More annual reports from Sterling Infrastructure:
2023 ReportPeers and competitors of Sterling Infrastructure:
Aegion Corp2 1 0 2 , 1 3 r e b m e c e D d e d n e r a e y e h t r o f t r o p e R l a u n n A Dear Shareholders, Last September, I was elected Chief Executive officer of Sterling Construction Company, Inc. My history of over 25 years of civil construction experience, which includes 14 years as President and CEO of various operating units for Skanska, has prepared me to take the leadership of this company and continue to grow its capabilities. Since being elected, I have begun the process of integrating our operating units into a cohesive group. Peter E. MacKenna President & CEO Financial Results In 2012, revenue climbed to $630.5 million, demonstrating a 25.8% growth compared with fiscal 2011. We have emerged from the past couple of recession years in a strong financial position. At December 31, 2012 working capital totaled $87.5 million, including $52.4 million of cash, cash equivalents and short term investments, and a tangible net worth of $157.8 million that is more than adequate to support our bonding requirements. The total 2012 contract awards (excluding acquired contracts) were $643 million, an increase of 8% over total 2011 awards. Gross margin increased in the fourth quarter to 10.3% up from 3.4% over the same period in 2011 resulting in gross margin for all of 2012 of 7.5%. People I would like to thank Patrick Manning and Joseph Harper, Sr. for their 40 years of outstanding service to our company. Through their leadership and vision, Sterling has grown into a successful, well‐capitalized, geographically‐diverse heavy civil construction company. We are fortunate that Joe and Pat have agreed to remain on the Board so that Sterling will continue to benefit from their experience, insights and practical wisdom. I have promoted our Human Resources Director to Senior Vice President and Chief Human Resources Officer and have added the positions of Chief Information Officer and Director of IT Operations. The newly formed IT positions will manage the IT infrastructure and systems, improving measurement, and focusing on process improvement. Growth In 2011 we added the capabilities of J. Banicki Construction, Inc. (“JBC”) in Arizona and acquired a 50% interest in Myers & Sons Construction, L.P. in California, and in 2012 we had the benefit of a full year's earning contribution from these companies. Both companies added to our earnings and backlog, with our subsidiary, Ralph L. Wadsworth Construction Company, LLC (“RLW”), winning a $71 million job in a Joint Venture with JBC, and with Myers & Sons winning an $88 million job from the California Department of Transportation. Our solid financial position affords us the ability to target more acquisitions that will expand or deepen our geographic penetration in attractive regions, and provide us with increased capabilities in markets outside but adjacent to our traditional heavy highway focus. Consolidation and Integration On December 31, 2012 Sterling made an early exercise of its option under a December 2009 purchase agreement and purchased the remaining 20% membership interest in RLW that was previously held by RLW’s executive management. Sterling further retained the continued services of RLW’s CEO, its President, and its Vice President of Business Development under new employment agreements. This will provide for the operational continuity of RLW and a stable platform for organic growth and further integration of our operating units. Our immediate focus on integration involves creating a financial shared service within Sterling to ensure that our policies, processes, procedures and structure fully support our construction operations. In 2013 we are introducing Project Evergreen; this project will focus on reviewing our key financial operations and making appropriate consolidation, integration and efficiency improvements. Markets and Outlook Since joining Sterling in September 2012, I’ve become increasingly optimistic about the opportunities in front of us. While highway funding and political gridlock are outside of our control, we have made enhancements to our operations that should yield improving performance over time. We anticipate limited organic revenue growth in 2013 as government funding remains constrained. Based on our current estimates, the average gross margin of projects in our backlog is below the 7.5% gross margin achieved on 2012. As the year progresses and these projects are completed, we anticipate improvement in margins. For 2013, SG&A as a percent of revenues should be comparable to 2012. Our current budget anticipates capital expenditures to return to 2011 levels. Looking out over the next several years, we believe we can leverage our current fleet, along with leased assets to achieve significantly higher revenues. Strategy and Objectives As we continue in 2013, our operating units are focused on achieving the following objectives: Extend our construction service capabilities Expand into new markets and selectively pursue opportunities Apply core competencies and best practices across our platform Increase market leadership in core geographic markets Position our business for future infrastructure spending Optimize operations through implementation of systems, processes, policies and the addition of key personnel Continue to attract, retain and develop our employees Our company continues its proud past with a focus on safety and quality and looks forward to a successful future. On behalf of our over 1,600 employees, I would like to thank our shareholders for their continued support. Peter E. MacKenna President & Chief Executive Officer March 28, 2013 UNITED STATES SECURITIES AND EXCHANGE COMMISSION Washington, D.C. 20549 FORM 10-K [X] ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 For the fiscal year ended: December 31, 2012 [ ] TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 For the transition period from _______________________to ________________________________ Commission file number 1-31993 STERLING CONSTRUCTION COMPANY, INC. (Exact name of registrant as specified in its charter) Delaware State or other jurisdiction of incorporation or organization 20810 Fernbush Lane Houston, Texas (Address of principal executive offices) 25-1655321 (I.R.S. Employer Identification No.) 77073 (Zip Code) Registrant’s telephone number, including area code (281) 821-9091 Securities registered pursuant to Section 12(b) of the Act: Title of each class Common Stock, $0.01 par value per share (Title of Class) Name of each exchange on which registered The NASDAQ Stock Market LLC Securities registered pursuant to section 12(g) of the Act: None Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. [ ] Yes [√] No Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. [ ] Yes [√] No Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. [√] Yes [ ] No Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter prior that the registrant was required to submit and post such files). [√] ] Yes [ ] No Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K [ ] Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. Large accelerated filer [ ] Accelerated filer [√] Non-accelerated filer [ ] (Do not check if a smaller reporting company) Smaller reporting company [ ] Indicate by check mark if the registrant is a shell company (as defined in Rule 12b-2 of the Act). [ ] Yes [√] No Aggregate market value of the voting and non-voting common equity held by non-affiliates at June 30, 2012: $154,195,017. At March 6, 2013, the registrant had 16,602,034 shares of common stock outstanding. DOCUMENTS INCORPORATED BY REFERENCE Portions of the Company’s definitive Proxy Statement to be filed with the Securities and Exchange Commission and delivered to stockholders in connection with the Annual Meeting of Stockholders to be held on May 9, 2013 are incorporated by reference into Part III of this Form 10-K. STERLING CONSTRUCTION COMPANY, INC. ANNUAL REPORT ON FORM 10-K TABLE OF CONTENTS PART I PART II PART III PART IV Cautionary Comment Regarding Forward-Looking Statements ......................................... Item 1. Business .............................................................................................................................. Item 1A. Risk Factors ........................................................................................................................ Item 1B. Unresolved Staff Comments ............................................................................................... Item 2. Properties ............................................................................................................................ Item 3. Legal Proceedings ............................................................................................................... Item 4. Mine Safety Disclosures ..................................................................................................... Item 5. Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities ........................................................................................... Item 6. Selected Financial Data ...................................................................................................... Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operation ............................................................................................................................ Item 7A. Quantitative and Qualitative Disclosures About Market Risk ............................................ Item 8. Financial Statements and Supplementary Data ................................................................... Item 9. Changes in and Disagreements With Accountants on Accounting and Financial Disclosure ........................................................................................................................... Item 9A. Controls and Procedures ..................................................................................................... Item 9B. Other Information ............................................................................................................... Item 10. Directors , Executive Officers and Corporate Governance ................................................ Item 11. Executive Compensation .................................................................................................... Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters ............................................................................................................ Item 13. Certain Relationships and Related Transactions, and Director Independence .................... Item 14. Principal Accounting Fees and Services ............................................................................. Item 15. Exhibits and Financial Statement Schedules ...................................................................... Financial Statements ........................................................................................................... Exhibits ............................................................................................................................... Signatures ........................................................................................................................... 3 4 13 20 20 21 21 22 24 25 35 35 35 36 37 37 37 37 37 38 38 38 38 41 2 PART I Cautionary Comment Regarding Forward-Looking Statements This Report includes statements that are, or may be considered to be, “forward-looking statements” within the meaning of Section 27A of the Securities Act of 1933, as amended, or the Securities Act, and Section 21E of the Securities Exchange Act of 1934, as amended, or the Exchange Act. These forward-looking statements are included throughout this Report, including in the sections entitled “Business,” “Risk Factors,” and “Management’s Discussion and Analysis of Financial Condition and Results of Operations” and relate to matters such as our industry, business strategy, goals and expectations concerning our market position, future operations, margins, profitability, capital expenditures, liquidity and capital resources and other financial and operating information. We have used the words “anticipate,” “assume,” “believe,” “budget,” “continue,” “could,” “estimate,” “expect,” “forecast,” “future,” “intend,” “may,” “plan,” “potential,” “predict,” “project,” “should,” “will,” “would” and similar terms and phrases to identify forward-looking statements in this Report. Forward-looking statements reflect our current expectations as of the date of this Report regarding future events, results or outcomes. These expectations may or may not be realized. Some of these expectations may be based upon assumptions or judgments that prove to be incorrect. In addition, our business and operations involve numerous risks and uncertainties, many of which are beyond our control, that could result in our expectations not being realized or otherwise could materially affect our financial condition, results of operations and cash flows. Actual events, results and outcomes may differ materially from our expectations due to a variety of factors. Although it is not possible to identify all of these factors, they include, among others, the following: changes in general economic conditions, including recessions, reductions in federal, state and local government funding for infrastructure services and changes in those governments’ budgets, practices, laws and regulations; delays or difficulties related to the completion of our projects, including additional costs, reductions in revenues or the payment of liquidated damages, or delays or difficulties related to obtaining required governmental permits and approvals; actions of suppliers, subcontractors, design engineers, joint venture partners, customers, competitors, banks, surety companies and others which are beyond our control, including suppliers’, subcontractors, and joint venture partners’ failure to perform; the effects of estimates inherent in our percentage-of-completion accounting policies, including onsite conditions that differ materially from those assumed in our original bid, contract modifications, mechanical problems with our machinery or equipment and effects of other risks discussed in this document; design/build contracts which subject us to the risk of design errors and omissions; cost escalations associated with our contracts, including changes in availability, proximity and cost of materials such as steel, cement, concrete, aggregates, oil, fuel and other construction materials, and cost escalations associated with subcontractors and labor; our dependence on a limited number of significant customers; adverse weather conditions; although we prepare our budgets and bid contracts based on historical rain and snowfall patterns, the incidence of rain, snow, hurricanes, etc., may differ materially from these expectations; the presence of competitors with greater financial resources or lower margin requirements than ours, and the impact of competitive bidders on our ability to obtain new backlog at reasonable margins acceptable to us; our ability to successfully identify, finance, complete and integrate acquisitions; citations Administration; federal, state and local environmental laws and regulations non-compliance can result in penalties and/or termination of contracts as well as civil and criminal liability; the instability of certain financial institutions, which could cause losses on our cash and cash equivalents and short-term investments; adverse economic conditions in our markets; and the other factors discussed in more detail in Item 1A. —Risk Factors. issued by any governmental authority, the Occupational Safety and Health including In reading this Report, you should consider these factors carefully in evaluating any forward-looking statements and you are cautioned not to place undue reliance on any forward-looking statements. Although we believe that our plans, intentions and expectations reflected in, or suggested by, the forward-looking statements that we make in this Report are reasonable, we can provide no assurance that they will be achieved. 3 The forward-looking statements included in this Report are made only as of the date of this Report, and we undertake no obligation to update any information contained in this Report or to publicly release the results of any revisions to any forward-looking statements to reflect events or circumstances that occur, or that we become aware of after the date of this Report, except as may be required by applicable securities laws. Item 1. Business. Overview of the Company’s Business. Sterling Construction Company, Inc. was founded in 1991 as a Delaware corporation. Our principal executive offices are located at 20810 Fernbush Lane, Houston, Texas 77073, and our telephone number at this address is (281) 821-9091. Our construction business was founded in 1955 by a predecessor company in Michigan and is now conducted through our subsidiaries which primarily include: Texas Sterling Construction Co., a Delaware corporation, or “TSC”; Road and Highway Builders, LLC, a Nevada limited liability company, or “RHB”; Road and Highway Builders of California, Inc., a California corporation, or “RHBCa”; Ralph L. Wadsworth Construction Company, LLC, a Utah limited liability company, or “RLW”; J. Banicki Construction, Inc., an Arizona corporation, or “JBC”; and Myers & Sons Construction, L.P., a California limited partnership, or “Myers”. The terms “Company,” “Sterling,” and “we” refer to Sterling Construction Company, Inc. and its subsidiaries except when it is clear that those terms mean only the parent company or a particular subsidiary. Sterling is a leading heavy civil construction company that specializes in the building and reconstruction of transportation and water infrastructure projects in Texas, Utah, Nevada, Arizona, California and other states where there are construction opportunities. Its transportation infrastructure projects include highways, roads, bridges and light rail and its water infrastructure projects include water, wastewater and storm drainage systems. Sterling performs the majority of the work required by its contracts with its own crews and equipment. Although we describe our business in this report in terms of the services we provide, our base of customers and the geographic areas in which we operate, we have concluded that our operations comprise one reportable segment and one reporting unit component: heavy civil infrastructure construction. In making this determination, we considered that each project has similar characteristics, includes similar services and similar types of customers and is subject to similar regulatory and economic environments. We organize, evaluate and manage our financial information around each project when making operating decisions and assessing our overall performance. Sterling has grown its service profile and geographic reach both organically and through acquisitions. Expansions into Utah, Arizona and California were achieved with the 2009 acquisition of RLW and the 2011 acquisitions of JBC and Myers, respectively. These acquisitions also extended Sterling’s service profiles. Recent Developments. Financial Results for 2012, Operational Issues and Outlook for 2013 Financial Results. As was the case in 2011, the Company’s 2012 results were adversely affected by production issues on a number of construction projects. In 2012, the Company had operating income of $15.0 million and net loss attributable to Sterling common stockholders of $297,000. Included in the net loss attributable to Sterling common stockholders for 2012 is additional earnings allocated to noncontrolling interest owners of $6.7 million, or $4.3 million net of tax, resulting from an amendment to the RLW operating agreement to change the treatment of goodwill impairments for purposes of determining net income distributable to RLW’s members. This is discussed further in Note 2 to the Consolidated Financial Statements. Our gross margins have decreased to 7.5% in 2012 from 8.0% in 2011 and 13.6% in 2010. In 2012, our gross margins continued to be adversely impacted by downward revisions to estimated profitability on certain projects. The majority of our revenues and backlog is derived from fixed unit price contracts. Some of our revenues are derived from lump sum contracts. Fixed unit price contracts require us to provide materials and services at a fixed unit price based on approved quantities irrespective of our actual per unit costs. Lump sum contracts require that the total amount of work be performed for a single price irrespective of our actual costs. As discussed in “Item 1A. Risk Factors,” we realize a profit on our contracts only if we accurately estimate our costs and then successfully control actual costs and avoid cost overruns, and our revenues exceed actual costs. If our cost estimates for a contract are inaccurate, or if we do not execute the contract within our cost estimates, then cost overruns may cause the contract not to be as profitable as we expected or result in a loss, negatively affecting our cash flow, earnings and financial position. While the risks of cost overruns and changes in estimated contract revenues are an inherent part of the construction business, during 2012 we implemented the following changes in order to improve the profitability of our 4 projects, reduce the variability in profitability of our projects in the future and strengthen the internal control environment: changed roles and responsibilities to improve functional support and controls; developed management tools designed to improve the estimating process and increase the oversight of that process; implemented processes designed to better identify, evaluate and quantify risks for individual projects; improved the methodologies for allocating overhead, indirect costs and equipment costs to individual projects; and improved the timeliness and content of reporting available to operations management. In addition to the factors discussed above which impact the profitability on individual projects, there are other factors which have adversely affected our ability to secure construction projects at favorable margins. Our highway and related bridge work is generally funded through federal and state authorizations. The federal government enacted the SAFETEA-LU bill in 2005, which authorized $244 billion for transportation spending through 2009. The SAFETEA-LU bill expired on September 30, 2009, and the federal government enacted a number of extensions on an interim basis, most recently through June 30, 2012. In July 2012, the federal government enacted the Moving Ahead for Progress in the 21st Century (“MAP-21”) legislation: a two-year, $105 billion reauthorization of the federal surface transportation program. This legislation maintains annual federal highway spending close to the previous level of $41 billion under the SAFETEA-LU bill. While we believe that a longer term bill is needed, the new bill does alleviate some of the uncertainty which has adversely affected the levels of transportation and water infrastructure capital expenditures in our markets, reduced opportunities to replace backlog at reasonable margins and increased competition for new projects. While we expect that implementation of the internal changes discussed above will improve profitability in the future, we are not expecting a significant improvement in gross margins for 2013. In addition, we expect continued pressure on our gross margins on new contract awards. Senior Management Team. Peter MacKenna joined the Company in September 2012 and serves as its President & Chief Executive Officer. Patrick Manning, the Company’s previous Chief Executive Officer, continues to serve as the Chairman of the Board of Directors. As planned, Joseph P. Harper, Sr., who has served as the Company’s President and Chief Operating Officer and Treasurer, retired in December 2012 and continues to serve as a director. Our Business Strategy. Key features of our business strategy include: Continue to add construction capabilities: by adding capabilities that augment our core contracting and construction competencies, we are able to improve gross margin opportunities, and more effectively compete for contracts that might not otherwise be available to us. Expand into new markets and selectively pursue opportunities and strategic acquisitions: we will continue to seek to identify attractive new markets and opportunities in select western, southwestern and southeastern U.S. areas. We will also continue to assess opportunities to extend our service capabilities and expand our markets through acquisitions. Apply core competencies across our markets: we will seek to capitalize on opportunities to export our Texas experience constructing water infrastructure projects and our Nevada earthmoving, aggregates and asphalt paving experience into Utah markets. Similarly, we believe that RLW’s experience with design-build, construction manager and general contractor (“CM/GC”) and other alternative project delivery methods in Utah, and its development of accelerated bridge construction (“ABC”) techniques can enhance opportunities for us in our Texas, California, Arizona and Nevada markets. Increase our market leadership in our core markets: we have a strong presence in a number of markets in Texas, Utah and Nevada and intend to expand our presence in these states as well as Arizona, California, Hawaii and other states where we believe opportunities exist. Position our business for future infrastructure spending: currently there are considerable uncertainties surrounding federal, state and local funding in our markets; however, we believe there is awareness of the need to build, reconstruct and repair our country’s infrastructure, including transportation infrastructure, such as bridges, highways, and mass transit systems and water infrastructure, such as water, wastewater and storm drainage systems. We will continue to build our expertise to capture this infrastructure spending. We also see opportunities to make enhancements to our operations that should yield improving performance 5 over time. These include a tighter integration of the acquisitions we have made over the past several years which should result in cost reductions and better collaboration between business units when pursuing new contract opportunities. Continue to attract, retain and develop our employees: we believe that our employees are key to the successful implementation of our business strategy, and we will continue allocating significant resources in order to attract and retain talented managers and supervisory and field personnel. Our Markets, Competition and Customers. Although we occasionally undertake contracts for private customers, the vast majority of our revenues are attributable to work for public sector customers. The majority of the services provided to these customers are pursuant to contracts awarded through competitive bidding processes. Demand for transportation and water infrastructure depends on a variety of factors, including overall population growth, economic expansion and the vitality of the market areas in which we operate, as well as unique local topographical, structural and environmental issues. In addition to these factors, demand for the replacement of infrastructure is driven by the general aging of infrastructure and the need for technical improvements to achieve more efficient or safer use of infrastructure and resources. Funding for this infrastructure depends on federal, state and local governmental resources, budgets and authorizations. Our competitors include companies that we bid against for construction contracts and compete against for short listings, mandates and joint ventures. We have many competitors of