2 million. For further details regarding our non-recourse project-
finance debt of a VIE consolidated by KBR, including the total amount of debt outstanding at December 31, 2012, please refer to
Note 8. Assets collateralizing the JV’s senior bonds include cash and equivalents of $25 million and property, plant and equipment
of approximately $72 million, net of accumulated depreciation of $53 million as of December 31, 2012.

Note 16. Transactions with Former Parent

105

As discussed above under “Barracuda-Caratinga Project Arbitration,” we have recorded an indemnification receivable due
from Halliburton of approximately $219 million, including interest, associated with our estimated liability in the bolts matter which
is included in “Other current assets” as of December 31, 2012. In January 2013, Halliburton paid $219 million to the claimant and
the matter is considered concluded. We believe the arbitration award payable to Petrobras will be deductible for tax purposes when
paid and the indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not
taxable. In 2011 and 2012, we recorded discrete tax benefits of $71 million and $8 million, respectively. At December 31, 2012
the deferred tax balance is $79 million. We have reviewed this matter in light of the direct payment by Halliburton to BCLC and its
public announcement that they have recorded a tax benefit related to this transaction. Based on advice from outside legal counsel,
we have determined that it is more likely than not that we are the proper taxpayer to recognize this benefit although the underlying
uncertainties with respect to the tax treatment of the transaction may ultimately lead to alternate outcomes.

Note 17. Retirement Plans

We have various plans that cover our employees. These plans include defined contribution plans and defined benefit plans.

• Our defined contribution plans provide retirement benefits in return for services rendered. These plans provide an
individual account for each participant and have terms that specify how contributions to the participant’s account
are to be determined rather than the amount of pension benefits the participant is to receive. Contributions to
these plans are based on pretax income and/or discretionary amounts determined on an annual basis. Our expense
for the defined contribution plans totaled $81 million in 2012, $71 million in 2011 and $64 million in 2010.
Additionally, we participate in a Canadian multi-employer plan to which we contributed $10 million in both 2012
and 2011 and $12 million in 2010;

• Our defined benefit plans are funded pension plans, which define an amount of pension benefit to be provided,

usually as a function of age, years of service or compensation.

We account for our defined benefit pension plan in accordance with ASC 715 - Compensation - Retirement Benefits, which

requires an employer to:

•

recognize on its balance sheet the funded status (measured as the difference between the fair value of plan assets
and the benefit obligation) of pension plan;
recognize, through comprehensive income, certain changes in the funded status of a defined benefit plan in the
year in which the changes occur;

• measure plan assets and benefit obligations as of the end of the employer’s fiscal year; and
• disclose additional information.

106

Benefit obligation and plan assets

We used a December 31 measurement date for all plans in 2012 and 2011. Plan asset, expenses and obligation for

retirement plans are presented in the following tables.

Benefit obligation

United States

Int’l

United States

Int’l

Pension Benefits

Millions of dollars
Change in projected benefit obligation

Projected benefit obligation at beginning of period

Service cost

Interest cost

Foreign currency exchange rate changes

Actuarial (gain) loss

Other

Benefits paid

Projected benefit obligation at end of period

Accumulated benefit obligation at end of period

2012

2011

—

(5)

1,660

115

(2)

(57)

1,862

81 $
—
4
—
8
—
(5)

88 $
88 $

1,538

(2)

(50)

1,660

Plan assets

Millions of dollars
Change in plan assets

Pension Benefits

United States

Int’l

United States

Int’l

2012

2011

Fair value of plan assets at beginning of period

1,354

Actual return on plan assets

Employer contributions

Foreign currency exchange rate changes

Benefits paid

Other

Fair value of plan assets at end of period

Funded status

Millions of dollars

Amounts recognized on the consolidated balance sheet

Noncurrent liabilities

—

(5)

—

(20) $

117

(57)

(2)

1,491

(371)

65 $
(2 )
6
—
(5 )
—
64 $
(24) $

1,286

(50)

(2)

1,354

(306)

United States

Int’l

United States

Int’l

2012

2011

(20) $

(371)

(24) $

(306)

Weighted-average assumptions used to determine benefit
obligations at measurement date

Discount rate

3.09%

4.50%

3.74%

4.90%

Assumed long-term rates of return on plan assets and discount rates for estimating benefit obligations vary for the different
plans according to the local economic conditions. The expected long-term rate of return on assets was determined by a stochastic
projection that takes into account asset allocation strategies, historical long-term performance of individual asset classes, an analysis
of additional return (net of fees) generated by active management, risks using standard deviations and correlations of returns among
the asset classes that comprise the plans’ asset mix. The discount rate used to determine the benefit obligations was determined
using a cash flow matching approach, which uses projected cash flows matched to spot rates along a high quality corporate yield
curve to determine the present value of cash flows to calculate a single equivalent discount rate. Because all plans have been
frozen, there is no rate of compensation increase.