different sizes in all of the markets that we serve, and they include large international, national and regional construction companies as well as many smaller contractors. Historically, the construction business has not typically required large amounts of capital for smaller contracts, which can result in relative ease of market entry for companies possessing acceptable qualifications. Factors influencing our competitiveness include price, our reputation for quality, our innovativeness, our equipment fleet, our work crews, our financial strength, our bonding capacity and prequalification criteria, our knowledge of local markets and conditions, our project management and estimating abilities, our customer relationships, our marketing abilities, our ability to enter into strategic relationships with other contractors and our ability to perform many aspects of each project. Although some of our competitors are larger than we are and may possess greater resources or provide more vertically-integrated services, we believe that we are well-positioned to compete in the markets in which we operate on the basis of the foregoing factors. Based on publicly available information on awarded construction projects, we believe that we are one of the larger participants in each of our Texas, Utah and Nevada markets. Because we own and maintain most of the equipment required for our contracts and have the key experienced workforce to handle many types of heavy civil construction, we are able to bid competitively on many categories of contracts, especially complex, multi-task projects. In the state highway markets, most of our competitors are large international, national and regional contractors, and individual contracts tend to be larger and require more specialized skills than those in the municipal markets. Some of these competitors have the advantage of being more vertically-integrated, or they specialize in certain types of projects such as construction over water. Since 2008, our markets have been much more competitive than in the past because of reductions in federal, state and local spending on transportation and water-related infrastructure; bidding by our traditional competitors at what appears to have been break-even or loss margins; the entry of new competitors from other states and the expansion of foreign competitors into our markets. While our business includes only minimal residential and commercial infrastructure work, the severe fall-off in new projects in those markets has resulted in some residential and commercial infrastructure contractors bidding on smaller public sector transportation and water infrastructure projects, sometimes at bid levels below our break-even pricing, thus increasing competition and creating downward pressure on the bid prices in our markets. These factors have compressed the profitability on many new projects where we submitted successful bids. The nationwide decline in home sales, the increase in foreclosures and the prolonged recession resulted in decreases in property taxes and some other local taxes, which are among the sources of funding for municipal road, bridge and water infrastructure construction. Expenditures by municipalities have also been impacted by federal, state and local funding limitations in the current economic environment. The ongoing disagreements in Congress over balancing the federal budget in the short-term and long-term as well as reducing the federal deficit add to the uncertainties surrounding the renewal or enactment of federal highway funding legislation. These and other factors have adversely affected the levels of transportation and water infrastructure capital awards and expenditures in our markets, reducing opportunities to replace backlog at reasonable margins and increasing competition for new projects. We do, however, expect that our markets will ultimately recover from the conditions described above and that our backlog and revenues will grow and gross margins, net income and earnings per share will return to levels more consistent with historical rates of return. However, we cannot predict the timing 6 of such a return to historical normalcy in our markets. We believe that the Company is in sound financial condition and has the resources and management experience to weather current market conditions and to continue to compete successfully for projects as they become available at acceptable profit margin levels. The U.S. Department of Transportation (“U.S.DOT”) had actual appropriations of $41.8 billion for federal highway financial assistance to the states for 2011, had authority to spend $41.5 billion in the fiscal year ended September 2012 and has requested authority to spend $39.7 billion in fiscal 2013 and $40.3 billion in fiscal 2014 for highways and bridges. Our principal markets are in Texas, Utah, Nevada, Arizona and California, states that management believes benefit from both positive long-term demographic trends as well as an historical commitment to funding transportation and water infrastructure projects. Currently, the Company also has highway construction contracts in Hawaii, Montana, Idaho and Louisiana. From 2005 to 2010, the populations of Texas, Utah, Nevada, Arizona and California grew 10.2%, 15.8%, 14.8%, 9.1% and 3.5%, respectively, compared to approximately 4.5% for the national average. According to the 2010 U.S. Census Bureau Information, Texas, Utah, Nevada, Arizona, and California are expected to continue to experience population increases from 25.1 million, 2.8 million, 2.7 million, 6.4 million, and 37 million people in 2010, respectively, to populations of over 33 million, 3 million, 4 million, 10 million and 46 million, respectively, by 2030. While the near-term funding available for infrastructure spending in these markets is currently limited, management anticipates that long-term population growth and increased spending for infrastructure in these markets will positively affect business opportunities over the coming years. In Texas, our customers include Texas Department of Transportation (“TxDOT”), Texas county and municipal public works departments, regional transit and water authorities, port authorities, school districts, municipal utility districts and the U.S. Corps of Engineers. TxDOT contract awards (“lettings”) for transportation construction projects were estimated at $3.0 billion in 2013 and are estimated to be $2.3 billion in 2014. In Texas, substantial funds for transportation infrastructure spending are also being provided by toll road and regional mobility authorities for construction of toll roads, which provides Sterling with additional construction contracting opportunities; however, such spending could be limited by federal, state and local funding limitations. In Utah, our public sector customers include the Utah Department of Transportation (“UDOT”) and the Utah Transit Authority. Spending for highway and bridge construction in Utah was $957.3 million in 2012, and $1.2 billion has been authorized for 2013. The details of the capital spending for 2014 have not been released; however the Utah Governor’s recommendation for total capital spending in 2014 is approximately $649.2 million. In Utah, we have been competitive, in part, because of successful marketing efforts, design-build and CM/GC capabilities and development of innovative methods for completing projects. Competition for design-build projects is not totally focused on cost factors but is also significantly dependent on successful marketing efforts, reputation, quality of designs and aesthetics. We believe that we were one of the first construction companies to utilize ABC technology to build bridges offsite, move them to their location, and complete their installation in a very short period of time in order to minimize mobility disruptions. In Nevada, we believe that we are a leading asphalt paving contractor on suburban and rural highway projects. Our primary public sector customer is the Nevada Department of Transportation (“NDOT”). Nevada’s budget for construction of roadways and facilities is $212 million in 2013 and $391 million in 2014 compared with expenditures of $221 million in 2012. In addition, RHB is currently performing eight projects in Hawaii. In Arizona, our principal customers are the Arizona Department of Transportation (“ADOT”) and municipal airport authorities. Arizona’s expenditures for transportation construction were $1.3 billion in 2012, appropriations are $1.6 billion in 2013 and a budget of $1.5 billion has been requested for 2014. In California, our principal customer is the California Department of Transportation (“Caltrans”). California’s transportation capital outlays and local assistance were $2.6 billion in 2012, while such expenditures are estimated to be $4.8 billion in 2013 and $3.5 billion in 2014. A substantial portion of the change between 2013 and 2014 is due to a reduction in expected Federal Trust highway funds. The majority of our contracts pertain to state highway and related bridge work. In 2012, state highway and related bridge work accounted for 61% of our consolidated revenues compared with 65% and 68% in 2011 and 2010, respectively. In 2012, contracts with UDOT and Caltrans represented 16.0% and 15.0% of our consolidated revenues, respectively. In the past, we have also completed the construction of certain infrastructure for new light rail systems in Houston, Dallas and Galveston, Texas, and in Salt Lake City, Utah. We anticipate that expenditures in the cities of Houston and San Antonio for road, rail and water infrastructure projects will continue to increase due to steady gains 7 in population in these metropolitan areas as a result of the immigration of new residents and the annexation of surrounding communities and due to continuing programs in these metropolitan areas to expand storm water and flood control systems and water delivery systems. We believe that similar municipal civil construction opportunities are available in other municipalities in our major markets. We provide services to our municipal customers principally pursuant to contracts awarded through competitive bidding processes. Backlog. Backlog is our estimate of the revenues that we expect to earn in future periods on our construction projects. In prior periods we generally added the anticipated revenue value of each new project to our backlog when management reasonably determined that we would be awarded the contract and there were no known impediments to being awarded the contract. However, due to the operating environment of our California subsidiaries in which low bid awards are at times contested, management has revised the definition of backlog to exclude low bid awards not officially awarded. The new definition of backlog applies whenever backlog is mentioned throughout this document, and we have updated prior period backlog information to conform to our current definition. As the construction on our projects progresses, we increase or decrease backlog to take into account our estimates of the effects of changes in estimated quantities, changed conditions, change orders and other variations from initially anticipated contract revenues, including completion penalties and incentives. At December 31, 2012, our backlog was $656 million. Substantially all of the contracts in our contract backlog may be canceled at the election of the customer; however, we have not been materially adversely affected by contract cancellations or modifications in the past. See the section below entitled “— Contracts — Contract Management Process.” Construction Delivery Methods. Alternative construction delivery methods describe different contractual and responsibility relationships among the owner, the builder and the designer of a project. There are three primary construction delivery methods: design- bid-build, design-build and construction management. The traditional method by which the majority of our projects have historically been completed is design-bid- build. Under this type of construction delivery, the owner hires a design engineer to design the project and then solicits bids from construction firms and typically awards the contract to build the pre-designed project to the lowest qualifying bidder. The contractor to whom the project is awarded becomes the general contractor and is responsible for completing the project in accordance with the owner’s designs using the contractor’s own employees or resources, or subcontractors. Projects under this method are typically fixed unit price contracts. Design-build is increasingly being used by public entities as a method of project delivery. Unlike traditional projects where the owner first hires a design firm or designs a project itself and then puts the project out to bid for construction, design-build projects provide the owner with a single point of responsibility and a single contact for both final design and construction. The owner selects a builder who hires the design team as required and construction typically starts before the design is complete. This project delivery method is typically undertaken through either fixed unit price contracts or lump sum contracts, and price is not the only determining factor used by the owner when selecting a particular contractor. Construction management is a newer method of delivering a project whereby a contractor agrees to manage a project for the owner for an agreed-upon fee, which may be fixed or may vary based upon negotiated factors. The owner of the project typically hires the contractor as a construction manager early in the design phase of the project. The construction manager works with the design team to help ensure that the design is something that can in fact be built within the owner’s desired cost and other parameters and that the ultimate construction contractor will be able to understand the design drawings and specifications. There are two basic types of construction management: construction manager as advisor and construction manager at risk. In the construction manager as advisor type of arrangement, the construction manager acts as a technical consultant to the owner of the project and has no legal responsibility for the performance of the actual construction work. In the construction manager at risk type of arrangement, the construction manager becomes the prime contractor during the construction phase and makes a determination as to which portions of the work will be self-performed and which will be performed through subcontracts. In either type of construction management process, portions of a project are often submitted for bid during the course of the construction manager relationship, with the construction manager bidding, and oftentimes having the first right to bid, on portions of the project. Contracts. Types of Contracts. We provide our services primarily by using traditional general contracting arrangements, including fixed-unit price contracts, lump sum contracts and cost-plus contracts. 8 Fixed unit price contracts are generally used in competitively-bid public civil construction contracts. Contractors under fixed unit price contracts are generally committed to provide all of the resources required to complete the contract for a fixed price per unit. These contracts are generally subject to negotiated change orders, frequently due to differences in site conditions from those initially anticipated or asserted by the customer. Some fixed unit price contracts provide for penalties, if the contract is not completed on time, or incentives, if it is completed ahead of schedule. Under a lump sum contract, the contractor typically agrees to deliver a completed project in accordance with the contract’s requirements for a specific price, and the customer agrees to pay the price according to a negotiated payment schedule. In developing a lump sum bid, the contractor estimates the costs of labor, subcontracts and materials and adds an amount for overhead and profit. The amount of the profit included in the bid is based on the contractor’s assessment of risk and other factors such as availability of resources. If the actual costs of labor, subcontracts, materials and overhead are higher than the contractor’s estimate, the profit will be reduced or become a loss; if the actual costs are lower, the contractor may earn more profit. In a cost plus contract, the owner of a project generally agrees to pay the cost of all of the contractor’s labor, subcontracts and materials plus an amount for contractor overhead and profit (usually as a percentage of the labor, subcontracts and material cost). If actual costs are lower than the estimate, the owner benefits from the cost savings. If actual costs are higher than the estimate, the owner bears the economic burden of the additional costs. Contract Management Process. We identify potential contracts from a variety of sources, including through subscriber services that notify us of contracts out for bid; through advertisements by federal, state and local governmental entities; through our business development efforts; through contacts at government agencies; and through meetings with other participants in the construction industry. After determining which contracts are available, we decide which contracts to pursue based on such factors as the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the size and makeup of our current backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, geographic location, likely competition, construction risks, gross margin opportunities, penalties or incentives and the type of contract. As a condition to pursuing some contracts, we are required to complete a prequalification process with the applicable agency or customer. Some customers, such as TxDOT, NDOT and UDOT, require yearly prequalification, and some other customers have experience requirements specific to the contract. The prequalification process generally limits bidders to those companies with the operational experience and financial capability to effectively complete the particular contract in accordance with the plans, specifications and construction schedule. There are several factors that can create variability in contract performance and financial results compared to our bid assumptions on a contract. The most significant of these include the completeness and accuracy of our original bid analysis, recognition of costs associated with added scope changes, extended overhead due to customer and weather delays, subcontractor availability and performance issues, changes in productivity expectations, site conditions that differ from those assumed in the original bid, and changes in the availability and proximity of materials. In addition, our original bids for some contracts are based on the contract customer’s estimates of the quantities needed to complete a contract. If the quantities ultimately needed are different, our backlog and financial performance on the contract will change. All of these factors can lead to inefficiencies in contract performance, which can increase costs and lower profits. Conversely, if any of these or other factors is more favorable than the assumptions in our bid, contract profitability can improve. Design-build projects carry additional risks such as design error risk and the risk associated with estimating quantities and prices before the project design is completed. Design errors may result in higher than anticipated construction costs and additional liability to the contract owner. Although we manage this additional risk by adding contingencies to our bid amounts, obtaining errors and omissions insurance and obtaining indemnifications from our design consultants where possible, there is no guarantee that these risk management strategies will always be successful. Generally, gross margins included in bids on design-build contracts are higher than for other types of contracts due to the higher risks involved. The estimating process for our traditional fixed unit price competitive bid contracts typically involves three phases. Initially, we consider the level of anticipated competition and our available resources for the prospective project. If we then decide to continue considering a project, we undertake the second phase of the contract process and spend several weeks performing a detailed review of the plans and specifications, summarizing the various types of work involved and related estimated quantities, determining the contract duration and schedule and highlighting the unique and riskier aspects of the contract. Concurrent with this process, we estimate the cost and availability of labor, material, equipment, subcontractors and the project team required to complete the contract on time and in accordance with the plans and specifications. Substantially all of our estimates are made on a per-unit basis for each line item, and it is not unusual for an estimate to contain over 300 line items. The final phase consists of a detailed review of the estimate by management, including, among other things, assumptions regarding cost, approach, means 9 and methods, productivity, risk and the estimated profit margin. This profit amount will vary according to management’s perception of the degree of difficulty of the contract, the current competitive climate and the size, availability of resources and makeup of our backlog. Our project managers are intimately involved throughout the estimating and construction process so that contract issues, and risks, can be understood and addressed on a timely basis. Although the factors described above are relevant in determining the appropriate amount to bid, the contracting process is managed differently if the project is to be performed on a design-build basis or a CM/GC basis. For design- build projects, we assemble a team that may include project managers, engineers, quality managers and surveyors, to learn about a project that we have identified as one on which we may desire to bid. For some projects, pre- qualification for the project is required where each contractor and/or contracting team prepares a description of financial strengths, past experience on similar types of projects, safety record and the persons who will be on the project management and design team, after which, the customer will usually announce a short list of three to five contractors to respond to a request for proposal, generally within three months. Utilizing the limited design specifications provided by the customer, we generally meet weekly over a two to three month period with design engineers to generate a bid containing quantities, prices, timing and a description of our approach for completing the project. The customer then reviews the bids and selects the one that has the best value, and considers factors such as contractor qualifications, the time estimated to complete the project and the price bid. For our CM/GC projects, the customer typically sends out a request for proposal to general contractors for a project. The customer scores each contractor that submits a bid based on the unit prices submitted for five to twenty items that comprise approximately 10% to 20% of the project design, the profit margin proposed, the experience of the contractor for similar types of projects, the contractor’s approach to completing the specific project and whether the contractor understands the CM/GC process. A committee reviews each bid and determines the best value winner to be the general contractor. If we are the winning general contractor, we work with the customer and the engineer to design the project. As various phases of the project are designed, we usually submit bids to construct phases of the project for which we are qualified. In some situations, we also solicit bids from other construction contractors. If we are the lower bidder, we are awarded a contract for that phase. In other situations, if our bid is close to the cost estimates determined by the customer and the engineer, then we will generally be awarded the contract for a particular phase; otherwise, the customer negotiates with us on an appropriate contract price; and if those negotiations are not successful, then the customer can terminate our contract. To manage risks of changes in material prices and subcontracting costs used in tendering bids for construction contracts, we generally obtain firm price quotations from our suppliers and subcontractors, except for fuel and trucking, before submitting a bid. For fixed unit price contracts, these quotations do not include any quantity guarantees, and we have no obligation for materials or subcontract services beyond those required to complete the respective contracts that we are awarded for which quotations have been provided. For design-build and CM/GC projects, lump sum subcontracts are often executed with subcontractors. During the construction phase of a contract, we monitor our progress by comparing actual costs incurred and quantities completed to date with budgeted amounts and the contract schedule, and periodically prepare an updated estimate of total forecasted revenue, cost and expected profit for the contract. During the normal course of most contracts, the customer, and sometimes the contractor, initiates modifications or changes to the original contract to reflect, among other things, changes in quantities, specifications or design, method or manner of performance, facilities, materials, site conditions and the period for completion of the work. In many cases, final contract quantities may differ from those specified by the customer. Generally, the scope and price of these modifications are documented in a “change order” to the original contract and reviewed, approved and paid in accordance with the normal change order provisions of the contract. We are often required to perform extra or change order work under our fixed unit price contracts as directed by the customer even if the customer has not agreed in advance on the scope or price of the work to be performed. This process may result in disputes over whether the work performed is beyond the scope of the work included in the original contract plans and specifications or, even if the customer agrees that the work performed qualifies as extra work, the price that the customer is willing to pay for the extra work. These disputes may not be settled to our satisfaction. Even when the customer agrees to pay for the extra work, we may be required to fund the cost of the work for a lengthy period of time until the change order is approved and funded by the customer. In addition, any delay caused by the extra work may adversely impact the timely scheduling of other work on the contract (or on other contracts) and our ability to meet contract milestone dates. The process for resolving contract claims varies from one contract to another but, in general, we attempt to resolve claims at the project supervisory level through the normal change order process or, if necessary, with higher levels of management within our organization and the customer’s organization. Regardless of the process, when a potential claim arises on a contract, we typically have the contractual obligation to perform the work and must incur 10 the related costs. We do not recoup the costs unless and until the claim is resolved, which could take a significant amount of time. Most of our construction contracts provide for termination of the contract for the convenience of the customer, with provisions to pay us only for work performed through the date of termination. Our backlog and results of operations have not been materially adversely affected by these provisions in the past. We act as the prime contractor on the majority of the construction contracts that we undertake. We generally complete the majority of the work on our contracts with our own resources, and we typically subcontract only specialized activities, such as traffic