Plan fiduciaries of the Company’s retirement plans set investment policies and strategies and oversee its investment
direction, which includes selecting investment managers, commissioning asset-liability studies and setting long-term strategic
targets. Long-term strategic investment objectives include preserving the funded status of the plan and balancing risk and return and
have a wide diversification of asset types, fund strategies and fund managers. Targeted asset allocation ranges are guidelines, not
limitations and occasionally plan fiduciaries will approve allocations above or below a target range.

107

During 2012, the plan fiduciaries for the Company's international plan implemented a new investment program taking into
account their distinct liabilities, liquidity needs and regulatory requirements. Under the new program, investments were reallocated
from a portfolio of equities and bonds to a more diversified mix of equities, bonds, real estate and other return seeking investments.
The goal of the program reflected in the 2013 targeted asset allocation is to maintain a reasonable long-term expected return for
plan assets while reducing underlying portfolio risk.

The target asset allocation for the International and Domestic plans for 2013 are as follows:

Target Allocation - Asset Class

Equity funds and securities

Fixed income funds and securities

Hedge funds

Real estate funds

Other

Total

2013 Targeted

Asset Allocation

International

Domestic

19%

56%

12%

100%

63%

37%

—

100%

The range of targeted asset allocations for the International plans for 2013 and 2012, by asset class, are as follows:

International Plans - Asset Class

Equity funds and securities

Fixed income funds and securities

Hedge funds

Real estate funds

Other

2013 Targeted

Percentage Range

2012 Targeted

Percentage Range

Minimum

Maximum

Minimum

Maximum

—

51%

100%

20%

10%

35%

56%

35%
—
—
—

61%

40%

—

The range of targeted asset allocations for the Domestic plans for 2013 and 2012, by asset class, are as follows:

Domestic Plans - Asset Class

Equity funds, securities and other

Fixed income funds and securities

2013 Targeted

Percentage Range

2012 Targeted

Percentage Range

Minimum

Maximum

Minimum

Maximum

51%

29%

76%

44%

51 %

29 %

77%

43%

108

ASC 820-10 addresses fair value measurements and disclosures, defining fair value, establishing a framework for using fair
value to measure assets and liabilities and expanding disclosures about fair value measurements. This standard applies whenever
other standards require or permit assets or liabilities to be measured at fair value. ASC 820-10 establishes a three-tier value
hierarchy, categorizing the inputs used to measure fair value. The inputs and methodology used for valuing securities are not an
indication of the risk associated with investing in those securities. The following is a description of the primary valuation
methodologies and classification used for assets measured at fair value.

Fair values of our Level 1 assets are based on observable inputs such as unadjusted quoted prices for identical assets or
liabilities in active markets. These consist of our Equity Securities valued at the closing price reported on the active market on
which the individual securities are traded and Equity and Fixed Income Funds, which have readily determinable or published net
asset values and may be liquidated in the near term without restrictions.

Fair values of our Level 2 assets are based on inputs other than the quoted prices in active markets that are observable either
directly or indirectly, such as quoted prices for similar assets or liabilities; quoted prices that are in inactive markets; inputs other
than quoted prices that are observable for the asset or liability; and inputs that are derived principally from or corroborated by
observable market data by correlation or other means. Our level 2 assets include Equity Funds and Fixed Income Funds, which are
valued using net asset values provided by the investment managers and may be liquidated at net asset value within 90 days without
restrictions.

Fair values of our Level 3 assets are based on unobservable inputs in which there is little or no market data and require us to
develop our own assumptions. Such funds are valued using net asset values provided by the investment managers, have inherent
liquidity restrictions that may affect our ability to sell the investment at its net asset value within 90 days or reflect funds with
lagged valuation data. A summary of total investments for KBR’s pension plan assets measured at fair value is presented below.

109

Millions of dollars
Asset Category at December 31, 2012
United States plan assets

Equity funds

Equity securities

Fixed income funds

Government bonds

Corporate bonds

Cash and cash equivalents

Total U.S. plan assets

International plan assets
Equity funds

Equity securities

Fixed income funds

Hedge funds

Real estate funds

Other funds

Cash and cash equivalents

Other

Total international plan assets

Total plan assets at December 31, 2012

Millions of dollars
Asset Category at December 31, 2011
United States plan assets

Equity funds

Equity securities

Fixed income funds

Government bonds

Corporate bonds

Cash and cash equivalents

Total U.S. plan assets

International plan assets
Equity funds

Equity securities

Fixed income funds

Government bonds

Corporate bonds

Hedge funds

Real estate funds

Other funds

Cash and cash equivalents

Other

Total international plan assets

Total plan assets at December 31, 2011

110

Fair Value Measurements at Reporting Date Using

Total

Level 1

Level 2

Level 3

357

784

115

110

—

410

—

1,491

1,562

557

608

6
—
—
4
9
1
20

263
1
330
27
35
57
2
—
715
735

—

219

Fair Value Measurements at Reporting Date Using

Total

Level 1

Level 2

Level 3

463

293

259

261

—

463

293

—

1,354

1,418

808

854

5
—
—
4
8
1
18

—
—
8
259
260
—
8
—
—
1
536
554

—

The fair value measurement of plan assets using significant unobservable inputs (level 3) changed each year due to the

following:

Level 3 fair value measurement rollforward

Millions of dollars
International plan assets

Balance at December 31, 2010 $

Purchases, sales and settlements

Balance at December 31, 2011 $
Return on assets held at end of
year
Purchases, sales and settlements

Foreign exchange impact
Balance at December 31, 2012 $

Total

Fixed Income
Funds

Hedge Funds

Real Estate
Funds

Other Funds

Other

(4)

198

219

—

—
—
—
1
25
1
27

—

(4)

—

(3)

—

The amounts in accumulated other comprehensive loss that have not yet been recognized as components of net periodic

benefit cost at December 31, 2012, net of tax were as follows:

Millions of dollars

Net actuarial loss, net of tax of $16 and $188, respectively

Total in accumulated other comprehensive loss

Expected cash flows

Pension Benefits

United States

Int’l

25 $
25 $

496

Contributions. Funding requirements for each plan are determined based on the local laws of the country where such plan
resides. In certain countries the funding requirements are mandatory while in other countries they are discretionary. We expect to
contribute $24 million to our international pension plans and $1 million to our domestic plan in 2013. We are in discussions with
the Trustees of our U.K. pension plan concerning the Plan's triennial valuation. At present, it is uncertain how the results of these
discussions will impact our future funding obligations.

111

Benefit payments. The following table presents the expected benefit payments over the next 10 years.

Millions of dollars

2013

2014

2015

2016

2017

Years 2018 – 2022

Net periodic cost

Pension Benefits

United States
6
7
7
7
8
26

Int’l

372

United States

Int’l

United States

Int’l

United States

Int’l

Pension Benefits

Millions of dollars
Components of net periodic benefit

Service cost

Interest cost

Expected return on plan assets

Recognized actuarial loss

Net periodic benefit cost

2012

— $
3
(4)

2
1 $

2011

— $

(93)

(4)

(98)

2010

—
4
(3)

1
2

(90)

Weighted-average assumptions used to
determine
net periodic benefit cost

Pension Benefits

Discount rate

Expected return on plan assets

United States

Int’l

United States

Int’l

United States

Int’l

2012

3.74%

7.00%

4.90%

6.60%

2011

4.84%

7.00%

5.45%

7.00%

2010

5.35%

7.00%

5.84%

7.00%

Estimated amounts that will be amortized from accumulated other comprehensive income, net of tax, into net periodic

benefit cost in 2013 are as follows:

Millions of dollars

Actuarial (gain) loss

Total

Note 18. Recent Accounting Pronouncements

Pension Benefits

United States
1
1

International

On February 5, 2013, the FASB issued Accounting Standards Update ("ASU") No. 2013-02, Reporting of Amounts
Reclassified Out of Accumulated Other Comprehensive Income. This ASU requires that companies present information about
reclassification adjustments from accumulated other comprehensive income in their annual financial statements in a single note or
on the face of the financial statements. ASU 2013-02 requires that companies present the effect of significant amounts reclassified
from each component of accumulated other comprehensive income based on its source and the income statement line items affected
by the reclassification. If a component is not required to be reclassified to net income in its entirety, companies would instead cross
reference to the related footnote for additional information. This may be presented either in the notes or parenthetically on the face
of the financial statements provided that all of the required information is presented in a single location. The requirements will take
effect for public companies in interim and annual reporting periods beginning after December 15, 2012. The adoption of ASU
2013-02 concerns disclosure only and is not expected to have a material impact on our financial position, results of operations and
cash flows.

In July 2012, the FASB issued ASU No. 2012-02, Intangibles - Goodwill and Other (ASC 350): Testing Indefinite-Lived
Intangible Assets for Impairment. ASU 2012-02 states that an entity has the option first to assess qualitative factors to determine
whether the existence of events and circumstances indicates that it is more likely than not that the indefinite-lived intangible asset is
impaired. If, after assessing the totality of events and circumstances, an entity concludes that it is not more likely than not that the

112

indefinite-lived intangible asset is impaired, then the entity is not required to take further action. An entity also has the option to
bypass the qualitative assessment for any indefinite-lived intangible asset in any period and proceed directly to performing the
quantitative impairment test. ASU 2012-02 is effective for annual and interim impairment tests performed for fiscal years
beginning after September 15, 2012, and early adoption is permitted. The adoption of this accounting standard is not expected to
have a material impact on our financial position, results of operations, cash flows and disclosures.