control, electrical systems, signage, trucking and, in Utah, earthmoving. As the prime contractor, we are responsible for the performance of the entire contract, including subcontract work. Thus, we are subject to increased costs associated with the failure of one or more subcontractors to perform as anticipated. We manage this risk by reviewing the size of the subcontract, the financial stability of and prior experience with the subcontractor and other factors. Although we generally do not require that our subcontractors furnish a bond or other type of security to guarantee their performance, we require performance and payment bonds on some specialized or large subcontract portions of our contracts. Disadvantaged business enterprise regulations require us to use our best efforts to subcontract a specified portion of contract work performed for governmental entities to certain types of subcontractors, including minority- and women-owned businesses. We have not experienced significant costs associated with subcontractor performance issues in the past. Joint Ventures. We participate in joint ventures with other large construction companies and other partners, typically for large, technically complex projects, including design-build projects, when it is desirable to share risk and resources in order to seek a competitive advantage or when the project is too large for us to obtain sufficient bonding. Joint venture partners typically provide independently prepared estimates, furnish employees and equipment, enhance bonding capacity and often also bring local knowledge and expertise. We select our joint venture partners based on our analysis of their construction and financial capabilities, expertise in the type of work to be performed and past working relationships with us, among other criteria. Under a joint venture agreement, one partner is typically designated as the sponsor or manager. The sponsoring partner typically provides all administrative, accounting and most of the project management support for the project and generally receives a fee from the joint venture for these services. We have been designated as the sponsoring partner in certain of our current joint venture projects and are a non-sponsoring partner in others. Joint venture contracts with project owners typically impose joint and several liability on the joint venture partners. Although our agreements with our joint venture partners provide that each party will assume and pay its share of any losses resulting from a project, if one of our partners is unable to pay its share, we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurs a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement. Insurance and Bonding. All of our buildings and equipment are covered by insurance, at levels which our management believes to be adequate. In addition, we maintain general liability and excess liability insurance, workers’ compensation insurance and auto insurance all in amounts consistent with our risk of loss and industry practice. As a normal part of the construction business, we are generally required to provide various types of surety and payment bonds that provide an additional measure of security for our performance under the contract. Typically, a bidder for a contract must post a bid bond, generally for 5% to 10% of the amount bid, and on winning the bid, must post a performance and payment bond for 100% of the contract amount. Upon completion of a contract, before receiving final payment on the contract, a contractor must post a maintenance bond for generally 1% of the contract amount for one to two years. Our ability to obtain surety bonds depends upon our capitalization, working capital, aggregate contract size, past performance, management expertise and external factors, including the capacity of the overall surety market. Surety companies consider such factors in light of the amount of our backlog that we have currently bonded and their current underwriting standards, which may change from time to time. As is customary, we have agreed to indemnify our bonding company for all losses incurred by it in connection with bonds that are issued, and we have granted our bonding company a security interest in certain assets as collateral for such obligation. Government and Environmental Regulations. Our operations are subject to compliance with numerous regulatory requirements of federal, state and local agencies and authorities, including regulations concerning safety, wage and hour, and other labor issues, immigration 11 controls, vehicle and equipment operations and other aspects of our business. For example, our construction operations are subject to the requirements of the Occupational Safety and Health Act, or OSHA, and comparable state laws directed toward the protection of employees. In addition, most of our construction contracts are entered into with public authorities, and these contracts frequently impose additional governmental requirements, including requirements regarding labor relations and subcontracting with designated classes of disadvantaged businesses. All of our operations are also subject to federal, state and local laws and regulations relating to the environment, including those relating to discharges into air, water and land, climate change, the handling and disposal of solid and hazardous waste, the handling of underground storage tanks and the cleanup of properties affected by hazardous substances. For example, we must apply water or chemicals to reduce dust on road construction projects and to contain contaminants in storm run-off water at construction sites. In certain circumstances, we may also be required to hire subcontractors to dispose of hazardous wastes encountered on a project in accordance with a plan approved in advance by the customer. Certain environmental laws impose substantial penalties for non-compliance and others, such as the federal Comprehensive Environmental Response, Compensation and Liability Act, or CERCLA, impose strict and retroactive joint and several liability upon persons responsible for releases of hazardous substances. CERCLA and comparable state laws impose liability, without regard to fault or the legality of the original conduct, on certain classes of persons that contributed to the release of a “hazardous substance” into the environment. These persons include the owner or operator of the site where the release occurred and companies that disposed or arranged for the disposal of the hazardous substances found at the site. Under CERCLA, these persons may be subject to joint and several liability for the costs of cleaning up the hazardous substances that have been released into the environment, for damages to natural resources and for the costs of certain health studies. CERCLA also authorizes the federal Environmental Protection Agency, or EPA, and, in some instances, third parties, to act in response to threats to the public health or the environment and to seek to recover from the responsible classes of persons the costs they incur. Solid wastes, which may include hazardous wastes, are subject to the requirements of the Federal Solid Waste Disposal Act, the Federal Resource Conservation and Recovery Act, referred to as RCRA, and comparable state statutes. Although we do not generate solid waste, we occasionally dispose of solid waste on behalf of customers. From time to time, the EPA considers the adoption of stricter disposal standards for non-hazardous wastes. Moreover, it is possible that additional wastes will in the future be designated as “hazardous wastes.” Hazardous wastes are subject to more rigorous and costly disposal requirements than are non-hazardous wastes. We continually evaluate whether we must take additional steps at our locations to ensure compliance with environmental laws. While compliance with applicable regulatory requirements has not materially adversely affected our operations in the past, there can be no assurance that these requirements will not change and that compliance will not adversely affect our operations in the future. That tighter regulation for the protection of the environment and other factors may make it more difficult to obtain new permits and renewal of existing permits may be subject to more restrictive conditions than currently exist. Employees. As of December 31, 2012, the Company had approximately 1,685 employees, including 1,489 field personnel. Of our field personnel, approximately 28 are project managers and 65 are superintendents. Of the 196 non-field employees, approximately 34 are headquarters’ personnel located in Houston. At December 31, 2012, 278 of our field employees were union members in Nevada, Arizona and California, and these union employees are represented by 8 unions. Our business is dependent upon a readily available supply of management, supervisory and field personnel. Substantially all of our employees are hired on a permanent basis; however, as is typical in the construction industry, we experienced a high degree of turnover as a result of construction projects being completed. In the past, we have been able to attract sufficient numbers of personnel to support the growth of our operations. We conduct extensive safety training programs, which have allowed us to maintain a high safety level at our worksites. All newly-hired employees undergo an initial safety orientation, and for certain types of projects, we conduct specific hazard training programs. Our project foremen and superintendents conduct weekly on-site safety meetings, and our full-time safety inspectors make random site safety inspections and perform assessments and training if infractions are discovered. In addition, all of our superintendents and project managers are required to complete an OSHA-approved safety course. Access to Company’s Filings. The Company maintains a website at www.sterlingconstructionco.com on which our latest Annual Report on Form 10-K, recent Quarterly Reports on Form 10-Q, recent Current Reports on Form 8-K, any amendments to those filings, and other filings may be accessed free of charge through a link to the Securities and Exchange Commission’s 12 (“SEC”) website (www.sec.gov) where those reports are filed. Our website also has recent press releases, the Company’s Code of Business Conduct & Ethics, the charters of the Audit Committee, Compensation Committee, and Corporate Governance & Nominating Committee of the Board of Directors and information on the Company’s “whistle-blower” procedures. Our website content is made available for information purposes only. It should not be relied upon for investment purposes, and none of the information on the website is incorporated into this Report by this reference to it. Item 1A . Risk Factors. The risks described below are those we believe to be the material risks we face. Any of the risk factors described below could significantly and adversely affect our business, prospects, financial condition, results of operations and cash flows. Risks Relating to Our Business. If we are unable to accurately estimate the overall risks, requirements or costs when we bid on or negotiate a contract that is ultimately awarded to us, we may achieve a lower than anticipated profit or incur a loss on the contract. The majority of our revenues and backlog are derived from fixed unit price contracts. Some of our revenues are derived from lump sum contracts. Fixed unit price contracts require us to provide materials and services at a fixed unit price based on approved quantities irrespective of our actual per unit costs. Lump sum contracts require that the total amount of work be performed for a single price irrespective of our actual per unit costs. We realize a profit on our contracts only if we accurately estimate our costs and then successfully control actual costs and avoid cost overruns, and our revenues exceed actual costs. If our cost estimates for a contract are inaccurate, or if we do not execute the contract within our cost estimates, then cost overruns may cause us to incur losses or cause the contract not to be as profitable as we expected. The final results under these types of contracts could negatively affect our cash flow, earnings and financial position. The costs incurred and gross profit realized on our contracts can vary, sometimes substantially, from our original projections due to a variety of factors, including, but not limited to: onsite conditions that differ from those assumed in the original bid or contract; failure to include required materials or work in a bid, or the failure to estimate properly the quantities or costs needed to complete a lump sum contract; delays caused by weather conditions; contract or project modifications creating unanticipated costs not covered by change orders; changes in availability, proximity and costs of materials, including steel, concrete, aggregates and other construction materials (such as stone, gravel, sand and oil for asphalt paving), as well as fuel and lubricants for our equipment; inability to predict the costs of accessing and producing aggregates and purchasing oil required for asphalt paving projects; availability and skill level of workers in the geographic location of a project; failure by our suppliers, subcontractors, designers, engineers, joint venture partners or customers to perform their obligations; fraud, theft or other improper activities by our suppliers, subcontractors, designers, engineers, joint venture partners or customers or our own personnel; mechanical problems with our machinery or equipment; issued by any governmental authority, citations Administration; difficulties in obtaining required governmental permits or approvals; changes in applicable laws and regulations; delays in quickly identifying and taking measures to address issues which arise during production; and claims or demands from third parties for alleged damages arising from the design, construction or use and operation of a project of which our work is part. the Occupational Safety and Health including Many of our contracts with public sector customers contain provisions that purport to shift some or all of the above risks from the customer to us, even in cases where the customer is partly at fault. Our experience has often been that public sector customers have been willing to negotiate equitable adjustments in the contract compensation or completion time provisions if unexpected circumstances arise. However, public sector customers may seek to impose contractual risk-shifting provisions more aggressively, which could increase risks and adversely affect our cash flow, earnings and financial position. We may be unable to sustain our historical revenue growth rate and maintain our profitability. 13 Our revenue has grown rapidly in recent years, in part through acquisitions that expanded our geographical footprint. We may be unable to sustain these recent revenue growth rates for a variety of reasons, including decreased government funding for infrastructure projects, limits on additional growth in our current markets, reduced spending by our customers, an increased number of competitors, less success in competitive bidding for contracts, limitations on access to necessary working capital and investment capital to sustain growth, limitations on access to bonding to support increased contracts and operations, inability to hire and retain essential personnel and to acquire equipment to support growth, and inability to identify acquisition candidates and successfully acquire and integrate them into our business. A substantial decline in our revenue could have a material adverse effect on our financial condition and results of operations if we are unable to also reduce our operating expenses. See “Recent Developments ― Financial Results for 2012, Operational Issues and Outlook for 2013 Financial Results” above for further discuss of the impact on our financial results. Economic downturns or reductions in government funding of infrastructure projects could reduce our revenues and profits and have a material adverse effect on our results of operations. Our business is highly dependent on the amount and timing of infrastructure work funded by various governmental entities, which, in turn, depends on the overall condition of the economy, the need for new or replacement infrastructure, the priorities placed on various projects funded by governmental entities and federal, state or local government spending levels. Spending on infrastructure could decline for numerous reasons, including decreased revenues received by state and local governments for spending on such projects, including federal funding. The nationwide decline in home sales, the increase in foreclosures and a prolonged recession have resulted in decreases in property taxes and some other local taxes, which are among the sources of funding for municipal road, bridge and water infrastructure construction. State spending on highway and other projects can be adversely affected by decreases or delays in, or uncertainties regarding, federal highway funding, which could adversely affect us. We are reliant upon contracts with state transportation departments for a significant portion of our revenues. See “Business−Our Markets, Competition and Customers” above for a more detailed discussion of our markets and their funding sources. We operate in Texas, Utah, Nevada, Arizona, California and to a lesser extent in other states, and adverse changes to the economy and business environment in those states have had an adverse effect on, and could continue to adversely affect, our operations, which could lead to lower revenues and reduced profitability. Because of this concentration in specific geographic locations, we are susceptible to fluctuations in our business caused by adverse economic or other conditions in these regions, including natural or other disasters. The stagnant or depressed economy, to varying degrees, in Texas, Utah, Nevada, Arizona and California have adversely affected, and could continue to adversely effect, our business and results of operations. The cancellation of significant contracts or our disqualification from bidding for new contracts could reduce our revenues and profits and have a material adverse effect on our results of operations. Contracts that we enter into with governmental entities can usually be canceled at any time by them with payment only for the work already completed. In addition, we could be prohibited from bidding on certain governmental contracts if we fail to maintain qualifications required by those entities. A cancellation of an unfinished contract or our debarment from the bidding process could cause our equipment and work crews to be idled for a significant period of time until other comparable work becomes available, which could have a material adverse effect on our business and results of operations. Our growth strategy involves a number of risks. While for a number of years we have pursued revenue and profit growth through the acquisition of companies and assets that enabled us to expand our project skill-sets and capabilities, enlarge our geographic markets, add experienced management and enhance our ability to bid on larger contracts, we may be unable or unwilling to continue to implement this strategy if we cannot reach agreements for potential acquisitions on acceptable terms or for other reasons. Risks related to growth, including growth through acquisitions, include: difficulties in the integration of operations and systems; difficulties applying our expertise in one market into another market; regulatory requirements that impose restrictions on bidding for certain projects because of historical operations by Sterling or the acquired company; the key personnel, customers and project partners of the acquired company may terminate or diminish their relationships with the acquired company; we may experience additional financial and accounting challenges and complexities in areas such as tax planning and financial reporting; 14 we may assume or be held liable for risks and liabilities (including for environmental-related costs and liabilities) as a result of our acquisitions, some of which we may not discover during our due diligence; we may not adequately anticipate competitive and other market factors applicable to the acquired company; we may not be able to realize cost savings or other financial benefits we anticipated or we may not realize our ongoing business may be disrupted or receive insufficient management attention; and the anticipated benefits in the time frame that we expected. Future growth, including growth through acquisitions, may require us to obtain additional equity or debt financing, as well as additional surety bonding capacity, which may not be available on terms acceptable to us or at all. Moreover, to the extent that any acquisition results in additional goodwill, it will reduce our tangible net worth, which might have an adverse effect on our credit and bonding capacity. Our industry is highly competitive, with a variety of companies competing against us, and our failure to compete effectively could reduce the number of new contracts awarded to us or adversely affect our margins on contracts awarded. In the past, a majority of the contracts on which we bid were awarded through a competitive bid process, with awards generally being made to the lowest bidder, but sometimes recognizing other factors, such as shorter contract schedules or prior experience with the customer. For our design-build, CM/GC and other alternative methods of delivering projects, reputation, marketing efforts, quality of design and minimizing public inconvenience are also significant factors considered in awarding contracts, in addition to cost. Within our markets, we compete with many international, national, regional and local construction firms. Some of these competitors have achieved greater market penetration than we have in the markets in which we compete, and some may have greater financial and other resources than we do. In addition, there are a number of international and national companies in our industry that are larger than we are and that, if they so desire, could establish a presence in our markets and compete with us for contracts. In some markets where residential and commercial projects have significantly diminished, the bidding environment in our markets has been much more competitive as construction companies that lack available work in those markets have begun bidding on projects in our markets, sometimes at bid levels below our break-even pricing. In addition, traditional competitors on larger transportation and water infrastructure projects also appear to have been bidding at less than normal margins, and in some cases at below our break-even pricing, in order to replenish their backlogs. As a result, we may need to accept lower contract margins in order to compete against competitors that have the ability to accept awards at lower prices or have a pre-existing relationship with a customer. In addition, if the use of design-build, CM/GC and other alternative project delivery methods continues to increase and we are not able to further develop our capabilities and reputation in connection with these alternative delivery methods, we will be at a competitive disadvantage, which may have a material adverse effect on our financial position, results of operations, cash flows and prospects. If we are unable to compete successfully in our markets, our relative market share and profits could also be reduced. Our dependence on subcontractors and suppliers of materials (including petroleum-based products) could increase our costs and impair our ability to complete contracts on a timely basis or at all, which would adversely affect our profits and cash flow. We rely on third-party subcontractors to perform some of the work on many of our contracts. We generally do not bid on contracts unless we have the necessary subcontractors committed for the anticipated scope of the contract and at prices that we have included in our bid, except in some instances for trucking arrangements. Therefore, to the extent that we cannot engage subcontractors, our ability to bid for contracts may be impaired. In addition, if a subcontractor is unable to deliver its services according to the negotiated terms for any reason, including the deterioration of its financial condition, we may suffer delays and be required to purchase the services from another source at a higher price or incur other unanticipated costs. This may reduce the profit to be realized, or result in a loss, on a contract. We also rely on third-party suppliers to provide most of the materials (including aggregates, cement, asphalt, concrete, steel, pipe, oil and fuel) for our contracts, except in Nevada where we source and produce some of the aggregates we use from quarries in which we have mining rights. We do not own or operate any quarries in Texas, Utah, Arizona or California. We normally do not bid on contracts unless we have commitments from suppliers for the materials and subcontractors for certain of the services required to complete the contract and at prices that we have included in our bid, except for some construction projects in Nevada where we use aggregates from quarries in which we have mining rights. Thus, to the extent that we cannot obtain commitments from our suppliers for materials and subcontractors for certain of the services, our ability to bid for contracts may be impaired. In addition, if a supplier or subcontractor is unable to deliver materials or services according to the negotiated terms of a supply/services agreement for any reason, including the deterioration of its financial condition, we may suffer delays 15 and be required to purchase the materials/services from another source at a higher price or incur other unanticipated costs. This may reduce the profit to be realized, or result in a loss, on a contract. Diesel fuel and other petroleum-based products are utilized to operate the plants and equipment on which we rely to perform our construction contracts. In addition, our asphalt plants and suppliers use oil in combination with aggregates to produce asphalt used in our road and highway construction projects. Decreased supplies of such products relative to demand, unavailability of petroleum supplies due to refinery turnarounds, higher prices charged for petroleum based products and other factors can increase the cost of such products. Future increases in the costs of fuel and other petroleum-based products used in our business, particularly if a bid has been submitted for a contract and the costs of such products have been estimated at amounts less than the actual costs thereof, could result in a lower profit, or a loss, on a contract. We may not accurately assess the quality, and we may not accurately estimate the quality, quantity, availability and cost, of aggregates we plan to produce, particularly for projects in rural areas of Nevada, which could have a material adverse effect on our results of operations. Particularly for projects in rural areas of Nevada, we typically estimate the quality, quantity, availability and cost for anticipated aggregate sources that we have not previously used to produce aggregates, which increases the risk that our estimates may be inaccurate. Inaccuracies in our estimates regarding aggregates could result in significantly higher costs to supply aggregates needed for our projects, as well as potential delays and other inefficiencies. As a result, our failure to accurately assess the quality, quantity, availability and cost of aggregates could cause us to incur losses, which could materially adversely affect our results of operations. If we are unable to attract and retain key personnel and skilled labor, or if we encounter labor difficulties, our ability to bid for and