In September 2011, The FASB issued ASU No. 2011-08, Intangibles - Goodwill and Other (ASC 350): Testing Goodwill
for Impairment. ASU 2011-08 is intended to simplify how entities test goodwill for impairment. ASU 2011-08 permits an entity to
first assess qualitative factors to determine whether it is “more likely than not” that the fair value of a reporting unit is less than its
carrying amount as a basis for determining whether it is necessary to perform the two-step goodwill impairment test described in
Topic 350, Intangibles - Goodwill and Other. The more-likely-than-not threshold is defined as having a likelihood of more than
50%. ASU 2011-08 is effective for annual and interim goodwill impairment tests performed for fiscal years beginning after
December 15, 2011. The adoption of this accounting standard did not have a material impact on our financial position, results of
operations, cash flows and disclosures.

In June 2011, the FASB issued ASU No. 2011-05, Comprehensive Income (ASC 220): Presentation of Comprehensive
Income. This ASU allows an entity the option to present the total of comprehensive income, the components of net income and the
components of other comprehensive income either in a single continuous statement of comprehensive income or in two separate but
consecutive statements. In both choices, an entity is required to present each component of net income along with total net income,
each component of other comprehensive income along with a total for other comprehensive income and a total amount for
comprehensive income. ASU 2011-05 eliminates the option to present the components of other comprehensive income as part of
the statement of changes in stockholders’ equity. The amendments to the Codification in the ASU do not change the items that
must be reported in other comprehensive income or when an item of other comprehensive income must be reclassified to net
income. However, in December 2011, the FASB issued ASU 2011-12, Comprehensive Income (ASC 220): Deferral of the
Effective Date for Amendments to the Presentation of Reclassifications of Items Out of Accumulated Other Comprehensive Income
in Accounting Standards Update No. 2011-05, which deferred the guidance on whether to require entities to present reclassification
adjustments out of accumulated other comprehensive income by component in both the statement where net income is presented
and the statement where other comprehensive income is presented for both interim and annual financial statements. ASU 2011-12
reinstated the requirements for the presentation of reclassifications that were in place prior to the issuance of ASU 2011-05 and did
not change the effective date for ASU 2011-05. For public entities, the amendments in ASU 2011-05 and ASU 2011-12 are
effective for fiscal years and interim periods within those years, beginning after December 15, 2011, and should be applied
retrospectively. The adoption of this ASU concerns disclosure only and did not have a material impact on our consolidated
financial position, results of operations, cash flows and disclosures.

In May 2011, the FASB issued ASU No. 2011-04, Fair Value Measurement (ASC 820): Amendments to Achieve Common
Fair Value Measurement and Disclosure Requirements in U.S. GAAP and IFRSs. This ASU represents the converged guidance of
the FASB and the IASB (the Boards) on fair value measurement. The collective efforts of the Boards and their staffs, reflected in
ASU 2011-04, have resulted in common requirements for measuring fair value and for disclosing information about fair value
measurements, including a consistent meaning of the term “fair value.” The Boards have concluded the common requirements will
result in greater comparability of fair value measurements presented and disclosed in financial statements prepared in accordance
with U.S. GAAP and IFRSs. The amendments to the FASB Accounting Standards Codification (Codification) in this ASU are to
be applied prospectively. For public entities, the amendments are effective during interim and annual periods beginning after
December 15, 2011. The adoption of this ASU did not have a material impact on our financial position, results of operations, cash
flows and disclosures.

113

Note 19. Quarterly Data (Unaudited)

Summarized quarterly financial data for the years ended December 31, 2012 and 2011 are presented in the following table.
In the following table, the sum of basic and diluted “Net income attributable to KBR per share” for the four quarters may differ
from the annual amounts due to the required method of computing weighted average number of shares in the respective periods.
Additionally, due to the effect of rounding, the sum of the individual quarterly earnings per share amounts may not equal the
calculated year earnings per share amount.

(in millions, except per share amounts)
2012

Total revenue

Operating income

Net income (loss)

Net income attributable to noncontrolling interests

Net income (loss) attributable to KBR

Net income attributable to KBR per share :

First

Second

Third

Fourth

Year

2,001

2,062

1,992

112

(7)

129

112

(8)

104

(11)

(60)

(21)

(81)

1,866
69
52
(22)

7,921

299

202

(58)

144

Net income (loss) attributable to KBR per share—Basic

Net income (loss) attributable to KBR per share—Diluted $

0.61

0.70

(0.55) $

0.20
0.20

0.97

2011

Total revenue

Operating income

Net income

Net income attributable to noncontrolling interests

Net income attributable to KBR

Net income attributable to KBR per share :

2,321

2,457

2,387

144

117

(12)

105

169

127

(27)

100

138

191

(6)

185

2,096
136
105
(15)

9,261

587

540

(60)

480

Net income attributable to KBR per share—Basic

Net income attributable to KBR per share—Diluted

0.69

0.65

1.23

1.22

0.60

3.18

3.16

114

Item 9. Changes In and Disagreements with Accountants on Accounting and Financial Disclosures

None.