successfully complete contracts may be negatively impacted. Our ability to attract and retain reliable, qualified personnel is a significant factor that enables us to successfully bid for and profitably complete our work. This includes members of our management, project managers, estimators, supervisors, foremen, equipment operators and laborers. The loss of the services of any of our management could have a material adverse effect on us. Our future success will also depend on our ability to hire and retain, or to attract when needed, highly-skilled personnel. If competition for these employees is intense, we could experience difficulty hiring and retaining the personnel necessary to support our business. If we do not succeed in retaining our current employees and attracting, developing and retaining new highly-skilled employees, our reputation may be harmed and our operations and future earnings may be negatively impacted. We rely heavily on immigrant labor. We have taken steps that we believe are sufficient and appropriate to ensure compliance with immigration laws. However, we cannot provide assurance that we have identified, or will identify in the future, all illegal immigrants who work for us. Our failure to identify illegal immigrants who work for us may result in fines or other penalties being imposed upon us, which could have a material adverse effect on our operations, results of operations and financial condition. In Nevada, California and Hawaii, a substantial number of our equipment operators and laborers are unionized. Any work stoppage or other labor dispute involving our unionized workforce, or inability to renew contracts with the unions, could have a material adverse effect on our operations and operating results. Our contracts may require us to perform extra or change order work, which can result in disputes and adversely affect our working capital, profits and cash flows. Our contracts often require us to perform extra or change order work as directed by the customer even if the customer has not agreed in advance on the scope or price of the extra work to be performed. This process may result in disputes over whether the work performed is beyond the scope of the work included in the original project plans and specifications or, if the customer agrees that the work performed qualifies as extra work, the price that the customer is willing to pay for the extra work. These disputes may not be settled to our satisfaction. Even when the customer agrees to pay for the extra work, we may be required to fund the cost of such work for a lengthy period of time until the change order is approved by the customer and we are paid by the customer. To the extent that actual recoveries with respect to change orders or amounts subject to contract disputes or claims are less than the estimates used in our financial statements, the amount of any shortfall will reduce our future revenues and profits, and this could have a material adverse effect on our reported working capital and results of operations. In addition, any delay caused by the extra work may adversely impact the timely scheduling of other project work and our ability to meet specified contract milestone dates. Our failure to meet schedule or performance requirements of our contracts could adversely affect us. In most cases, our contracts require completion by a scheduled acceptance date. Failure to meet any such schedule could result in additional costs, penalties or liquidated damages being assessed against us, and these could 16 exceed projected profit margins on the contract. Performance problems on existing and future contracts could cause actual results of operations to differ materially from those anticipated by us and could cause us to suffer damage to our reputation within the industry and among our customers. The design-build project delivery method subjects us to the risk of design errors and omissions. In the event of a design error or omission causing damages with respect to one of our design-build projects, we could be liable. Although we pass design responsibility on to the engineering firms that we engage to perform design services on our behalf for these projects, in the event of a design error or omission causing damages, there is risk that the engineering firm, its professional liability insurance, and the errors and omissions insurance that they and we purchase will not fully protect us from costs or liabilities. Any liabilities resulting from an asserted design defect with respect to our construction projects may have a material adverse effect on our financial position, results of operations and cash flows. Adverse weather conditions may cause delays, which could slow completion of our contracts and negatively affect our revenues and cash flow. Because all of our construction projects are built outdoors, work on our contracts is subject to unpredictable weather conditions, which could become more frequent or severe if general climatic changes occur. For example, evacuations in Texas due to hurricanes along the U.S. Gulf of Mexico coastal areas can result in our inability to perform work on all Houston-area contracts for several days. Lengthy periods of wet or cold winter weather will generally interrupt construction, and this can lead to under-utilization of crews and equipment, resulting in less efficient rates of overhead recovery. Extreme heat can prevent us from performing certain types of operations. During the late fall to early spring months of each year, our work on construction projects in Nevada and Utah may also be curtailed because of snow and other work-limiting weather. While revenues can be recovered following a period of bad weather, it is generally impossible to recover the cost of inefficiencies, and significant periods of bad weather typically reduce profitability of affected contracts both in the current period and during the future life of affected contracts. Such reductions in contract profitability negatively affect our results of operations in current and future periods until the affected contracts are completed. Timing of the award and performance of new contracts could have an adverse effect on our operating results and cash flow. It is generally very difficult to predict whether and when new contracts will be offered for tender, as these contracts frequently involve a lengthy and complex design and bidding process, which is affected by a number of factors, such as market conditions, funding arrangements and governmental approvals. Because of these factors, our results of operations and cash flows may fluctuate from quarter to quarter and year to year, and the fluctuation may be substantial. The uncertainty of the timing of contract awards may also present difficulties in matching the size of our equipment fleet and work crews with contract needs. In some cases, we may maintain and bear the cost of more equipment and ready work crews than are currently required, in anticipation of future needs for existing contracts or expected future contracts. If a contract is delayed or an expected contract award is not received, we would incur costs that could have a material adverse effect on our anticipated profit. In addition, the timing of the revenues, earnings and cash flows from our contracts can be delayed by a number of factors, including adverse weather conditions, such as prolonged or intense periods of rain, snow, storms or flooding; delays in receiving material and equipment from suppliers and services from subcontractors; and changes in the scope of work to be performed. Such delays, if they occur, could have adverse effects on our operating results for current and future periods until the affected contracts are completed. Our participation in construction joint ventures exposes us to liability and/or harm to our reputation for failures of our partners. As part of our business, we are a party to joint venture arrangements, pursuant to which we typically jointly bid on and execute particular projects with other companies in the construction industry. Success on these joint projects depends upon managing the risks discussed in the various risks described in these “Risk Factors” and on whether our joint venture partners satisfy their contractual obligations. We and our joint venture partners are generally jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partner’s shortfall. Furthermore, if we are unable to adequately address our partner’s performance issues, the customer may terminate the project, which could result in legal liability to us, harm to our reputation and reduction to our profit on a project. 17 In connection with acquisitions, certain counterparties to joint venture arrangements, which may include our historical direct competitors, may not desire to continue such arrangements with us and may terminate the joint venture arrangements or not enter into new arrangements. Any termination of a joint venture arrangement could cause us to reduce our backlog and could materially and adversely affect our business, results of operations and financial condition. Our dependence on a limited number of customers could adversely affect our business and results of operations. Due to the size and nature of our construction contracts, one or a few customers have in the past and may in the future represent a substantial portion of our consolidated revenues and gross profits in any one year or over a period of several consecutive years. For example, in 2012, approximately 16.0% of our revenue was generated from UDOT and approximately 15.0% was generated by Caltrans. Similarly, our backlog frequently reflects multiple contracts for certain customers; therefore, one customer may comprise a significant percentage of backlog at a certain point in time. Examples of this are Caltrans, NTTA, Central Texas Regional Mobility Authority, TxDOT and ADOT which comprised 31.0%, 16.2%, 7.4%, 6.8% and 5.7% of our backlog at December 31, 2012, respectively. The loss of business from any one of such customers could have a material adverse effect on our business or results of operations. Also, a default or delay in payment on a significant scale by a customer could materially adversely affect our business, results of operations, cash flows and financial condition. We may incur higher costs to lease, acquire and maintain equipment necessary for our operations, and the market value of our owned equipment may decline. A significant portion of our contracts is built with our own construction equipment rather than leased or rented equipment. To the extent that we are unable to buy construction equipment necessary for our needs, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short- term basis, which could increase the costs of performing our contracts. The equipment that we own or lease requires continuous maintenance, for which we maintain our own repair facilities. If we are unable to continue to maintain the equipment in our fleet, we may be forced to obtain third-party repair services, which could increase our costs. In addition, the market value of our equipment may unexpectedly decline at a faster rate than anticipated. An inability to obtain bonding could limit the aggregate dollar amount of contracts that we are able to pursue. As is customary in the construction business, we are required to provide surety bonds to our customers to secure our performance under construction contracts. Our ability to obtain surety bonds primarily depends upon our capitalization, working capital, past performance, management expertise and reputation and certain external factors, including the overall capacity of the surety market. Surety companies consider such factors in relationship to the amount of our backlog and their underwriting standards, which may change from time to time. Events that adversely affect the insurance and bonding markets generally may result in bonding becoming more difficult to obtain in the future, or being available only at a significantly greater cost. Our inability to obtain adequate bonding would limit the amount that we can bid on new contracts and could have a material adverse effect on our future revenues and business prospects. Our operations are subject to hazards that may cause personal injury or property damage, thereby subjecting us to liabilities and possible losses, which may not be covered by insurance. Our workers are subject to the usual hazards associated with providing construction and related services on construction sites, plants and quarries. Operating hazards can cause personal injury and loss of life, damage to or destruction of property, plant and equipment and environmental damage. We maintain general liability and excess liability insurance, workers’ compensation insurance, auto insurance and other types of insurance all in amounts consistent with our risk of loss and industry practice, but this insurance may not be adequate to cover all losses or liabilities that we may incur in our operations. Insurance liabilities are difficult to assess and quantify due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If we were to experience insurance claims or costs above our estimates, we might be required to use working capital to satisfy these claims rather than to maintain or expand our operations. To the extent that we experience a material increase in the frequency or severity of accidents or workers’ compensation and health claims, or unfavorable developments on existing claims, our operating results and financial condition could be materially and adversely affected. Environmental and other regulatory matters could adversely affect our ability to conduct our business and could require expenditures that could have a material adverse effect on our results of operations and financial condition. 18 Our operations are subject to various environmental laws and regulations relating to the management, disposal and remediation of hazardous substances, climate change and the emission and discharge of pollutants into the air and water. We could be held liable for such contamination created not only from our own activities but also from the historical activities of others on our project sites or on properties that we acquire or lease. Our operations are also subject to laws and regulations relating to workplace safety and worker health, which, among other things, regulate employee exposure to hazardous substances. Immigration laws require us to take certain steps intended to confirm the legal status of our immigrant labor force, but we may nonetheless unknowingly employ illegal immigrants. Violations of such laws and regulations could subject us to substantial fines and penalties, cleanup costs, third-party property damage or personal injury claims. In addition, these laws and regulations have become, and enforcement practices and compliance standards are becoming, increasingly stringent. Moreover, we cannot predict the nature, scope or effect of legislation or regulatory requirements that could be imposed, or how existing or future laws or regulations will be administered or interpreted, with respect to products or activities to which they have not been previously applied. Compliance with more stringent laws or regulations, as well as more vigorous enforcement policies of the regulatory agencies, could require us to make substantial expenditures for, among other things, pollution control systems and other equipment that we do not currently possess, or the acquisition or modification of permits applicable to our activities. Our aggregate quarry lease in Nevada could subject us to costs and liabilities. As lessee and operator of the quarry, we could be held responsible for any contamination or regulatory violations resulting from activities or operations at the quarry. Any such costs and liabilities could be significant and could materially and adversely affect our business, operating results and financial condition. Terrorist attacks have impacted, and could continue to negatively impact, the U.S. economy and the markets in which we operate. Terrorist attacks, like those that occurred on September 11, 2001, have contributed to economic instability in the United States, and further acts of terrorism, violence or war could affect the markets in which we operate, our business and our expectations. Armed hostilities may increase, or terrorist attacks, or responses from the United States, may lead to further acts of terrorism and civil disturbances in the United States or elsewhere, which may further contribute to economic instability in the United States. These attacks or armed conflicts may affect our operations or those of our customers or suppliers and could impact our revenues, our production capability and our ability to complete contracts in a timely manner. Risks Related to Our Financial Results and Financing Plans. Actual results could differ from the estimates and assumptions that we use to prepare our financial statements. To prepare financial statements in conformity with accounting principles generally accepted in the United States (“GAAP”), management is required to make estimates and assumptions, as of the date of the financial statements, which affect the reported values of assets and liabilities, revenues and expenses, and disclosures of contingent assets and liabilities. Areas requiring significant estimates by our management include: contract costs and profits; application of percentage-of-completion accounting and revenue recognition of contract change order claims; provisions for uncollectible receivables and customer claims and recoveries of costs from subcontractors, suppliers and others; impairment of long-term assets; valuation of assets acquired and liabilities assumed in connection with business combinations; accruals for estimated liabilities, including litigation and insurance reserves; and stock-based compensation. Our actual results could differ from, and could require adjustments to, those estimates. In particular, as is more fully discussed in “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations — Critical Accounting Policies,” we recognize contract revenue using the percentage-of-completion method. Under this method, estimated contract revenue is recognized by applying the percentage of completion of the contract for the period (based on the ratio of costs incurred to total estimated costs of a contract) to the total estimated revenue for the contract. Estimated contract losses are recognized in full when determined. Contract revenue and total cost estimates are reviewed and revised on a continuous basis as the work progresses and as change orders are initiated or approved, and adjustments based upon the percentage of completion are reflected in contract revenue in the accounting period when these estimates are revised. To the extent that these adjustments result in an increase, a reduction or an elimination of previously reported contract profit, we recognize a credit or a charge against current earnings, which could be material. We may need to raise additional capital in the future for working capital, capital expenditures and/or acquisitions, and we may not be able to do so on favorable terms or at all, which would impair our ability to operate our business or achieve our growth objectives. Our ability to obtain additional financing in the future will depend in part upon prevailing credit and equity market conditions, as well as conditions in our business and our operating results; such factors may adversely affect our efforts to arrange additional financing on terms satisfactory to us. We have pledged the proceeds and other rights 19 under our construction contracts to our bond surety, and we have pledged substantially all of our other assets as collateral in connection with our credit facility and mortgage debt. As a result, we may have difficulty in obtaining additional financing in the future if such financing requires us to pledge assets as collateral. In addition, under our credit facility, we must obtain the consent of our lenders to incur any amount of additional debt from other sources (subject to certain exceptions). If future financing is obtained by the issuance of additional shares of common stock, our stockholders may suffer dilution. If adequate funds are not available, or are not available on acceptable terms, we may not be able to make future investments, take advantage of acquisitions or other opportunities, or respond to competitive challenges. We are subject to financial and other covenants under our credit facility that could limit our flexibility in managing our business. We have a credit facility that restricts us from engaging in certain activities, including our ability (subject to certain exceptions) to: make distributions, pay dividends and buy back shares; make acquisitions. incur liens or encumbrances; incur other indebtedness; guarantee obligations; dispose of a material portion of assets; engage in a merger with a third party; and Our credit facility contains financial covenants that require us to maintain specified fixed charge coverage ratios, asset ratios and leverage ratios, and to maintain specified levels of tangible net worth. Our ability to borrow funds for any purpose will depend on our satisfying these tests. If we are unable to meet the terms of the financial covenants or fail to comply with any of the other restrictions contained in our credit facility, an event of default could occur. An event of default, if not waived by our lenders, could result in the acceleration of any outstanding indebtedness, causing such debt to become immediately due and payable. If such acceleration occurs, we may not be able to repay such indebtedness on a timely basis. Acceleration of our credit facility could result in foreclosure on and loss of our operating assets. In the event of such foreclosure, we would be unable to conduct our business and forced to discontinue operations. If we were required to write down all or part of our goodwill, our net earnings and net worth could be materially and adversely affected. We had approximately $54.8 million of goodwill recorded on our consolidated balance sheet at December 31, 2012. Goodwill represents the excess of cost over the fair value of net assets acquired in business combinations reduced by any impairments recorded subsequent to the date of acquisition. A shortfall in our revenues or net income or changes in various other factors from that expected by securities analysts and investors could significantly reduce the market price of our common stock. If our market capitalization drops significantly below the amount of net equity recorded on our balance sheet, it might indicate a decline in our fair value and would require us to further evaluate whether our goodwill has been impaired. We perform an annual review of our goodwill and intangible assets to determine if they have become impaired, which would require us to write down the impaired portion of these assets. On an interim basis, we also review the factors that have or may affect our operations or market capitalization for events that may trigger impairment testing. Writedowns of goodwill may be substantial. For example, in 2011, our annual review indicated that goodwill was impaired, and as a result we recorded a charge of $67.0 million representing approximately 55% of the $121 million of recorded goodwill prior to the write down. As a result, the Company incurred a significant loss for 2011 and equity declined by $41.8 million. If we were required to write down all or a significant part of our goodwill in future periods, our net earnings and equity could be materially and adversely affected. Item 1B . Unresolved Staff Comments None Item 2. Properties We own our headquarters office building in Houston, Texas, which is located on a seven-acre parcel of land on which our Texas equipment repair center is also located. We also own land and newly constructed offices in San Antonio and Dallas. Our Utah operations leases office space in Draper, Utah, near Salt Lake City, and repair facilities in West Jordan City, Utah from entities owned primarily by certain officers of RLW – see Note 17 (references to “Note” or “Notes” 20 are to the Notes to Consolidated Financial Statements for the year ended December 31, 2012, included in this document). For our Nevada operations, we lease office space in Sparks, Nevada, and own our office and repair facilities located on a forty-five acre parcel of land in Lovelock, Nevada. We also lease the right to mine stone and sand at four quarry sites in Nevada. Unlike in Texas and Utah where we acquire aggregates from third-party suppliers, in Nevada we generally source and produce our own aggregates, either from our own quarries or from other sources near job sites where we enter into short-term leases to acquire the aggregates necessary for the job. For our Arizona operations, we lease office space in Tempe, and for our California operations, we lease office space in Sacramento. In order to complete most contracts, we also lease small parcels of real estate near the site of a contract job site to store materials, locate equipment, and provide offices for the contracting customer, its representatives and our employees. Item 3. Legal Proceedings. We are and may in the future be involved as a party to various legal proceedings that are incidental to the ordinary course of business. We regularly analyze current information about these proceedings and, as necessary, provide accruals for probable liabilities on the eventual disposition of these matters. In the opinion of management, after consultation with legal counsel, there are currently no threatened or pending legal matters that would reasonably be expected in the future to have a material adverse impact on our consolidated results of operations, financial position or cash flows. Item 4. Mine Safety Disclosures. The information concerning mine safety violations and other regulatory matters required by section 1503(a) of the Dodd-Frank Wall Street Reform and Consumer Protection Act and Item 104 of Regulation S-K is included in Exhibit 95.1 of this Annual Report on Form 10-K, which is incorporated by reference. EXECUTIVE OFFICERS OF THE REGISTRANT (At March 1, 2013) The following is a list of the Company's executive officers, their ages, positions, offices and the year they became executive officers together with a brief description of their business experience. Name Age Position/Offices Peter MacKenna (1) Elizabeth D. Brumley Joseph P. Harper, Jr. Brian R. Manning 50 54 41 46 President & Chief Executive Officer Executive Vice President & Chief Financial Officer, Treasurer, Controller Executive Vice President Executive Vice President & Chief Business Development Officer Roger M. Barzun 71 Senior Vice President & General Counsel, (1) Member of the Board of Directors. Secretary Executive Officer Since 2012 2011 2010 2010 2006 Each executive officer is elected by the Board of Directors and, subject to the terms of his employment agreement with the Company, holds office for such term as the Board of Directors may prescribe or until his death, disqualification, resignation or removal. Mr. MacKenna was elected Chief Executive Officer effective September 1, 2012, and on January 28, 2013 he was given the additional title of President on the retirement of Joseph P. Harper, Sr., the Company’s former President and Chief Operating Officer. Prior to joining the Company, Mr. MacKenna was employed by Skanska AB for more than fourteen years as president and chief executive officer of several of its operating companies. Skanska AB is a Fortune 500 public company and one of the ten largest construction companies in the world. Ms. Brumley was elected Chief Accounting Officer & Controller effective March 17, 2011 and Executive Vice President & Chief Financial Officer effective November 28, 2011. Prior to joining the Company, from November, 2005 through June, 2010, she was with Bristow Group Inc. serving in various roles, the most recent of which was as the Company’s Vice President-Finance and Chief Financial Officer. Bristow Group Inc. is listed on the New York 21 Stock Exchange and is a leading global provider of helicopter services to the worldwide offshore energy industry. Prior to that she held controller and accounting positions with several Houston-based corporations. Ms. Brumley is a certified public accountant. Messrs. Harper and Manning have been officers of the Company for more than the last five years. Messrs. Harper and Manning were elected to their current positions on September 1, 2010. Mr. Barzun has been an officer of the Company for more than the last five years and also serves as general counsel to other corporations from time to time on a part-time basis. He is a member of the bar of New York and Massachusetts. PART II Item 5. Market for the Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities. The Company’s common stock is traded on the NASDAQ Global Select Market (“NGS”). The table below shows the market high and low closing sales prices of the common stock for 2011 and 2012 by quarter. Year Ended December 31, 2011 First Quarter ............................................................ $ Second Quarter ....................................................... Third Quarter .......................................................... Fourth Quarter ........................................................ Year Ended December 31, 2012 First Quarter ........................................................... $ Second Quarter ....................................................... Third Quarter .......................................................... Fourth Quarter ........................................................ High Low 16.89 $ 16.85 14.27 13.11 12.30 $ 10.22 10.80 10.00 12.42 12.25 10.70 10.05 8.98 8.75 9.64 7.81 On February 28, 2013, there were 1,092 holders of record of our common stock. Dividend Policy. We have never paid any cash dividends on our common stock. For the foreseeable future, we intend to retain any earnings in our business, and we do not anticipate paying any cash dividends. Whether or not we declare any dividends will be at the discretion of the Board of Directors considering then-existing conditions, including the Company’s financial condition and results of operations, capital requirements, bonding prospects, contractual restrictions (including those under the Company’s Credit Facility), business prospects and other factors that our Board of Directors considers relevant. Equity Compensation Plan Information. Certain information about the Company’s equity compensation plans is incorporated into Item 11. — Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters from the Company’s proxy statement for its 2013 Annual Meeting of Stockholders. Performance Graph. The following graph compares the percentage change in the Company’s cumulative total stockholder return on its common stock for the last five years with the Dow Jones US Index, a broad market index, and the Dow Jones US Heavy Construction Index, a group of companies whose focus is limited primarily to heavy civil construction. Both indices are published in The Wall Street Journal. The returns are calculated assuming that an investment with a value of $100 was made in the Company’s common stock and in each index at the end of 2007 and that all dividends were reinvested in additional shares of common stock. The graph lines merely connect the measuring dates and do not reflect fluctuations between those dates. The stock performance shown on the graph is not intended to be indicative of future stock performance. 22 COMPARISON OF 5 YEAR CUMULATIVE TOTAL RETURN* Among Sterling Construction Company, Inc, the Dow Jones US Index, and the Dow Jones US Heavy Construction Index $120 $100 $80 $60 $40 $20 $0 12/07 12/08 12/09 12/10 12/11 12/12 Sterling Construction Company, Inc Dow Jones US Dow Jones US Heavy Construction *$100 invested on 12/31/07 in stock or index, including reinvestment of dividends. Fiscal year ending December 31. Copyright© 2013 Dow Jones & Co. All rights reserved. December 2007 ($) December 2008 ($) December 2009 ($) December 2010 ($) December 2011 ($) December 2012 ($) Sterling Construction Company, Inc. Dow Jones US Dow Jones US Heavy Construction 100.00 100.00 100.00 84.92 62.84 44.88 87.72 80.93 51.30 59.76 94.40 65.87 49.36 95.67 54.30 45.55 111.29 65.94 Issuer Purchases of Equity Securities. In October 2008, the Company announced a share-repurchase program to purchase up to $5 million in shares of common stock. In August 2010, the Company announced an increase to the share-repurchase program to purchase an additional $5 million in shares of common stock, for a total up to $10 million. The specific timing and amount of repurchase will vary based on market conditions, securities law limitations and other factors. There were no repurchases of shares during the twelve months ended December 31, 2012. 23 Item 6. Selected Financial Data The following table sets forth selected financial and other data of the Company and its subsidiaries and should be read in conjunction with both “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations,” which follows, and “Item 8. Financial Statements and Supplementary Data.” Years ended December 31, 2012 2011 2010 2009 2008 Revenues ........................................................$ 630,507 $ 501,156 $ 459,893 $ 390,847 $ 415,074 Income (loss) before income taxes and earnings attributable to noncontrolling interests........................................................$ Income tax benefit (expense) ......................... Net income (loss) ..................................... Noncontrolling owners’ interests in earnings of subsidiaries .............................................. Net income (loss) attributable to Sterling 17,133 $ 579 17,712 (51,716) $ 17,012 (34,704) 36,494 $ (10,270) 26,224 37,795 $ (12,267) 25,528 28,999 (10,025) 18,974 (18,009) (1,196) (7,137) (1,824) (908) common stockholders ..................................$ (297) $ (35,900) $ 19,087 $ 23,704 $ 18,066 Net income (loss) per share attributable to Sterling common stockholders: Basic ........................................................$ Diluted .....................................................$ (0.26) $ (0.26) $ (2.24) $ (2.24) $ 1.15 $ 1.13 $ 1.77 $ 1.71 $ 1.38 1.32 Weighted average number of common shares outstanding used in computing per share amounts: Basic ....................................................... Diluted ..................................................... 16,421 16,421 16,396 16,396 16,195 16,563 13,359 13,856 Cash dividends declared .................................$ -- $ -- $ -- $ -- $ 13,120 13,702 -- Balance sheet: Total assets .....................................................$ Long-term debt ...............................................$ Equity attributable to Sterling common 331,510 $ 24,201 $ 303,831 $ 263 $ 367,131 $ 336 $ 385,741 $ 40,409 $ 289,615 55,483 stockholders .................................................$ 210,148 $ 213,311 $ 250,429 $ 230,766 $ 159,116 Book value per share of outstanding common stock attributable to Sterling common stockholders ..................................$ Shares outstanding .......................................... 12.74 $ 16,495 13.07 $ 16,321 15.21 $ 16,468 14.35 $ 16,082 12.07 13,185 24 Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations. Overview. We are a company that operates in one segment, heavy civil construction, through our subsidiaries, and which specializes in the building, reconstruction and repair of transportation and water infrastructure in Texas, Utah, Nevada, Arizona and California and other states where we see opportunities. We have strategically expanded our operations, either by establishing an office in a new market, often after having successfully bid on and completed a project in that market, or by acquiring a company that gives us an immediate entry into a market. On August 1, 2011, we expanded our operations into Arizona and California with the acquisitions of JBC and Myers. Critical Accounting Policies. On an ongoing basis, the Company evaluates the critical accounting policies used to prepare its consolidated financial statements, including, but not limited to, those related to: Revenue recognition Contracts receivable, including retainage Valuation of property and equipment, goodwill and other long-lived assets Construction joint ventures Income taxes Segment reporting Our significant accounting policies are described in Note 1, and conform to the FASB’s Accounting Standards Codification (or GAAP or ASC). Use of Estimates. The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities, the disclosure of contingent assets and liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Certain of the Company’s accounting policies require higher degrees of judgment than others in their application. These include the recognition of revenue and earnings from construction contracts under the percentage- of-completion method, the valuation of long-lived assets, and income taxes. Management continually evaluates all of its estimates and judgments based on available information and experience; however, actual amounts could differ from those estimates. Contract Revenue Recognition The majority of our contracts with our customers are “fixed unit price.” Under such contracts, we are committed to providing materials or services required by a contract at fixed unit prices (for example, dollars per cubic yard of concrete poured or per cubic yard of earth excavated). Most of our state and municipal contracts provide for termination of the contract for the convenience of the owner, with provisions to pay us only for work performed through the date of termination. Credit risk is minimal with public owners since the Company ascertains that funds have been appropriated by the governmental project owner prior to commencing work on such projects. While most public contracts are subject to termination at the election of the government entity, in the event of termination the Company is entitled to receive the contract price for completed work and reimbursement of termination-related costs. Credit risk with private owners is minimized because of statutory mechanics liens, which give the Company high priority in the event of lien foreclosures following financial difficulties of private owners. We use the percentage-of-completion accounting method for construction contracts. Revenue is recognized as costs are incurred in an amount equal to cost plus the related expected profit based on the percentage of completion method of accounting in the ratio of costs incurred to estimated final costs. Our contracts generally take 12 to 36 months to complete. Contract costs consist of direct costs on contracts, including labor, materials, amounts payable to subcontractors and those indirect costs related to contract performance, such as indirect salaries and wages, equipment maintenance, repairs, fuel and depreciation, insurance and payroll taxes. Contract cost is recorded as incurred, and revisions in contract revenue and cost estimates are reflected in the accounting period when known. Provisions for estimated losses on uncompleted contracts are made in the period in which such losses are determined. Changes in job performance, job conditions and estimated profitability, including those changes arising from contract penalty provisions and final contract settlements may result in revisions to costs and income and are recognized in the period in which the revisions are determined. An amount attributable to contract claims is included in revenues when 25 realization is probable and the amount can be reasonably estimated. The Company generally provides a one to two- year warranty for workmanship under its contracts. Warranty claims historically have been insignificant. The accuracy of our revenue and profit recognition in a given period is dependent on the accuracy of our estimates of the revenues and costs to finish uncompleted contracts. Our estimates for all of our significant contracts use a highly detailed “bottom up” approach, and we believe our experience allows us to produce reliable estimates. However, our projects can be highly complex, and in almost every case, the profit margin estimates for a contract will either increase or decrease to some extent from the amount that was originally estimated at the time of bid. Because we have a large number of projects of varying levels of size and complexity in process at any given time, these changes in estimates can sometimes offset each other without materially impacting our overall profitability. However, large changes in revenue or cost estimates can have a significant effect on profitability. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include the completeness and accuracy of the original bid, recognition of costs associated with scope changes, extended overhead due to customer-related and weather-related delays, subcontractor and supplier performance issues, site conditions that differ from those assumed in the original bid (to the extent contract remedies are unavailable), the availability and skill level of workers in the geographic location of the project and changes in the availability and proximity of materials. The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins, may cause fluctuations in gross profit between periods, and these fluctuations may be significant. Results for 2012 and 2011 were adversely affected by revisions to estimated profitability on a number of construction projects. See “Recent Developments ― Financial Results for 2012, Operational Issues and Outlook for 2013 Financial Results” above and “Results of Operations ― Fiscal Year Ended December 31, 2012 Compared with Fiscal Year Ended December 31, 2011” for further discussion of the impact on our financial results. Contracts Receivable, Including Retainage Contracts receivable are generally based on amounts billed to the customer. At December 31, 2012 and 2011, contracts receivable included $18.1 million and $22.6 million of retainage, respectively, which is being withheld by customers until completion of the contracts. All other contracts receivable include only balances approved for payment by the customer. Many of the contracts under which the Company performs work contain retainage provisions. Retainage refers to that portion of billings made by the Company but held for payment by the customer pending satisfactory completion of the project. Retainage on active contracts is classified as a current asset regardless of the term of the contract and is generally collected within one year of the completion of a contract. Based upon a review of outstanding contracts receivable, historical collection information and existing economic conditions, management has determined that all contracts receivable at December 31, 2012, including retainage, are fully collectible, and, accordingly, no allowance for doubtful accounts against contracts receivable was necessary. Contracts receivable are written off based on individual credit evaluation and specific circumstances of the customer, when such treatment is warranted. Valuation of Long-Lived Assets. Long-lived assets, which include property, equipment and acquired intangible assets, including goodwill, are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. Impairment evaluations involve fair values and management estimates of useful asset lives and future cash flows. Actual useful lives and cash flows could be different from those estimated by management, and this could have a material effect on operating results and financial position. Goodwill must be reviewed for impairment at least annually, and we completed our most recent annual impairment review for historical goodwill during the fourth quarter of 2012. It indicated that there was no impairment in goodwill. Note 8 to the Consolidated Financial Statements discusses the three valuation approaches used by the Company to determine the fair value of the Company’s equity for purposes of evaluating whether there is an indication of goodwill impairment. These valuation approaches are impacted by a number of factors but the key ones are the Company’s stock price, the Company’s financial performance relative to its peer group, the financial performance of the peer group, the estimated control premium and the estimated forecasted cash flows. The valuation approaches contain uncertainty regarding the estimates used. One of the largest uncertainties relates to government and state spending which management expects to increase in the next few years. There are a number of other uncertainties with respect to our future financial performance that could impact estimated future cash flows. These are discussed in a number of places including “Item IA. Risk Factors.” We determined that the fair value of the Company’s equity was approximately 3% above the carrying value of the Company’s equity, and therefore a modest change in estimated forecasted cash flows could result in an impairment of goodwill. In 2011, we determined that there was an impairment in goodwill of $67.0 million, which has been recognized as a charge in 2011. At December 31, 2012, we had goodwill with a remaining carrying amount of approximately $54.8 million. 26 Income Taxes. Deferred tax assets and liabilities are recognized based on the differences between the financial statement carrying amounts and the tax bases of assets and liabilities. We regularly review our deferred tax assets for recoverability and, where necessary, establish a valuation allowance. We are subject to the alternative minimum tax, or AMT, and payments of AMT result in a reduction of our deferred tax liability. Segment Reporting. We operate in one segment and have only one reportable segment and one reporting unit component, heavy civil construction. In making this determination, we considered that each project has similar characteristics, includes similar services and similar types of customers and is subject to similar regulatory and economic environments. We organize, evaluate, and manage our financial information around each project when making operating decisions and assessing overall performance. Even if our local offices were to be considered separate components of our heavy civil construction operating segment, those components could be aggregated into a single reporting unit for purposes of testing goodwill for impairment under ASC 280 and EITF D-101 because our local offices all have similar economic characteristics and are similar in all of the following areas: The nature of the products and services — each of our local offices perform similar construction projects — they build, reconstruct and repair roads, highways, bridges, light rail and water, waste water and storm drainage systems. The nature of the production processes — our heavy civil construction services rendered in the construction process for each of our construction projects performed by each local office is the same — they excavate dirt, remove existing pavement and pipe, lay aggregate or concrete pavement, pipe and rail and build bridges and similar large structures in order to complete our projects. The type or class of customer for products and services — substantially all of our customers are state departments of transportation, cities, counties, and regional water, rail and toll-road authorities. A substantial portion of the funding for the state departments of transportation to finance the projects we construct is furnished by the federal government. The methods used to distribute products or provide services — the heavy civil construction services rendered on our projects are performed primarily with our own field work crews (laborers, equipment operators and supervisors) and equipment (backhoes, loaders, dozers, graders, cranes, pug mills, crushers, and concrete and asphalt plants). The nature of the regulatory environment — we perform substantially all of our projects for federal, state and municipal governmental agencies, and all of the projects that we perform are subject to substantially similar regulation under U.S. and state department of transportation rules, including prevailing wage and hour laws; codes established by the federal government and municipalities regarding water and waste water systems installation; and laws and regulations relating to workplace safety and worker health of the U.S. Occupational Safety and Health Administration and to the employment of immigrants of the U.S. Department of Homeland Security. The economic characteristics of our local offices are similar. While profit margin objectives included in contract bids have some variability from contract to contract, our profit margin objectives are not differentiated by our chief operating decision maker or our office management based on local office location. Instead, the projects undertaken by each local office are primarily competitively-bid, fixed-unit or negotiated lump-sum price contracts, all of which are bid based on achieving gross margin objectives that reflect the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the makeup and level of our existing backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, anticipated start and completion dates, construction risks, penalties or incentives and general economic conditions. Results of Operations. Backlog at December 31, 2012 At December 31, 2012, our backlog of construction projects was $656 million, as compared to $616 million at December 31, 2011. Our Company was awarded $643 million of new contracts in 2012, excluding acquired contracts, compared to $595 million of new contracts in 2011. Our contracts are typically completed in 12 to 36 months. At December 31, 2012, there was approximately $63 million excluded from our consolidated backlog where we were the apparent low bidder, but had not yet been formally awarded the contract or the contract price had not been finalized. Backlog includes $77 million attributable to our share of estimated revenues related to joint ventures where we are a noncontrolling joint venture partner. As discussed further in “Item 1. Business―Recent Developments―Financial Results for 2012, Operational Issues and Outlook for 2013 Financial Results,” based on our current estimates, the gross margin in our backlog is lower than the gross margin of 7.5% realized in 2012 as a result of operational issues and lower infrastructure capital expenditures by federal and state governments. 27 We do, however, expect that our markets will ultimately recover from the conditions discussed in “Item 1. Business” and that our backlog and revenues will grow and gross margins, net income and earnings per share will return to levels more consistent with historical rates of return. However, we cannot predict the timing of such a return to historical normalcy in our markets. We believe that the Company is in sound financial condition and has the resources and management experience to weather current market conditions and to continue to compete successfully for projects as they become available at acceptable profit margin levels. See “Item 1. Business — Our Markets, Competition and Customers” for a more detailed discussion of our markets and their funding sources. Fiscal Year Ended December 31, 2012 Compared with Fiscal Year Ended December 31, 2011 Revenues ........................................................................$ Gross profit ....................................................................$ General and administrative expenses ............................. Goodwill impairment ..................................................... Unusual items ................................................................. Other income (expense) ................................................. Operating income (loss) ................................................. Gains (losses) on the sale of short-term investments ..... Interest income ............................................................... Interest expense .............................................................. Income (loss) before income taxes and earnings attributable to noncontrolling interests .................... Income tax benefit (expense) ......................................... Net income (loss) ........................................................... Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures .................................. Net income (loss) attributable to Sterling common $ $ 2011 2012 (Dollar amounts in thousands) 630,507 47,472 (35,187) -- (511) 3,205 14,979 1,797 1,301 (944) 501,156 39,837 (24,785) (67,000) (676) 390 (52,234) 94 1,655 (1,231) 17,133 579 17,712 (51,716) 17,012 (34,704) (18,009) (1,196) stockholders ..............................................................$ (297) $ (35,900) Gross margin .................................................................. Operating margin (deficit) .............................................. Contract backlog, end of year ........................................