Item 9A. Controls and Procedures

Management’s Evaluation of Disclosure Controls and Procedures

In accordance with Rules 13a-15 and 15d-15 under the Securities and Exchange Act of 1934 as amended (the “Exchange
Act”), we carried out an evaluation, under the supervision and with the participation of management, including our Chief Executive
Officer and Chief Financial Officer, of the effectiveness of our disclosure controls and procedures as of the end of the period
covered by this report. Based on that evaluation, our Chief Executive Officer and Chief Financial Officer concluded that our
disclosure controls and procedures were effective as of December 31, 2012 to provide reasonable assurance that information
required to be disclosed in our reports filed or submitted under the Exchange Act is recorded, processed, summarized and reported
within the time periods specified in the Securities and Exchange Commission’s rules and forms. Our disclosure controls and
procedures include controls and procedures designed to ensure that information required to be disclosed in reports filed or
submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer
and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.

Changes in Internal Control Over Financial Reporting

There has been no change in our internal control over financial reporting that occurred during the three months ended
December 31, 2012 that have materially affected, or are reasonably likely to materially affect, the Company’s internal control over
financial reporting.

Management’s Annual Report on Internal Control Over Financial Reporting

Management is responsible for establishing and maintaining adequate internal control over financial reporting as defined in
the Securities Exchange Act Rule 13a-15(f). Internal control over financial reporting, no matter how well designed, has inherent
limitations. Therefore, even those systems determined to be effective can provide only reasonable assurance with respect to
financial statement preparation and presentation. Further, because of changes in conditions, the effectiveness of internal control
over financial reporting may vary over time.

Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief
Financial Officer, we conducted an evaluation to assess the effectiveness of our internal control over financial reporting as of
December 31, 2012, based upon criteria set forth in the Internal Control-Integrated Framework issued by the Committee of
Sponsoring Organizations of the Treadway Commission. Based on our assessment, we have concluded that, as of December 31,
2012, our internal control over financial reporting is effective. Our independent registered public accounting firm, KPMG LLP, has
issued its report on the effectiveness of our internal control over financial reporting as of December 31, 2012, which follows.

115

Report of Independent Registered Public Accounting Firm

The Board of Directors and Stockholders
KBR, Inc.:

We have audited KBR, Inc.’s internal control over financial reporting as of December 31, 2012, based on criteria established in
Internal Control - Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission
(COSO). KBR, Inc.’s management is responsible for maintaining effective internal control over financial reporting and for its
assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Annual
Report on Internal Control Over Financial Reporting. Our responsibility is to express an opinion on the Company’s internal control
over financial reporting based on our audit.

We conducted our audit in accordance with the standards of the Public Company Accounting Oversight Board (United States).
Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control
over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control
over financial reporting, assessing the risk that a material weakness exists and testing and evaluating the design and operating
effectiveness of internal control based on the assessed risk. Our audit also included performing such other procedures as we
considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.

A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability
of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted
accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain
to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of
the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial
statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are
being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable
assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that
could have a material effect on the financial statements.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also,
projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because
of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

In our opinion, KBR, Inc. maintained, in all material respects, effective internal control over financial reporting as of December 31,
2012, based on criteria established in Internal Control - Integrated Framework issued by the Committee of Sponsoring
Organizations of the Treadway Commission.

We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the
consolidated balance sheets of KBR, Inc. and subsidiaries as of December 31, 2012 and 2011, and the related consolidated
statements of income, comprehensive income, shareholders’ equity and cash flows for each of the years in the three-year period
ended December 31, 2012, and our report dated February 20, 2013 expressed an unqualified opinion on those consolidated financial
statements.

/s/ KPMG LLP

Houston, Texas
February 20, 2013

116

Item 9B. Other Information

None.

PART III

Item 10. Directors, Executive Officers and Corporate Governance

The information required by this Item is incorporated herein by reference to the KBR, Inc. Company Proxy Statement for

our 2013 Annual Meeting of Stockholders.

Item 11. Executive Compensation

The information required by this Item is incorporated herein by reference to the KBR, Inc. Company Proxy Statement for

our 2013 Annual Meeting of Stockholders.

Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

The information required by this Item is incorporated herein by reference to the KBR, Inc. Company Proxy Statement for

our 2013 Annual Meeting of Stockholders.

Item 13. Certain Relationships and Related Transactions, and Director Independence

The information required by this Item is incorporated herein by reference to the KBR, Inc. Company Proxy Statement for

our 2013 Annual Meeting of Stockholders.

Item 14. Principal Accounting Fees and Services

The information required by this Item is incorporated herein by reference to the KBR, Inc. Company Proxy Statement for

our 2013 Annual Meeting of Stockholders.

PART IV

Item 15. Exhibits and Financial Statement Schedules.

Financial Statements:
(a)

The report of the Independent Registered Public Accounting Firm and the financial
statements of the Company as required by Part II, Item 8, are included on page 62
and pages 63 through 114 of this annual report. See index on page 61.