$ 7.5 % 2.4 % 656,000 8.0 % (10.4) % $ 616,000 NM – Not meaningful. Revenues. % Change 25.8% 19.2 42.6 NM NM NM NM NM (21.4) (23.3) NM (96.3) NM NM (99.2) (6.3) NM 6.5 Revenues for 2012 increased 25.8% compared with the prior year. Most of this increase is attributable to revenues from contracts performed in Arizona and California which totaled $168.9 million in 2012 as compared to $19.5 million in 2011. Prior to the August 1, 2011 acquisitions of JBC and Myers, we did not perform any work in these states. Since our acquisition of these entities they have performed well in their respective markets. We also had higher revenues in Utah, Nevada, and Texas reflecting higher activity levels and improvements in estimated profitability in certain projects. During 2012, results included $43.7 million of revenues and $11.8 million of gross profit attributable to our share of the results from a construction project joint venture in which we were a minority participant. The joint venture’s construction project is substantially complete, and we do not anticipate a significant amount of additional earnings from this joint venture in future periods. Gross Profit. Gross profit increased $7.6 million for 2012 compared with the prior year. Gross margins declined to 7.5% in 2012 from 8.0% in 2011 due to net downward revisions of estimated revenues and gross margins on a number of construction projects, primarily in Texas. Upward revisions on projects in Utah substantially offset the downward revisions for Texas projects in 2012. Downward revisions for Texas projects had a significant impact on 2011 gross profits as well. These upward revisions were primarily related to the joint venture project which is substantially complete discussed under “Revenues” above. The net revisions to contract estimates were the result of different factors affecting various contracts, some positively and some negatively. While there are a number of factors which 28 cause the costs incurred and gross profit realized on our contracts to vary, sometimes substantially, from our original projections, the primary factors which resulted in downward revisions in estimates in 2012 were: conditions or contract requirements that differed from those assumed in the original bid or contract; delays in quickly identifying and taking measures to address issues which arose during production. lower than expected activity levels; and At December 31, 2012, we had approximately 91 contracts-in-progress which were less than 90% complete of various sizes, of different expected profitability and in various stages of completion. The nearer a contract progresses toward completion, the more visibility we have in refining our estimate of total revenues (including incentives, delay penalties and change orders), costs and gross profit. Thus gross profit as a percent of revenues can increase or decrease from comparable and sequential quarters due to variations among contracts and depending upon the stage of completion of contracts. General and administrative expenses General and administrative expenses for 2012 included a full year of general and administrative expenses for JBC and Myers which we acquired on August 1, 2011 as well as an increase in compensation related expenses and professional fees. As a percent of revenues, general and administrative expenses in 2012 were higher at 5.7% compared with 5.1% for the prior year and included a signing bonus of $250,000 paid to our newly appointed CEO and $670,000 in compensation for our retiring CEO. Goodwill Impairment. During the fourth quarter of 2011, the Company completed an evaluation of the carrying value of goodwill resulting in an impairment charge of $67.0 million. This charge had an impact of $41.8 million on the net loss attributable to Sterling common stockholders (net of the related tax benefits and reduced for the amount attributable to noncontrolling interest owners) or $2.55 per diluted share. No goodwill impairment charge was recorded in 2012. See Note 8 to the Consolidated Financial Statements. Income taxes. Our effective income tax rates for 2012 and 2011 were (3.4)% and 32.9%, respectively, and varied from the statutory rate primarily as a result of net income attributable to noncontrolling interest owners which are taxed to those owners rather than Sterling. In addition, the effective tax rate for 2012 was impacted by non-taxable interest income, and the effective tax rate for 2011 was impacted by the portion of the goodwill impairment attributable to goodwill that is not deductible for tax purposes. Net income attributable to noncontrolling interests. Net income attributable to noncontrolling interest owners increased in 2012 compared with 2011 and is primarily related to net income attributable to the 20% noncontrolling interest owners in RLW. This subsidiary was 80% owned until December 31, 2012 when we acquired the remaining 20% interest. As discussed further in Note 2 to the consolidated financial statements, the members of RLW, including the Company, agreed to amend RLW’s operating agreement effective January 1, 2012 to provide that any goodwill impairment, including the 2011 fourth quarter goodwill impairment, is not to be allocated to RLW for the purpose of calculating the distributions to be made to the RLW noncontrolling interest holders. This amendment resulted in an increase in the net income attributable to RLW’s noncontrolling interests of $6.7 million during 2012. This increase is included in “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures” in the accompanying consolidated statements of operations with an increase in the “Current obligation for noncontrolling owners’ interest in subsidiaries and joint ventures” in the consolidated balance sheet. This increase has a related tax impact of $2.4 million which increased the tax benefit for 2012. 29 Fiscal Year Ended December 31, 2011 Compared with Fiscal Year Ended December 31, 2010. 2011 2010 % Change Revenues ...............................................................................$ Gross profit ........................................................................... General and administrative expenses .................................... Goodwill impairment………………………………………. Unusual items ....................................................................... Other income (expense) ........................................................ Operating income (loss) ........................................................ Gains (losses) on the sale of short-term investments ............ Interest income ...................................................................... Interest expense .................................................................... Income (loss) before income taxes and earnings attributable to noncontrolling interests .................................................... Income tax benefit (expense) ................................................ Net income (loss) .................................................................. Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures ............................................................. Net income (loss) attributable to Sterling common stockholders ..........................................................................$ Gross margin ......................................................................... Operating margin (deficit) .................................................... Contract backlog, end of year ............................................... $ NM – not meaningful Revenues. $ (Dollar amount in thousands) 459,893 62,705 (24,895 ) -- -- (1,900 ) 35,910 (38 ) 1,809 (1,187 ) 501,156 39,837 (24,785) (67,000) (676) 390 (52,234) 94 1,655 (1,231) (51,716) 17,012 (34,704) 36,494 (10,270 ) 26,224 9.0% (36.5) (0.4) NM NM NM NM NM (8.5) 3.7 NM NM NM (1,196) (7,137 ) (83.2) (35,900) % 8.0 (10.4) % % $ 19,087 13.6 % 7.8 % 616,000 $ 522,000 NM (41.0) NM 18.0 Revenues increased 9.0% or $41.3 million in fiscal year 2011 over fiscal year 2010. The increase was primarily due to increased production levels in 2011 as a result of execution on contracts awarded in Texas markets in 2010, increased revenues resulting from a higher level of activity on joint ventures in which we participate, primarily in Utah, and $19.5 million in revenues in Arizona and California attributable to JBC and Myers which were acquired on August 1, 2011. Revenues for our Nevada operations declined from the prior year due to fewer construction contracts, and in Texas the increase in revenues between the periods was less than expected due to severe adverse weather conditions during the first quarter of 2011 and delays by a customer in starting two sizable contracts. Gross Profit. Gross profit decreased $22.8 million for 2011 compared with the prior year and gross margins decreased to 8.0% from 13.6% in 2010 due to net downward revisions of estimated revenues and gross margins on a number of construction projects, primarily in Texas. The primary factors which caused the net charge in 2011 were: onsite conditions that differed from those assumed in the original bid or contract; delays caused by weather conditions; contract or project modifications creating unanticipated costs not covered by change orders; failure by our suppliers, subcontractors or customers to perform their obligations; shortages in the availability of skilled workers in the geographic location of certain projects, especially due to the rapid expansion of our business in certain markets; delays in obtaining required governmental permits or approvals causing cost overruns on certain projects, including two large construction projects in Dallas where the construction start date was delayed significantly by the owner; and delays in quickly identifying and taking measures to address issues which arose during production. 30 At December 31, 2011, we had approximately 83 contracts-in-progress which were less than 90% complete of various sizes, of different expected profitability and various stage of completion. General and administrative expenses. General and administrative expenses for 2011 included $676,000 related to litigation and acquisition related costs which are shown separately in the table above. In addition, 2011 included the general and administrative expenses of the two companies we acquired on August 1, 2011 as well as an increase in salaries, wages and related benefits primarily resulting from added positions. Offsetting these increases was a decrease in bonus compensation resulting from lower earnings for the period. As a percent of revenues, general and administrative expenses were 5.1% in 2011 compared with 5.4% in 2010. Income taxes. The Company’s effective income tax rates for 2011 and 2010 were 32.9% and 28.1%, respectively, and varied from the statutory rate primarily as a result of net income attributable to noncontrolling interest owners which are taxed to those owners rather than Sterling. In addition, the effective tax rate for 2011 was impacted by the portion of the goodwill impairment attributable to goodwill that is not deductible for tax purposes. Net income attributable to noncontrolling interests. The net income attributable to noncontrolling interest owners decreased in 2011 compared with 2010 as a result of the $6.7 million impact for the impairment of goodwill attributable to noncontrolling interest owners. Offsetting this impact was an increase in earnings from a 60% owned consolidated joint venture controlled by RLW as well as income attributable to the noncontrolling interest owners of Myers which was acquired in August 2011. Historical Cash Flows. The following table sets forth information about our cash flows and liquidity (in thousands): Years Ended December 31, 2011 2012 2010 Net cash provided by (used in): Operating activities ......................................................$ Capital expenditures .................................................... Proceeds from sale of property and equipment ............ Acquisition of noncontrolling interest ......................... Net assets of acquired companies ................................ Net sales (purchases) of short-term securities .............. Distributions to noncontrolling interest owners ........... Purchases of treasury stock .......................................... Net drawdowns (repayment) on the Credit Facility ..... Other ............................................................................ Total ........................................................................$ 24,789 $ (37,359) 12,464 (23,144) -- (3,493) (10,185) -- 24,012 (313) (13,229) $ 20,988 $ (23,989) 1,296 (8,205) (3,911) (7,897) (7,809) (3,592) -- 49 (33,070) $ 47,073 (13,409) 1,607 -- -- 2,946 (4,160) -- (40,000) 978 (4,965) Cash and cash equivalents ....................................................$ Working capital ....................................................................$ 3,142 $ 87,484 $ 16,371 94,738 As of December 31, 2011 2012 Operating Activities. Significant non-cash items included in operating activities are: the impairment of goodwill of $67.0 million in 2011; depreciation and amortization which increased to $19.0 million in 2012 as compared to $17.3 million in 2011 and $15.8 million in 2010 as a result of an increase in capital expenditures as well as depreciation associated with JBC and Myers which were acquired in 2011; deferred tax (benefit) expense was $(1.2) million, $(18.7) million and $3.9 million in 2012, 2011 and 2010, respectively; the deferred tax benefit for 2011 is primarily the result of recording the impairment of goodwill 31 for financial reporting purposes whereas goodwill is amortized for tax return purposes; the deferred tax expense in 2010 is the result of recognizing accelerated depreciation methods used on equipment for tax purposes as compared to straight-line depreciation used for financial reporting purposes and amortizing goodwill for tax return purposes but not for financial reporting purposes. Besides the net income (loss) in 2012, 2011 and 2010 and the non-cash items discussed above, other significant components of cash flows from operations (which excludes the impact of changes attributable to the net assets of acquired companies) was a decrease in cash and cash equivalents related to non-cash working capital of $(4.7) million, $(10.8) million, and $(2.4) million in 2012, 2011 and 2010, respectively. Investing Activities. Capital equipment is acquired as needed to support increased levels of production activities and to replace retiring equipment. Expenditures for the replacement of certain equipment and to expand our construction fleet totaled $37.4 million in 2012. Proceeds from the sale of property and equipment totaled $12.5 million for 2012 with an associated net gain of $3.2 million. For the years ended December 31, 2011 and 2010, capital expenditures totaled $24.0 million and $13.4 million, respectively, while proceeds from the sale of property and equipment totaled $1.3 million and $1.6 million, respectively, with an associated net gain/(loss) of $0.4 million and ($1.9) million, respectively. Capital expenditures for 2012 are higher than 2011 to support our higher level of operations and to replace equipment. In addition, proceeds from sales of property and equipment in 2012 have been higher than in previous periods as management undertook a program to dispose of underutilized and aging equipment. The lower expenditures in 2010 reflect the smaller size of our operations as well as efforts to minimize expenditures in response to the poor economic conditions. During 2012, 2011 and 2010, the Company had net purchases (sales) of short-term securities of $3.5 million, $7.9 million and $(2.9) million, respectively. The net purchases in 2012 and 2011 were primarily due to the investment of cash generated by operations, after repayment of indebtedness. On August 1, 2011, the Company used $8 million of existing cash and short-term investments to fund the acquisition of JBC, a heavy civil construction business operating in Arizona. Additional purchase consideration of up to $5 million may be paid in connection with this acquisition subject to the achievement of certain earnings requirements during the period from 2011 through July 31, 2016. Also on August 1, 2011, the Company acquired a 50% interest in Myers, a construction limited partnership located in California. The Company paid a purchase price of $1.2 million which was funded by available cash of the Company. In December 2011, the Company acquired the remaining 8.33% interest in RHB from the noncontrolling interest owner for $8.2 million as a result of the owner’s exercise of his right to put the interest. On December 31, 2012, the Company acquired the remaining unowned 20% interest in RLW for $23.1 million. The purchase price was subject to further adjustment once earnings for 2012 were finalized and as result an additional $568,000 shall be paid in 2013. Financing Activities. Financing activities in 2012 consisted of drawdowns and repayments on the Credit Facility (with a net drawdown of $24.0 million, primarily to fund the purchase of the 20% interest in RLW on December 31, 2012 discussed above) and distributions to noncontrolling interest owners of $10.2 million. Financing activities in 2011 primarily reflect distributions to noncontrolling interest owners of $7.8 million and purchases of treasury stock of $3.6 million. Financing activities in 2010 primarily reflect a reduction of $40.0 million in borrowings under our Credit Facility and distributions to noncontrolling interest owners of $4.2 million. The amount of borrowings under the Credit Facility is based on the Company’s expectations of working capital requirements. Liquidity and Sources of Capital . The need for working capital for our business varies due to fluctuations in: customer receivables and contract retentions; costs and estimated earnings in excess of billings; billings in excess of costs and estimated earnings; the size and status of contract mobilization payments and progress billings; and the amounts owed to suppliers and subcontractors. Some of these fluctuations can be significant. As of December 31, 2012, we had working capital of $87.5 million, a decrease of $7.3 million over December 31, 2011. The decrease in working capital was the result of the following (in thousands): 32 Net income ........................................................................................................ $ Current portion of obligation to noncontrolling interest owners of RLW…….. Depreciation and amortization .......................................................................... Capital expenditures ......................................................................................... Acquisition of noncontrolling interests ............................................................. Proceeds from sales of property and equipment, net of gain (loss)…………… Distributions to noncontrolling interest owners ................................................ Net drawdowns on the Credit Facility………………………………………... Other ................................................................................................................. Total decrease in working capital ..................................................................... $ 17,712 (2,887) 18,997 (37,359) (23,144) 9,280 (10,185) 24,012 (3,680) (7,254) In addition to our available cash and cash equivalents, short-term investments and cash provided by operations, from time to time, we use borrowings under our $50.0 million Credit Facility with Comerica Bank to finance our capital expenditures and working capital needs. The Credit Facility has a maturity date of September 30, 2016. Subject to the conditions under the terms of the Credit Facility, including the financial covenants discussed below, up to $50 million in borrowings and letters of credit is available under the amended Credit Facility with, under certain circumstances, an optional increase of $50 million. Borrowings under the Credit Facility are secured by all assets of the Company, other than proceeds and other rights under our construction contracts which are pledged to our bond surety. At December 31, 2012, there were borrowings of $24.0 million outstanding under the Credit Facility and a letter of credit of $1.8 million outstanding which reduced availability under the Credit Facility to $24.2 million. In January 2013, the Company sold approximately $27.7 million of its short-term investments in order to repay the $24.0 million of borrowings outstanding under the Credit Facility at December 31, 2012. Average borrowings under the Credit Facility for the 2012 fiscal year were $1.1 million and the largest amount of borrowings under the Credit Facility was $24.0 million on December 31, 2012. Average borrowings under the Credit Facility for the 2011 fiscal year were $104,000, and the largest amount of borrowings under the Credit Facility was $8.0 million on September 30, 2011. The Credit Facility is subject to our compliance with certain covenants, including financial covenants at year-end relating to leverage, tangible net worth, and asset coverage. The Credit Facility contains restrictions on our ability to: Make distributions or pay dividends; Incur liens and encumbrances; Incur further indebtedness; Guarantee obligations; Dispose of a material portion of assets or merge with a third party; and Make investments in securities. To date the Company has not experienced any difficulty in borrowing under the Credit Facility, and the Company was in compliance with all covenants under the Credit Facility as of December 31, 2012. Management believes that the Company has sufficient liquid financial resources, including the unused portion of its Credit Facility, to fund its requirements for the next twelve months of operations, including its bonding requirements, and the Company expects no material adverse change in its liquidity. Future developments or events, such as an increase in our level of purchases of equipment to support significantly higher backlog or an acquisition of another company could, however, affect our level of working capital and tangible net worth. 33 Contractual Obligations. The following table sets forth our fixed, non-cancelable obligations at December 31, 2012: Payments due by period Total < 1 Year 1 - 3 Years (Amounts in thousands) 4 – 5 Years > 5 Years Credit Facility .....................................................$ 24,012 $ Operating leases .................................................. Mortgage ............................................................. Earn-out liability to former owner of JBC .......... RLW put/call liabilities ...................................... 6,006 262 2,420 568 $ 33,268 $ -- 941 73 2,047 568 3,629 $ $ -- 1,903 189 -- -- 2,092 $ $ 24,012 1,129 -- 373 -- 25,514 $ $ -- 2,033 -- -- -- -- 2,033 Our obligations for interest are not included in the table above as these amounts vary according to the levels of debt outstanding at any time. Interest on our Credit Facility is paid monthly and fluctuates with the balances outstanding during the year, as well as with fluctuations in interest rates. In 2012, interest on the Credit Facility was approximately $37,000. To manage risks of changes in the material prices and subcontracting costs used in submitting bids for construction contracts, we generally obtain firm quotations from our suppliers and subcontractors before submitting a bid. These quotations do not include any quantity guarantees, and we have no obligation for materials or subcontract services beyond those required to complete the contracts that we are awarded for which quotations have been provided. As is customary in the construction business, we are required to provide surety bonds to secure our performance under construction contracts. Our ability to obtain surety bonds primarily depends upon our capitalization, working capital, past performance, management expertise and reputation and certain external factors, including the overall capacity of the surety market. Surety companies consider such factors in relationship to the amount of our backlog and their underwriting standards, which may change from time to time. We have pledged all proceeds and other rights under our construction contracts to our bond surety company. Events that affect the insurance and bonding markets may result in bonding becoming more difficult to obtain in the future, or being available only at a significantly greater cost. To date, we have not encountered difficulties or material cost increases in obtaining new surety bonds. Capital Expenditures. Capital equipment is acquired as needed by increased levels of production and to replace retiring equipment. Management expects capital expenditures in 2013 to be lower than the $37.4 million incurred in 2012; however, the award of a project requiring significant purchases of equipment or other factors could result in increased expenditures. Inflation. Inflation generally has not had a material impact on our financial results; however, from time to time increases in oil, fuel, and steel prices have affected our cost of operations. Anticipated cost increases and reductions are considered in our bids to customers on proposed new construction projects. In order to mitigate our exposure to increases in fuel prices, we have a program to hedge our exposure to increases in diesel fuel prices by entering into swap contracts for diesel fuel. We believe that the gains and losses on these contracts will tend to offset increases and decreases in the price we pay for diesel fuel and reduce the volatility of such fuel costs in our operations. As of December 31, 2012, we had diesel futures contracts for 1,190,000 gallons which fixed prices at an average of $2.92 per gallon. This compares to the December 31, 2012 price for off-road ultra-low sulfur diesel published by Platts of $2.99. We will continue to evaluate this strategy and may increase or decrease our commitments depending on our forecast of the diesel fuel market and other operational considerations. There can be no assurance that this strategy will be successful. Where we are the successful bidder on a project, we execute purchase orders with material suppliers and contracts with subcontractors covering the prices of most materials and services, other than oil and fuel products, thereby mitigating future price increases and supply disruptions. These purchase orders and contracts do not contain quantity guarantees, and we have no obligation for materials and services beyond those required to complete the contracts with our customers. There can be no assurance that increases in prices of oil and fuel used in our business will be adequately covered by the estimated escalation we have included in our bids or derivative contracts entered 34 into to hedge against such increases, and there can be no assurance that all of our vendors will fulfill their pricing and supply commitments under their purchase orders and contracts with the Company. We adjust our total estimated costs on our projects when we believe it is probable that we will have cost increases which will not be recovered from customers, vendors or re-engineering. Off-Balance Sheet Arrangements and Joint Ventures. We participate in various construction joint venture partnerships in order to share expertise, risk and resources for certain highly complex projects. The venture’s contract with the project owner typically requires joint and several liability among the joint venture partners. Although our agreements with our joint venture partners provide that each party will assume and fund its share of any losses resulting from a project, if one of our partners was unable to pay its share, we would be fully liable for such share under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurred a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement. At December 31, 2012, there was approximately $214 million of construction work to be completed on unconsolidated construction joint venture contracts, of which $77 million represented our proportionate share. Due to the joint and several liability under our joint venture arrangements, if one of our joint venture partners fails to perform, we and the remaining joint venture partners would be responsible for completion of the outstanding work. As of December 31, 2012, we are not aware of any situation that would require us to fulfill responsibilities of our joint venture partners pursuant to the joint and several liability under our contracts. Off-balance sheet arrangements related to the operating leases are included in the table in “Contractual Obligations” above. New Accounting Pronouncements. See “Recent Accounting Pronouncements” in Note 1 for a discussion of new accounting pronouncements. Item 7A. Quantitative and Qualitative Disclosures about Market Risk. Changes in interest rates are one of our sources of market risks. Outstanding indebtedness under our Credit Facility bears interest at floating rates. The average borrowings under this facility during 2012 were $1.1 million. Based on our expected levels of borrowings for 2013, we do not expect that a change in our interest rate would have a material impact on our results from operations. We are exposed to market risk from changes in commodity prices. In the normal course of business, we enter into derivative transactions, specifically cash flow hedges, to mitigate our exposure to diesel fuel commodity price movements. We do not participate in these transactions for trading or speculative purposes. While the use of these arrangements may limit the benefit to us of decreases in the prices of diesel fuel, it also limits the risk of adverse price movements. The following represents the outstanding contracts at December 31, 2012: Period Beginning Ending Range 2013 2014 January 1, 2013 December 31, 2013 $ 2.80 – 3.29 $ January 1, 2014 December 31, 2014 $ 2.79 – 2.93 $ Weighted Average 2.96 2.84 Price Per Gallon Fair Value of Derivatives at December 31, 2012 (in thousands) 7 1 8 Remaining Volume (gallons) 830,000 $ 360,000 $ See “Inflation” above regarding risks associated with materials and fuel purchases required to complete our construction contracts. Item 8. Financial Statements and Supplementary Data. Financial statements start on page F-1. Item 9. Changes in and Disagreements with Accountants on Accounting and Financial Disclosure. None 35 Item 9A. Controls and Procedures. Evaluation of Disclosure Controls and Procedures. The Company’s