Financial Statement Schedules:

(a)

(b)

KPMG LLP Report on supplemental schedule

Schedule II—Valuation and qualifying accounts for the three years ended
December 31, 2012

Note: All schedules not filed with this report required by Regulations S-X have been omitted as not
applicable or not required, or the information required has been included in the notes to financial
statements.

Page No.

121

122

Exhibits:

117

Exhibit
Number

Description

Agreement and Plan of Merger dated as of May 6, 2008, by and among KBR, Inc., BE&K, Inc., and Whitehawk Sub, Inc.,
(incorporated by reference to Exhibit 2.1 to KBR’s Current Report on Form 8-K; File No. 001-33416)

KBR Amended and Restated Certificate of Incorporation (incorporated by reference to Exhibit 3.1 to KBR’s current report
on Form 8-K filed June 7, 2012; Registration No. 333-133302)

Amended and Restated Bylaws of KBR, Inc. (incorporated by reference to Exhibit 99.1 Charter to KBR’s current report on
Form 8-K filed January 23, 2012; File No. 1-33146)

Form of specimen KBR common stock certificate (incorporated by reference to Exhibit 4.1 to KBR’s registration
statement on Form S-1; Registration No. 333-133302)

Master Separation Agreement between Halliburton Company and KBR, Inc. dated as of November 20, 2006 (incorporated
by reference to Exhibit 10.1 to KBR’s current report on Form 8-K dated November 20, 2006; File No. 001-33146)

Tax Sharing Agreement, dated as of January 1, 2006, by and between Halliburton Company, KBR Holdings, LLC and
KBR, Inc., as amended effective February 26, 2007 (incorporated by reference to Exhibit 10.2 to KBR’s Annual Report on
Form 10-K for the year ended December 31, 2006; File No. 001-33146)

Amended and Restated Registration Rights Agreement, dated as of February 26, 2007, between Halliburton Company and
KBR, Inc. (incorporated by reference to Exhibit 10.3 to KBR’s Annual Report on Form 10-K for the year ended December
31, 2006; File No. 001-33146)

Transition Services Agreement dated as of November 20, 2006, by and between Halliburton Energy Services, Inc. and
KBR, Inc. (KBR as service provider) (incorporated by reference to Exhibit 10.4 to KBR’s current report on Form 8-K
dated November 20, 2006; File No. 001-33146)

Transition Services Agreement dated as of November 20, 2006, by and between Halliburton Energy Services, Inc. and
KBR, Inc. (Halliburton as service provider) (incorporated by reference to Exhibit 10.5 to KBR’s current report on Form 8-
K dated November 20, 2006; File No. 001-33146)

Employee Matters Agreement dated as of November 20, 2006, by and between Halliburton Company and KBR, Inc.
(incorporated by reference to Exhibit 10.6 to KBR’s current report on Form 8-K dated November 20, 2006; File No. 001-
33146)

Intellectual Property Matters Agreement dated as of November 20, 2006, by and between Halliburton Company and KBR,
Inc. (incorporated by reference to Exhibit 10.7 to KBR’s current report on Form 8-K dated November 20, 2006; File No.
001-33146)

Form of Indemnification Agreement between KBR, Inc. and its directors (incorporated by reference to Exhibit 10.18 to
KBR’s registration statement on Form S-1; Registration No. 333-133302)

KBR, Inc. 2006 Stock and Incentive Plan (As Amended and Restated March 7, 2012) (incorporated by reference to KBR's
definitive Proxy Statement dated April 5, 2012; File No. 1-33146)

KBR, Inc. Senior Executive Performance Pay Plan (incorporated by reference to Exhibit 10.21 to KBR’s Form 10-K for
the fiscal year ended December 31, 2006; File No. 1-33146)

KBR, Inc. Management Performance Pay Plan (incorporated by reference to Exhibit 10.22 to KBR’s Form 10-K for the
fiscal year ended December 31, 2006; File No. 1-33146)

KBR, Inc. Transitional Stock Adjustment Plan (incorporated by reference to Exhibit 10.23 to KBR’s Form 10-K for the
fiscal year ended December 31, 2006; File No. 1-33146)

KBR Dresser Deferred Compensation Plan (incorporated by reference to Exhibit 4.5 to KBR’s Registration Statement on
Form S-8 filed on April 13, 2007)

KBR Supplemental Executive Retirement Plan (incorporated by reference to Exhibit 10.3 to KBR’s current report on Form
8-K dated April 9, 2007; File No. 1-33146).

KBR Benefit Restoration Plan (incorporated by reference to Exhibit 10.4 to KBR’s current report on Form 8-K dated April
9, 2007; File No. 1-33146).

2.1

3.1

3.2

4.1

10.1

10.2

10.3

10.4

10.5

10.6

10.7

10.8

10.9+

10.10+

10.11+

10.12+

10.13+

10.14+

10.15+

118

Exhibit
Number

10.16+

10.17+

10.18+

10.19+

10.20+

10.21+

10.22+

10.23+

10.24+

10.25*

10.26+

10.27

10.28+

10.29+

10.30+

10.31+

10.32+

10.33+

10.34+

Description

KBR Elective Deferral Plan (incorporated by reference to Exhibit 10.5 to KBR’s current report on Form 8-K dated April 9,
2007; File No. 1-33146).

Restricted Stock Unit Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan (incorporated by reference to
Exhibit 10.2 to KBR’s Form 10-Q for the quarter ended June 30, 2007; File No. 1-33146)

Stock Option Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan (incorporated by reference to Exhibit 10.3
to KBR’s Form 10-Q for the quarter ended June 30, 2007; File No. 1-33146)

KBR Restricted Stock Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan (incorporated by reference to
Exhibit 10.4 to KBR’s Form 10-Q for the quarter ended June 30, 2007; File No. 1-33146)

KBR, Inc. Transitional Stock Adjustment Plan Stock Option Award (incorporated by reference to Exhibit 10.5 to KBR’s
Form 10-Q for the quarter ended June 30, 2007; File No. 1-33146)

KBR, Inc. Transitional Stock Adjustment Plan Restricted Stock Award (incorporated by reference to Exhibit 10.6 to
KBR’s Form 10-Q for the quarter ended June 30, 2007; File No. 1-33146)

Form of Restricted Stock Agreement between KBR, Inc. and William P. Utt pursuant to KBR, Inc. 2006 Stock and
Incentive Plan (incorporated by reference to Exhibit 10.1 to KBR’s Form 10-Q for the quarter ended September 30, 2007;
File No. 1-33146)

Form of KBR Performance Award Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan (incorporated by
reference to Exhibit 10.5 to KBR’s Form 10-Q for the quarter ended September 30, 2007; File No. 1-33146)

Form of revised KBR Performance Award Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan (incorporated
by reference to Exhibit 10.25 to KBR’s Form 10-K for the year ended December 31, 2010; File No. 1-33146).
Form of revised KBR Performance Award Agreement pursuant to KBR, Inc. 2006 Stock and Incentive Plan.

Form of Severance and Change in Control Agreement (incorporated by reference to Exhibit 10.1 to KBR’s Form 10-Q for
the quarter ended September 30, 2008; File No. 1-33146)

Five Year Revolving Credit Agreement dated as of December 2, 2011 among KBR, Inc., the Banks party thereto, The
Royal Bank of Scotland PLC, as Syndication Agent, ING Bank, N.V. and The Bank of Nova Scotia, as Co-Documentation
Agents, Citigroup Global Markets Inc., RBS Securities Inc. ING Bank, N.V., and The Bank of Nova Scotia as Joint Lead
Arrangers and Bookrunners, and Citibank, N.A., as Administrative Agent. (incorporated by reference to Exhibit 10.1 to
KBR’s current report on Form 8-K dated December 7, 2011; File No. 1-33146)

Severance and Change of Control Agreement, between KBR Technical Services, Inc., a Delaware corporation, KBR, Inc.,
and Susan K. Carter (incorporated by reference to Exhibit 10.1 to KBR’s current report on Form 8-K dated October 26,
2009; File No. 1-33146)

Severance and Change of Control Agreement, between KBR Technical Services, Inc., a Delaware corporation, KBR, Inc.,
and Mark S. Williams (incorporated by reference to Exhibit 10.1 to KBR’s current report on Form 8-K dated January 18,
2010; File No. 1-33416)

Severance and Change of Control Agreement (incorporated by reference to Exhibit 10.1 to KBR’s current report on Form
8-K dated August 16, 2010, by and between KBR Technical Services, Inc., a Delaware corporation, KBR, Inc., and Dennis
S. Baldwin; File No. 1-33146)

Severance and Change of Control Agreement effective as of December 31, 2008, by and between KBR Technical Services,
Inc., a Delaware corporation, KBR, Inc., and William P. Utt (incorporated by reference to Exhibit 10.7 to KBR's current
report on Form 8-K dated January 7, 2009; File No. 1-33146.

Severance and Change of Control Agreement effective as of August 26, 2008, by and between KBR Technical Services,
Inc., a Delaware corporation, KBR, Inc., and John L. Rose; File No. 1-33146.

Severance and Change of Control Agreement effective as of August 26, 2008, by and between KBR Technical Services,
Inc., a Delaware corporation, KBR, Inc., and Andrew D. Farley; File No. 1-33146.

Severance and Change of Control Agreement effective as of August 26, 2008, by and between KBR Technical Services,
Inc., a Delaware corporation, KBR, Inc., and David L. Zimmerman; File No. 1-33146.

119

Exhibit
Number

10.35+

10.36+

10.37+

10.38*

*21.1

*23.1

*31.1

*31.2

**32.1

**32.2

Description

Amendment to the 2008 Severance and Change in Control Agreements effective as of December 31, 2008; File No. 1-
33146.

Amendment to the Severance and Change in Control Agreement with Susan K. Carter effective as of January 15, 2010;
File No. 1-33146.

Severance and Change of Control Agreement effective as of July 9, 2012, by and between KBR Technical Services, Inc., a
Delaware corporation, KBR, Inc., and Ivor Harrington (incorporated by reference to Exhibit 10.1 to KBR's current report
on Form 8-K dated July 12, 2012; File No. 1-33146)

Severance and Change of Control Agreement effective as of December 11, 2011, by and between KBR Technical Services,
Inc., a Delaware corporation, KBR, Inc., and Roy Oelking; File No. 1-33146.

List of subsidiaries

Consent of KPMG LLP—Houston, Texas

Certification by Chief Executive Officer Pursuant to Rule 13a-14(a)/15d-14(a).

Certification by Chief Financial Officer Pursuant to Rule 13a-14(a)/15d-14(a).

Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act
of 2002.

***101.INS

XBRL Instance Document

***101.SCH

XBRL Taxonomy Extension Schema Document

***101.CAL

XBRL Taxonomy Extension Calculation Linkbase Document

***101.DEF

XBRL Taxonomy Extension Definition Linkbase Document

*** 101.LAB

XBRL Taxonomy Extension Labels Linkbase Document

*** 101.PRE

XBRL Taxonomy Extension Presentation Linkbase Document

***

Filed with this Form 10-K

Furnished with this Form 10-K

Submitted pursuant to Rule 405 and 406T of Regulation S-T.

Management contracts or compensatory plans or arrangements

120

Report of Independent Registered Public Accounting Firm

The Board of Directors and Stockholders
KBR, Inc.:

Under date of February 20, 2013, we reported on the consolidated balance sheets of KBR, Inc. and subsidiaries as of December 31,
2012 and 2011, and the related consolidated statements of income, comprehensive income, shareholders’ equity, and cash flows for
each of the years in the three-year period ended December 31, 2012, contained in the annual report on Form 10-K for the year 2012.
In connection with our audits of the aforementioned consolidated financial statements, we also audited the related consolidated
financial statement schedule as listed in the accompanying index. The financial statement schedule is the responsibility of the
Company’s management. Our responsibility is to express an opinion on the financial statement schedule based on our audits.

In our opinion, such financial statement schedule, when considered in relation to the basic consolidated financial statements taken
as a whole, presents fairly, in all material respects, the information set forth therein.

/s/ KPMG LLP

Houston, Texas

February 20, 2013

121

KBR, Inc.
Schedule II—Valuation and Qualifying Accounts (Millions of Dollars)

The table below presents valuation and qualifying accounts for continuing operations.

Descriptions
Year ended December 31, 2012:

Deducted from accounts and notes receivable:

Allowance for bad debts

Reserve for losses on uncompleted contracts

Reserve for potentially disallowable costs
incurred under government contracts

Year ended December 31, 2011:

Deducted from accounts and notes receivable:

Allowance for bad debts

Reserve for losses on uncompleted contracts

Reserve for potentially disallowable costs
incurred under government contracts

Year ended December 31, 2010:

Deducted from accounts and notes receivable:

Allowance for bad debts

Reserve for losses on uncompleted contracts

Reserve for potentially disallowable costs
incurred under government contracts

Additions

Balance at
Beginning
Period

Charged to
Costs and
Expenses

Charged to
Other
Accounts

Deductions

Balance at
End of Period

127

141

116

—

$(15)(a) $

(19)

$5(b) $

(10)

122

(2) $

—

$(1)(a) $

(17)

—

$22(b) $

(36)

127

—

$(12)(a) $

(15)

$34(b) $

(9)

141

(a) Receivable write-offs, net of recoveries, and reclassifications.
(b) Reserves have been recorded as reductions of revenue, net of reserves no longer required.

122

SIGNATURES

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the registrant has duly caused

this report to be signed on its behalf by the undersigned, thereunto duly authorized.

Dated: February 20, 2013

KBR, INC.

By:

Dated: February 20, 2013

/s/ William P. Utt

William P. Utt
President and Chief Executive Officer

Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below by the following

persons on behalf of the registrant and in the capacities and on the dates indicated:

Signature

/s/ William P. Utt

William P. Utt

/s/ Susan K. Carter

Susan K. Carter

/s/ Dennis Baldwin

Dennis Baldwin

/s/ W. Frank Blount

W. Frank Blount

/s/ Loren K. Carroll

Loren K. Carroll

/s/ Linda Z. Cook

Linda Z. Cook

/s/ Jeffrey E. Curtiss

Jeffrey E. Curtiss

/s/ John R. Huff

John R. Huff

/s/ Lester L. Lyles

Lester L. Lyles

/s/ Richard J. Slater

Richard J. Slater

/s/ Jack B. Moore

Jack B. Moore

Title

President, Chief Executive Officer and Director

(Principal Executive Officer)

Executive Vice President and Chief Financial Officer

(Principal Financial Officer)

Senior Vice President and Chief Accounting Officer

(Principal Accounting Officer)

Director

123

EXHIBIT INDEX