principal executive officer and principal financial officer reviewed and evaluated the Company’s disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934) as of December 31, 2012. Based on that evaluation, the Company’s principal executive officer and principal financial officer have concluded that the Company’s disclosure controls and procedures were effective at December 31, 2012 to ensure that the information required to be disclosed by the Company in this Annual Report on Form 10-K is recorded, processed, summarized and reported within the time periods specified in the Securities and Exchange Commission’s rules and forms and is accumulated and communicated to the Company’s management including the principal executive and principal financial officers, as appropriate to allow timely decisions regarding required disclosure. Management’s Report on Internal Control over Financial Reporting. The Company’s management is responsible for establishing and maintaining adequate internal control over financial reporting (as defined in Rule 13a-15(f)) under the Securities Exchange Act of 1934). Under the supervision and with the participation of the Company’s management, including the principal executive officer and principal financial officer, the Company conducted an evaluation of the effectiveness of internal control over financial reporting at December 31, 2012. In making this assessment, management used the criteria set forth by the Committee of Sponsoring Organizations of the Treadway Commission (COSO) in Internal Control-Integrated Framework. The Company’s management has concluded that, at December 31, 2012, the Company’s internal control over financial reporting is effective based on these criteria. Remediation of Material Weakness in Internal Control over Financial Reporting. In the fourth quarter of 2011, management identified a material weakness related to the established process for estimating revenues and costs on its construction projects. The accuracy of our revenue and profit recognition in a given period is dependent on the accuracy of our estimates of the revenues and costs to finish uncompleted contracts. Under our established estimation process, project managers make estimates for all of our significant contracts on a monthly basis using a highly detailed “bottom up” approach, and operations managers review those estimates for reasonableness. Our projects can be highly complex, and in almost every case, the profit margin estimates for a contract will either increase or decrease to some extent from the amount that was originally estimated at the time of bid. In order to ensure that revenues and gross profit are recognized in the proper period under the percentage-of- completion method of accounting, the monthly revisions to estimated revenues and costs must reflect changes in job performance, job conditions, change orders and estimated profitability, including those changes arising from contract penalty provisions and final contract settlements, which are known at that time. During the fourth quarter of 2011, significant revisions to estimated revenues and costs were made for a number of construction projects. In response, management undertook a thorough review and determined that certain of these revisions should have been made in prior quarters, but the impact of revising these estimates would not have had a material impact on revenues or gross profit reported in prior periods had the changes been made in the appropriate prior period. Management also determined that in some instances the procedures performed to make periodic revisions in estimates were not being made timely and that the review procedures being performed by operations management were not adequate to ensure that a material impact on the financial statements resulting from such revisions in estimates would be recognized in the proper period. Based on this evaluation and the material weakness noted above, management concluded that we did not maintain effective internal control over financial reporting at December 31, 2011. While the risks of cost overruns and changes in estimated contract revenues are an inherent part of the construction business, beginning in the first quarter of 2012 and through the fourth quarter of 2012, we implemented the following changes in order to improve the profitability of our projects, reduce the variability in profitability of our projects in the future and strengthen the internal control environment: changed roles and responsibilities to improve functional support and controls; developed management tools designed to improve the estimating process and increase the oversight of that process; implemented processes designed to better identify, evaluate and quantify risks for individual projects; improved the methodologies for allocating overhead, indirect costs and equipment costs to individual projects; and improved the timeliness and content of reporting available to operations management. 36 Changes in Internal Control over Financial Reporting. We maintain a system of internal control over financial reporting that is designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with accounting principles generally accepted in the United States. Based on the most recent evaluation, except for certain changes made related to the controls over the estimation of revenues and gross profits on construction projects discussed above, we have concluded that no significant changes in our internal control over financial reporting occurred during the three months ended December 31, 2012 that have materially affected or are reasonably likely to materially affect, our internal control over financial reporting. Inherent Limitations on Effectiveness of Controls. Internal control over financial reporting may not prevent or detect all errors and all fraud. Also, projections of any evaluation of effectiveness of internal control to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate. Item 9B. Other Information. None. PART III Item 10. Directors, Executive Officers and Corporate Governance of the Registrant. The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 9, 2013 and is incorporated herein by reference. The information can be found under the following headings in the proxy statement: Item 10 Information Location/Heading in the Proxy Statement Directors .......................................................... Election of Directors (Proposal 1) Compliance With Section 16(a) of the Exchange Act ........................................... Stock Ownership Information Code of Ethics ................................................. The Corporate Governance & Nominating Committee Communication with the Board; nominations; Board and committee meetings; committees of the Board; Board leadership and risk oversight; and director compensation. .................................................. Board Operations Information relating to the Company’s executive officers is set forth at the end of Part I of this report under the caption “Executive Officers of the Registrant” and is incorporated herein by reference. Item 11. Executive Compensation The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 9, 2013 and is incorporated herein by reference. The information can be found under the heading Executive Compensation in the proxy statement. Item 12. Security Ownership of Certain Beneficial Owners and Management, and Related Stockholder Matters. The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 9, 2013 and is incorporated herein by reference. Equity Compensation Plan Information can be found in the proxy statement under the heading Executive Compensation. Information regarding the ownership of the Company’s common stock can be found in the proxy statement under the heading Stock Ownership Information. Item 13. Certain Relationships and Related Transactions, and Director Independence. The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 9, 2013 and is incorporated herein by reference. 37 Information regarding any relationships between directors and officers and the Company can be found in the proxy statement under the heading Business Relationships with Directors and Officers. Information about director independence can be found in the proxy statement under the heading Election of Directors (Proposal 1). Item 14. Principal Accountant Fees and Services. The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 9, 2013 and is incorporated herein by reference. The information can be found in the proxy statement under the heading Information about Audit Fees and Audit Services. PART IV Item 15. Exhibits and Financial Statement Schedules. The following Financial Statements and Financial Statement Schedules are filed with this Report: Financial Statements: Reports of the Company’s Independent Registered Public Accounting Firm Consolidated Balance Sheets as of December 31, 2012 and 2011 Consolidated Statements of Operations for the years ended December 31, 2012, 2011 and 2010 Consolidated Statements of Comprehensive Income (Loss) for the years ended December 31, 2012, 2011 and 2010 Consolidated Statements of Cash Flows for the years ended December 31, 2012, 2011 and 2010 Consolidated Statements of Stockholders’ Equity for the years ended December 31, 2012, 2011 and 2010 Financial Statement Schedules. None. Exhibits. The following exhibits are filed with this Report. Explanatory Note: Prior to changing its name to Sterling Construction Company, Inc. in November 2001, the Company had the following names during the following periods: Hallwood Holdings Incorporated Oakhurst Capital, Inc. Oakhurst Company, Inc. May 1991 to July 1993 July 1993 to April 1995 April 1995 to November 2001 References in the following exhibit list use the name of the Company in effect at the date of the exhibit. Number 2.1.1 Exhibit Title Purchase Agreement, dated as of December 3, 2009, by and among Kip Wadsworth, Ty Wadsworth, Con Wadsworth, Tod Wadsworth and Sterling Construction Company, Inc. (incorporated by reference to Exhibit 2.1 to Sterling Construction Company, Inc.’s Current Report on Form 8 K, filed on December 3, 2009 (SEC File No. 1-31993)). Agreement dated December 28, 2012 by and among Kip Wadsworth, Ty Wadsworth, Con Wadsworth, Tod Wadsworth and Sterling Construction Company, Inc. relating to the exercise of the right to purchase the remaining 20% of Ralph L. Wadsworth Construction Company, LLC. Certificate of Incorporation of Sterling Construction Company, Inc. (incorporated by reference to Exhibit 3.0 to Sterling Construction Company, Inc.’s Quarterly Report on Form 10-Q, filed on August 10, 2009 (SEC File No. 1-31993)). Bylaws of Sterling Construction Company, Inc. as amended through March 13, 2008 (incorporated by reference to Exhibit 3.1 to Sterling Construction Company, Inc.’s Current Report on Form 8-K, filed on March 19, 2008 (SEC File No. 1-31993)). Form of Common Stock Certificate of Sterling Construction Company, Inc. (incorporated by reference to Exhibit 4.5 to its Form 8-A, filed on January 11, 2006 (SEC File No. 1-31993)). 2.1.2* 3.1 3.2 4.1 10.1.1# The Sterling Construction Company, Inc. Stock Incentive Plan as amended and restated (incorporated by reference to Exhibit 10.13 to Sterling Construction Company, Inc.’s. Current Report on Form 8-K, filed on May 12, 2011 (SEC File No. 1-31993)). 38 10.1.2# 10.2# 10.3# Amendment dated May 6, 2012 to The Sterling Construction Company, Inc. Stock Incentive Plan (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.’s. Current Report on Form 8 K, filed on May 11, 2012 (SEC File No. 1-31993)). Forms of Stock Option Agreement under the Oakhurst Company, Inc. 2001 Stock Incentive Plan (incorporated by reference to Exhibit 10.51 to Sterling Construction Company, Inc.’s Annual Report on Form 10-K for the year ended December 31, 2004, filed on March 29, 2005 (SEC File No. 1-31993)). Summary of standard compensation arrangements for non-employee directors of Sterling Construction Company, Inc. adopted by the Board of Directors on August 3, 2011 (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.’s Quarterly Report on Form 10-Q, filed on November 8, 2011 (SEC File No. 1-31993)). 10.4.1 Credit Agreement by and among Sterling Construction Company, Inc., Texas Sterling Construction Co., Oakhurst Management Corporation and Comerica Bank and the other lenders from time to time party thereto, and Comerica Bank as administrative agent for the lenders, dated as of October 31, 2007 (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.’s Current Report on Form 8-K, Amendment No. 1 filed on November 21, 2007 (SEC File No. 1-31993)). 10.4.2 Joinder Agreement by Road and Highway Builders, LLC and Road and Highway Builders Inc. dated as of October 31, 2007 (incorporated by reference to Exhibit 10.3 to Sterling Construction Company, Inc.’s Current Report on Form 8-K, Amendment No. 1 filed on November 21, 2007 (SEC File No. 1-31993)). 10.4.3 Consent and Second Amendment to Credit Agreement by and among Sterling Construction Company, Inc., its subsidiaries, and Comerica Bank as Agent, Lender, Swing Line Lender and Issuing Lender dated as of November 8, 2011 (incorporated by reference to Exhibit 10.2 to Sterling Construction Company, Inc.’s Quarterly Report on Form 10-Q filed on November 8, 2011 (SEC File No. 1-31993)). 10.5 Security Agreement by and among Sterling Construction Company, Inc., Texas Sterling Construction Co., Oakhurst Management Corporation and Comerica Bank as administrative agent for the lenders, dated as of October 31, 2007 (incorporated by reference to Exhibit 10.4 to Sterling Construction Company, Inc.’s Quarterly Report on Form 10-Q, filed on November 9, 2009 (SEC File No. 1-31993)). 10.6#* Employment Agreement dated as of January 1, 2012 between Texas Sterling Construction Co. and Joseph P. Harper, Jr. 10.7# Change of Control Agreement dated as of January 1, 2011 between Sterling Construction Company, Inc. and Joseph P. Harper, Jr. (incorporated by reference to Exhibit 10.8 to Sterling Construction Company, Inc.’s Current Report on Form 8-K filed on May 12, 2011 (SEC File No. 1-31993)). 10.8# Employment Agreement dated as of January 1, 2011 between Sterling Construction Company, Inc. and Brian R. Manning (incorporated by reference to Exhibit 10.9 to Sterling Construction Company, Inc.’s Current Report on Form 8-K filed on May 12, 2011 (SEC File No. 1-31993)). 10.9# Change of Control Agreement dated as of January 1, 2011 between Sterling Construction 10.10# Company, Inc. and Brian R. Manning (incorporated by reference to Exhibit 10.10 to Sterling Construction Company, Inc.’s Current Report on Form 8-K filed on May 12, 2011 (SEC File No. 1-31993)). Employment Agreement dated as of February 1, 2011 between Sterling Construction Company, Inc. and Elizabeth D. Brumley (incorporated by reference to Exhibit 10.11 to Sterling Construction Company, Inc.’s Current Report on Form 8-K filed on May 12, 2011 (SEC File No. 1-31993)). 10.11# Change of Control Agreement dated as of January 1, 2011 between Sterling Construction Company, Inc. and Elizabeth D. Brumley (incorporated by reference to Exhibit 10.12 to Sterling Construction Company, Inc.’s Current Report on Form 8-K filed on May 12, 2011 (SEC File No. 1-31993)). 10.12.1# Employment Agreement dated as of March 17, 2006 between Sterling Construction Company, Inc. and Roger M. Barzun (incorporated by reference to Exhibit 10.11 to Sterling Construction Company, Inc.’s Annual Report on Form 10-K for the year ended December 31, 2009, filed on March 15, 2010 (SEC File No. 1-31993)). 10.12.2# Amendment dated January 18, 2012 of the Employment Agreement dated as of March 17, 2006 between Sterling Construction Company, Inc. and Roger M. Barzun. 39 10.13#* Employment Agreement dated December 28, 2012 between Ralph L. Wadsworth Construction Company, LLC and Kip L. Wadsworth. 10.14# Employment Agreement dated as of September 1, 2012 between Sterling Construction Company, Inc. and Peter E. MacKenna (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.’s Quarterly Report on Form 10-Q for the quarter ended September 30, 2012, filed on November 8, 2012 (SEC File No. 1-31993)). 21 Subsidiaries of Sterling Construction Company, Inc.: Name Texas Sterling Construction Co. Road and Highway Builders, LLC Road and Highway Builders Inc. Road and Highway Builders of California, Inc. Ralph L. Wadsworth Construction Company, LLC Ralph L. Wadsworth Construction Co. L.P. J. Banicki Construction, Inc. Consent of Grant Thornton LLP Certification of Peter E. MacKenna, Chief Executive Officer of Sterling Construction Company, State of Incorporation or Organization Delaware Nevada Nevada California Utah California Arizona Inc. 23.1* 31.1* 31.2* Certification of Elizabeth D. Brumley, Chief Financial Officer of Sterling Construction Company, Inc. 32.0* Certification pursuant to Section 1350 of Chapter 63 of Title 18 of the United States Code (18 U.S.C. 1350) of Peter E. MacKenna, Chief Executive Officer, and Elizabeth D. Brumley, Chief Financial Officer. 95.1* Mine Safety Disclosure # Management contract or compensatory plan or arrangement. * Filed herewith. 40 Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized. SIGNATURES STERLING CONSTRUCTION COMPANY, INC. Date: March 18, 2013 By: /s/ Peter E. MacKenna Peter E. MacKenna, Chief Executive Officer (duly authorized officer) Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated. Signature /s/ Patrick T. Manning Patrick T. Manning /s/ Peter E. MacKenna Peter E. MacKenna /s/ Elizabeth D. Brumley Elizabeth D. Brumley /s/ John D. Abernathy John D. Abernathy /s/ Robert A. Eckels Robert A. Eckels /s/ Joseph P. Harper, Sr. Joseph P. Harper, Sr. /s/Maarten D. Hemsley Maarten D. Hemsley /s/ Richard O. Schaum Richard O. Schaum /s/ Milton L. Scott Milton L. Scott /s/ David R. A. Steadman David R. A. Steadman /s/ Kip L. Wadsworth Kip L. Wadsworth Date March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 March 18, 2013 Title Chairman of the Board of Directors President & Chief Executive Officer (principal executive officer), Director Executive Vice President & Chief Financial Officer, Controller (principal financial officer and principal accounting officer), Treasurer Director Director Director Director Director Director Director Director 41 REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM To the Board of Directors and Stockholders Sterling Construction Company, Inc.: We have audited the accompanying consolidated balance sheets of Sterling Construction Company, Inc. (a Delaware corporation) and subsidiaries (the “Company”) as of December 31, 2012 and 2011, and the related consolidated statements of operations, comprehensive income (loss), stockholders’ equity and cash flows for each of the three years in the period ended December 31, 2012. These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements based on our audits. We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion. In our opinion, the consolidated financial statements referred to above present fairly, in all material respects, the financial position of Sterling Construction Company, Inc. and subsidiaries as of December 31, 2012 and 2011, and the results of their operations and their cash flows for each of the three years in the period ended December 31, 2012 in conformity with accounting principles generally accepted in the United States of America. We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), Sterling Construction Company, Inc. and subsidiaries’ internal control over financial reporting as of December 31, 2012, based on criteria established in Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO) and our report dated March 18, 2013 expressed an unqualified opinion. /s/ GRANT THORNTON LLP Houston, Texas March 18, 2013 F1 REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM To the Board of Directors and Stockholders Sterling Construction Company, Inc.: We have audited Sterling Construction Company, Inc. (a Delaware corporation) and subsidiaries’ (the “Company”) internal control over financial reporting as of December 31, 2012 based on criteria established in Internal Control— Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO). The Company’s management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Report on Internal Control over Financial Reporting. Our responsibility is to express an opinion on Sterling Construction Company, Inc. and subsidiaries’ internal control over financial reporting based on our audit. We conducted our audit in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion. A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements. Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate. In our opinion, Sterling Construction Company, Inc. and its subsidiaries maintained, in all material respects, effective internal control over financial reporting as of December 31, 2012, based on criteria established in Internal Control – Integrated Framework issued by COSO. We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the consolidated balance sheets of Sterling Construction Company Inc. and subsidiaries as of December 31, 2012 and 2011 and the related consolidated statements of operations, comprehensive income (loss), stockholders’ equity and cash flows for each of the three years in the period ended December 31, 2012, and our report dated March 18, 2013 expressed an unqualified opinion on those financial statements. /s/ GRANT THORNTON LLP Houston, Texas March 18, 2013 F2 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES CONSOLIDATED BALANCE SHEETS As of December 31, 2012 and 2011 (Amounts in thousands, except share and per share data) 2012 2011 Current assets: ASSETS Cash and cash equivalents .............................................................................................. $ Short-term investments ................................................................................................... Contracts receivable, including retainage ........................................................................ Costs and estimated earnings in excess of billings on uncompleted contracts ................ Inventories ....................................................................................................................... Deferred tax asset, net ..................................................................................................... Receivables from and equity in construction joint ventures ............................................ Other current assets ......................................................................................................... 3,142 $ 49,211 70,815 20,592 3,731 1,803 11,005 4,459 Total current assets ..................................................................................................... 164,758 Property and equipment, net ................................................................................................... 102,308 54,820 Goodwill ................................................................................................................................. 2,973 Long-term deferred tax, asset, net .......................................................................................... 6,651 Other assets, net ...................................................................................................................... Total assets ................................................................................................................. $ 331,510 Current liabilities: LIABILITIES AND EQUITY 16,371 44,855 74,875 16,509 1,922 1,302 6,057 2,132 164,023 83,429 54,050 828 1,501 $ 303,831 Accounts payable ............................................................................................................. $ 47,796 $ Billings in excess of costs and estimated earnings on uncompleted contracts ................. Current maturities of long-term debt ............................................................................... Income taxes payable ....................................................................................................... Accrued compensation ..................................................................................................... Current obligation for noncontrolling owners’ interest in subsidiaries and joint 18,918 73 -- 4,909 ventures ....................................................................................................................... Other current liabilities .................................................................................................... Total current liabilities ............................................................................................... 2,887 2,691 77,274 Long-term liabilities: Long-term debt, net of current maturities ........................................................................ Other long-term liabilities ................................................................................................ Total long-term liabilities ........................................................................................... 24,201 2,728 26,929 34,428 18,583 573 2,013 5,329 -- 8,359 69,285 263 2,597 2,860 Commitments and contingencies (Note 12) Obligations for noncontrolling owners’ interests in subsidiaries and joint ventures .............. Equity: 14,721 16,848 Sterling stockholders’ equity: Preferred stock, par value $0.01 per share; 1,000,000 shares authorized, none issued .... Common stock, par value $0.01 per share; 19,000,000 shares authorized, -- -- 16,495,216 and 16,321,116 shares issued ..................................................................... 163 165 196,143 Additional paid in capital ................................................................................................. 197,067 16,509 12,220 Retained earnings ............................................................................................................ 496 696 Accumulated other comprehensive income ..................................................................... 213,311 Total Sterling common stockholders’ equity .............................................................. 210,148 1,527 2,438 214,838 Total equity ................................................................................................................. 212,586 Total liabilities and equity .......................................................................................... $ 331,510 $ 303,831 Noncontrolling interests ....................................................................................................... The accompanying notes are an integral part of these consolidated financial statements. F3 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES CONSOLIDATED STATEMENTS OF OPERATIONS For the years ended December 31, 2012, 2011 and 2010 (Amounts in thousands, except per share data) Revenues .................................................................................................. $ Cost of revenues ....................................................................................... Gross profit ......................................................................................... General and administrative expenses ....................................................... Direct costs of acquisitions ....................................................................... Provision for loss on lawsuit .................................................................... Goodwill impairment ............................................................................... Other operating income (expense), net .................................................... Operating income (loss) ...................................................................... Gain (loss) on sale of securities and other ................................................ Interest income ......................................................................................... Interest expense ........................................................................................ Income (loss) before income taxes and earnings attributable to noncontrolling interests ........................................................................ Income tax benefit (expense) .................................................................... Net income (loss) ................................................................................ Noncontrolling owners’ interests in earnings of subsidiaries and joint 2012 630,507 (583,035) 47,472 (35,187) (202) (309) -- 3,205 14,979 1,797 1,301 (944) 17,133 579 17,712 ventures ................................................................................................. Net income (loss) attributable to Sterling common stockholders ............. $ (18,009) (297) Net income (loss) per share attributable to Sterling common stockholders: Basic ................................................................................................... $ Diluted ................................................................................................ $ (0.26) (0.26) Weighted average number of common shares outstanding used in computing per share amounts: 2011 501,156 (461,319) 39,837 (24,785) (456) (220) (67,000) 390 (52,234) 94 1,655 (1,231) (51,716) 17,012 (34,704) $ 2010 459,893 (397,188) 62,705 (24,895) -- -- -- (1,900) 35,910 (38) 1,809 (1,187) 36,494 (10,270) 26,224 (1,196) (35,900) $ (7,137) 19,087 (2.24) (2.24) $ $ 1.15 1.13 $ $ $ $ Basic .................................................................................................. 16,420,886 Diluted ................................................................................................ 16,420,886 16,395,739 16,395,739 16,194,708 16,563,169 The accompanying notes are an integral part of these consolidated financial statements. F4 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS) For the years ended December 31, 2012, 2011 and 2010 (Amounts in thousands) (297) $ (35,900) $ 19,087 Net income (loss) attributable to Sterling common stockholders ...............................$ -- 1,068 Net income attributable to noncontrolling interest included in equity........................ Net income attributable to noncontrolling interest included in liabilities ................... 16,941 7,137 Add /(deduct) other comprehensive income, net of tax: 261 935 2012 2011 2010 Realized (gain) / loss from available-for-sale securities...................................... Change in unrealized holding gain (loss) on available-for-sale securities .......... Realized loss from settlement of derivatives ....................................................... Change in the effective portion of unrealized loss in fair market value of derivatives ........................................................................................................ 107 Comprehensive income (loss) ....................................................................................$ 17,912 (510) 560 43 (1) 779 72 25 (404) -- (217) -- $ (34,071) $ 25,845 The accompanying notes are an integral part of these consolidated financial statements. F5 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES CONSOLIDATED STATEMENT OF STOCKHOLDERS’ EQUITY For the years ended December 31, 2012, 2011 and 2010 (Amounts in thousands) STERLING CONSTRUCTION COMPANY, INC. STOCKHOLDERS Accu- mulated Other Compre- hensive Income (Loss) Addi- tional Paid in Retained Capital Earnings -- $ 197,898 $ 32,466 $ -- -- -- -- 19,087 -- Common Stock Shares Amount 160 -- -- Treasury Stock Shares Amount -- $ -- -- Noncon- trolling Interests -- -- -- $ 242 -- (379) -- -- 36 350 Balance at January 1, 2010 ............16,082 $ Net income ................................... -- Other comprehensive loss ............ -- Stock issued upon option and warrant exercises ....................... Excess tax benefits from exercise of stock options ............ Issuance and amortization of restricted stock ........................... Stock-based compensation expense ...................................... Revaluation of noncontrolling interest RHB put/call liability .... -- -- -- (289 ) -- Balance at December 31, 2010 ......16,468 Net loss ........................................ Other comprehensive income ...... Purchases of treasury shares ........ Cancellation of treasury shares .... Stock issued upon option and warrant exercises ....................... Excess tax benefits from exercise of stock options ............ Issuance and amortization of restricted stock ........................... Stock-based compensation expense ...................................... Revaluation of noncontrolling interest RLW put/call liability.... Tax benefit related to the exercise of RHB’s put/call liability ....................................... Equity attributable to noncontrolling interest in acquired companies.................... 95 47 -- -- -- -- -- -- -- Balance at December 31, 2011 ......16,321 Net income (loss) ......................... Other comprehensive income ...... Stock issued upon option and warrant exercises ....................... Tax impact from exercise of stock options .............................. Issuance and amortization of restricted stock ........................... Revaluation of noncontrolling interest liabilities and other, net of tax .......................................... Distribution to owners ................. 150 24 -- -- -- 3 -- 1 -- -- 164 -- -- -- (2) 1 -- -- -- -- -- -- 163 -- -- -- -- 2 -- -- -- -- (3) -- -- -- -- -- 1,048 -- 473 121 -- -- -- -- -- -- -- -- -- (3) -- -- (286) 289 -- -- -- -- (3,592) 3,592 (691) 198,849 -- -- -- (3,422) -- 51,553 (35,900) -- -- (168) -- (137) -- 633 -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- -- 155 58 473 30 -- -- -- -- -- (1,268) -- 2,292 -- -- 196,143 16,509 -- -- 66 (79) 694 (297) -- -- -- -- 243 (3,992) -- -- -- -- -- -- -- -- -- 496 -- 200 -- -- -- -- -- Total $ 230,766 19,087 (379) 1,051 -- 474 121 (691) 250,429 (35,639) 633 (3,592) -- 156 58 473 30 (1,268) 2,292 1,266 214,838 771 200 66 (79) 696 -- -- -- -- -- -- 261 -- -- -- -- -- -- -- -- -- 1,266 1,527 1,068 -- -- -- -- (40) (117) $ 2,438 (3,789) (117) $ 212,586 Balance at December 31, 2012 ......16,495 $ 165 -- $ -- $ 197,067 $ 12,220 $ 696 The accompanying notes are an integral part of these consolidated financial statements. F6 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES CONSOLIDATED STATEMENTS OF CASH FLOWS For the years ended December 31, 2012, 2011 and 2010 (Amounts in thousands) Cash flows from operating activities: Net income (loss) attributable to Sterling common stockholders ..................................$ Plus: Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures . Net income (loss) .......................................................................................................... Adjustments to reconcile net income (loss) to net cash provided by operating activities: 2012 2011 2010 (297) $ (35,900) $ 18,009 17,712 1,196 (34,704) 19,087 7,137 26,224 Goodwill impairment ............................................................................................. Depreciation and amortization ............................................................................... (Gain) loss on disposal of property and equipment ............................................... Deferred tax expense (benefit) ............................................................................... Interest expense accreted on noncontrolling interests ............................................ Stock-based compensation expense ....................................................................... Loss (gain) on sale of securities and other ............................................................. Tax expense (benefits) from exercise of stock options and restricted stock .......... -- 18,997 (3,184) (1,167) 993 694 (918) 79 67,000 17,322 (390) (18,651) 881 503 (3) (58) -- 15,770 1,900 3,860 1,169 595 38 -- Other changes in operating assets and liabilities: (Increase) decrease in contracts receivable ............................................................ (Increase) decrease in costs and estimated earnings in excess of billings on uncompleted contracts ....................................................................................... (Increase) decrease in receivables from and equity in construction joint ventures (Increase) decrease in other current assets ............................................................. Increase (decrease) in accounts payables ............................................................... Increase (decrease) in billings in excess of costs and estimated earnings on uncompleted contracts ....................................................................................... Increase (decrease) in accrued compensation and other liabilities ......................... Net cash provided by operating activities ..................................................................... Cash flows from investing activities: Acquisition of noncontrolling interests .................................................................. Net assets of acquired companies, net of cash acquired ........................................ Additions to property and equipment .................................................................... Proceeds from sale of property and equipment ...................................................... Purchases of short-term securities, available for sale ............................................ Sales of short-term securities, available for sale .................................................... Net cash used in investing activities .............................................................................. Cash flows from financing activities: Cumulative daily drawdowns – Credit Facility ..................................................... Cumulative daily repayments – Credit Facility ..................................................... Distributions to noncontrolling interest owners ..................................................... Purchases of treasury stock .................................................................................... Issuance of common stock pursuant to warrants and options exercised ................ Tax benefits from exercise of stock options .......................................................... Other ...................................................................................................................... Net cash provided by (used in) financing activities ...................................................... Net decrease in cash and cash equivalents .................................................................... Cash and cash equivalents at beginning of period ......................................................... Cash and cash equivalents at end of period ...................................................................$ Supplemental disclosures of cash flow information: 4,060 1,933 9,982 (4,083) (4,948) (9,234) 7,730 335 (2,277) 24,789 (23,144) -- (37,359) 12,464 (30,154) 26,661 (51,532) 75,012 (51,000) (10,185) -- 68 (79) (302) 13,514 (13,229) 16,371 3,142 $ (5,921) 687 (538) (7,942) (539) 1,408 20,988 (8,205) (3,911) (23,989) 1,296 (109,312) 101,415 (42,706) (4,085) (4,403) 2,284 1,355 (13,325) 5,709 47,073 -- -- (13,409) 1,607 (137,547) 140,493 (8,856) 18,500 (18,500) (7,809) (3,592) 156 58 (165) (11,352) (33,070) 49,441 16,371 $ 57,700 (97,700) (4,160) -- 1,051 -- (73) (43,182) (4,965) 54,406 49,441 Cash paid during the period for interest .................................................................$ Cash paid during the period for income taxes ........................................................$ 88 $ 2,990 $ 299 $ 1,444 $ 44 3,740 Non-cash items: Reclassification of amounts payable to noncontrolling interest owner .................. $ Tax benefit related to the exercise of RHB’s liability ............................................$ Net liabilities assumed in connection with acquisitions ........................................$ Revaluation of noncontrolling interest – RLW and RHB’s put/call liability ........$ Issuance of noncontrolling interest in RHB in exchange for net assets of -- $ -- $ -- $ 3,992 $ 1,054 $ 2,292 $ 1,961 $ (1,268) $ acquired companies ............................................................................................$ Goodwill adjustments ............................................................................................$ 9,767 $ 410 $ -- -- The accompanying notes are an integral part of these consolidated financial statements. -- -- -- -- -- -- F7 STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES NOTES TO CONSOLIDATED FINANCIAL STATEMENTS 1. Summary of Business and Significant Accounting Policies Basis of Presentation Sterling Construction Company, Inc. (“Sterling” or “the Company”), a Delaware corporation, is a leading heavy civil construction company that specializes in the building and reconstruction of transportation and water infrastructure projects in Texas, Utah, Nevada, Arizona, California and other states in which there are construction opportunities. Our transportation infrastructure projects include highways, roads, bridges and light rail, and our water infrastructure projects include water, wastewater and storm drainage systems. We perform the majority of the work required by our contracts with our own crews and equipment. Sterling owns equity interests in the following subsidiaries: Texas Sterling Construction Co. (“TSC”); Road and Highway Builders, LLC (“RHB”); Road and Highway Builders, Inc. (“RHB Inc”); Road and Highway Builders of California, Inc. (“RHBCa”); Ralph L. Wadsworth Construction Company, LLC (“RLW”) and Ralph L. Wadsworth Construction Company, LP (“RLWLP”); J. Banicki Construction, Inc.(“JBC”); and Myers & Sons Construction, L.P. (“Myers”). TSC, RHB, RHB Ca, RLW, JBC and Myers perform construction contracts, and RHB Inc produces aggregates from a leased quarry, primarily for use by RHB. The accompanying consolidated financial statements include the accounts of subsidiaries and construction joint ventures in which the Company has a greater than 50% ownership interest or otherwise controls such entities, and all significant intercompany accounts and transactions have been eliminated in consolidation. For all years presented, the Company had no subsidiaries where its ownership interests were less than 50%. Under accounting principles generally accepted in the United States (“GAAP”), the Company must determine whether each entity, including joint ventures in which it participates, is a variable interest entity. This determination focuses on identifying which owner or joint venture partner, if any, has the power to direct the activities of the entity and the obligation to absorb losses of the entity or the right to receive benefits from the entity disproportionate to its interest in the entity, which could have the effect of requiring us to consolidate the entity in which we have a non- majority variable interest. We determined that Myers is a variable interest entity. As discussed further in Note 3, the Company determined that it exercises primary control over activities of the partnership and it is exposed to more than 50% of potential losses from the partnership. Therefore, the Company consolidates this partnership in the consolidated financial statements and includes the other partners’ interests in the equity and net income of the partnership in the balance sheet line item “Noncontrolling interests” in “Equity” and the statement of operations line item “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures,” respectively. Where the Company is a noncontrolling joint venture partner, its share of the operations of such construction joint venture is accounted for on a pro rata basis in the consolidated statements of operations and as a single line item (“Receivables from and equity in construction joint ventures”) in the consolidated balance sheets. See Note 6 for further information regarding the Company’s construction joint ventures, including those where the Company does not have a controlling ownership interest. Significant Accounting Policies Use of Estimates The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities, the disclosure of contingent assets and liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Certain of the Company’s accounting policies require higher degrees of judgment than others in their application. These include the recognition of revenue and earnings from construction contracts under the percentage-of-completion method, the valuation of long-term assets (including goodwill), and income taxes. Management continually evaluates all of its estimates and judgments based on available information and experience; however, actual amounts could differ from those estimates. Construction Revenue Recognition The Company is a general contractor which engages in various types of heavy civil construction projects principally for public (government) owners. Credit risk is minimal with public owners since the Company ascertains that funds have been appropriated by the governmental project owner prior to commencing work on such projects. While most public contracts are subject to termination at the election of the government entity, in the event of termination the Company is entitled to receive the contract price for completed work and reimbursement of F8 termination-related costs. Credit risk with private owners is minimized because of statutory mechanics liens, which give the Company high priority in the event of lien foreclosures following financial difficulties of private owners. Revenues are recognized on the percentage-of-completion method, measured by the ratio of costs incurred up to a given date to estimated total costs for each contract. Our contracts generally take 12 to 36 months to complete. Contract costs include all direct material, labor, subcontract and other costs and those indirect costs related to contract performance, such as indirect salaries and wages, equipment repairs and depreciation, insurance and payroll taxes. Administrative and general expenses are charged to expense as incurred. Provisions for estimated losses on uncompleted contracts are made in the period in which such losses are determined. Changes in job performance, job conditions and estimated profitability, including those changes arising from contract penalty provisions and final contract settlements may result in revisions to costs and income and are recognized in the period in which the revisions are determined. Changes in estimated revenues and gross margin during the year ended December 31, 2012 resulted in a net charge of $4.9 million included in operating income and a $5.3 million after-tax charge, or $0.32 per diluted share attributable to Sterling common stockholders, included in net loss attributable to Sterling common stockholders. Changes in estimated revenues and gross margin during the year ended December 31, 2011 resulted in a net charge of $11.8 million included in the operating loss and $7.6 million after-tax charge, or $0.46 per diluted share attributable to Sterling common stockholders, included in net income attributable to Sterling common stockholders. An amount attributable to contract claims is included in revenues when realization is probable and the amount can be reasonably estimated. Costs and estimated earnings in excess of billings included $0 and $2.5 million at December 31, 2012 and 2011, respectively, for contract claims not approved by the customer (which includes out-of-scope work, potential or actual disputes, and claims). The Company generally provides a one to two- year warranty for workmanship under its contracts. Warranty claims historically have been insignificant. The asset, “Costs and estimated earnings in excess of billings on uncompleted contracts” represents revenues recognized in excess of amounts billed on these contracts. The liability “Billings in excess of costs and estimated earnings on uncompleted contracts” represents billings in excess of revenues recognized on these contracts. Financial Instruments The fair value of financial instruments is the amount at which the instrument could be exchanged in a current transaction between willing parties. The Company’s financial instruments are cash and cash equivalents, short-term investments, short-term and long-term contracts receivable, derivatives, accounts payable, mortgage payable, a credit facility with Comerica Bank (“Credit Facility”), demand notes payable, the put related to certain noncontrolling owners’ interests in subsidiaries and an earn-out liability related to the acquisition of J. Banicki Construction, Inc. (“JBC”). The recorded values of cash and cash equivalents, short-term investments, short-term contracts receivable and accounts payable approximate their fair values based on their short-term nature. The recorded value of long-term contracts receivable is based on the amount of future cash flows discounted using the creditor’s borrowing rate and such recorded value approximates fair value. The recorded value of the Credit Facility debt approximates its fair value, as interest approximates market rates. See Note 9 regarding the fair value of derivatives and Note 2 regarding the fair value of the put and the earn-out liability. We had one mortgage outstanding at December 31, 2012 and December 31, 2011 with a remaining balance of $262,000 and $336,000, respectively. The mortgage was accruing interest at 3.50% at both December 31, 2012 and December 31, 2011 and contains pre-payment penalties. At December 31, 2012 and December 31, 2011 the fair value of the mortgage approximated its book value. To determine the fair value of the mortgage, the amount of future cash flows was discounted using the Company’s borrowing rate on its Credit Facility. The recorded value of the demand notes payable approximates the fair value as the interest rate approximates market rates and as the notes are due upon demand (i.e., they are short-term in nature). See Note 10 for further information regarding the demand notes payable which was paid during the 2012 third quarter. The Company does not have any off-balance sheet financial instruments other than operating leases (see Note 13). Contracts Receivable Contracts receivable are generally based on amounts billed to the customer. At December 31, 2012 and 2011, contracts receivable included $18.1 million and $22.6 million of retainage, respectively, discussed below, which is being withheld by customers until completion of the contracts, and at December 31, 2012, there were no unbilled receivables on contracts completed or substantially complete at that date. All other contracts receivable include only balances approved for payment by the customer. Many of the contracts under which the Company performs work contain retainage provisions. Retainage refers to that portion of billings made by the Company but held for payment by the customer pending satisfactory completion of the project. Unless reserved, the Company assumes that all amounts retained by customers under such provisions are fully collectible. Retainage on active contracts is classified as a current asset regardless of the term of the contract and is generally collected within one year of the completion of a contract. F9 There are certain contracts that are completed in advance of full payment. When the receivable will not be collected within our normal operating cycle, we consider it a long-term contract receivable and is recorded in “Other assets, net” in our balance sheet. At December, 2012 and 2011 there was $4.6 million and $0 recorded, respectively. We consider the credit quality of the borrower to assess the appropriate discount rate to apply and continuously monitor the borrower’s credit quality. Contracts receivable are written off based on individual credit evaluation and specific circumstances of the customer, when such treatment is warranted. However, based upon a review of outstanding contracts receivable, historical collection information and existing economic conditions, management has determined that all contracts receivable at December 31, 2012 and 2011 are fully collectible, and, accordingly, no allowance for doubtful accounts against contracts receivable is necessary. Inventories The Company’s inventories are stated at the lower of cost or market as determined by the average cost method. Inventories at December 31, 2012 and 2011 consist primarily of concrete, aggregate and millings which are expected to be utilized on construction projects in the future. The cost of inventory includes labor, trucking and other equipment costs. Property and Equipment Property and equipment are stated at cost. Depreciation and amortization are computed using the straight-line method. The estimated useful lives used for computing depreciation and amortizations are as follows: Buildings ................................. 39 years Construction equipment .......... 5-15 years Land improvements ................. 5-15 years Office furniture and fixtures .... 3-10 years 5 years Transportation equipment ........ Depreciation expense was $19.0 million, $16.9 million, and $15.5 million in 2012, 2011 and 2010, respectively. Equipment under Capital Leases The Company’s policy is to account for capital leases, which transfer substantially all the benefits and risks incident to the ownership of the leased property to the Company, as the acquisition of an asset and the incurrence of an obligation. Under this method of accounting, the recorded value of the leased asset is amortized principally using the straight-line method over its estimated useful life and the obligation, including interest thereon, is reduced through payments over the life of the lease. Depreciation expense on equipment subject to capital leases and the related accumulated depreciation is included with that of owned equipment. The Company had no capital leases during the years ended December 31, 2012, 2011 and 2010. Deferred Loan Costs Deferred loan costs represent loan origination fees paid to the lender and related professional fees such as legal fees related to drafting of loan agreements. These fees are amortized over the term of the loan. Unamortized costs are $289,000 and $321,000 at December 31, 2012 and 2011, respectively, and are primarily attributable to the Credit Facility (see Note 10). Loan cost amortization expense for fiscal years 2012, 2011 and 2010 was $32,000, $326,000 and $304,000 respectively. Goodwill and Intangibles Goodwill represents the excess of the cost of companies acquired over the fair value of their net assets at the dates of acquisition. GAAP requires that: (1) goodwill and indefinite lived intangible assets not be amortized, (2) goodwill is to be tested for impairment at least annually at the reporting unit level and (3) intangible assets deemed to have an indefinite life are to be tested for impairment at least annually by comparing the fair value of these assets with their recorded amounts. Refer to Note 8 for our disclosure regarding goodwill impairment. Evaluating Impairment of Long-Lived Assets When events or changes in circumstances indicate that long-lived assets may be impaired, an evaluation is performed. The evaluation would be based on estimated undiscounted cash flow associated with the assets as compared to the asset’s carrying amount to determine if a write-down to fair value is required. As described in Note 8, the testing under step one of the goodwill impairment test in 2011 indicated the adjusted fair value of the Company’s stock was less than its book value. Management then determined the fair value of its assets and liabilities, and found that no long-lived assets were impaired except for goodwill in 2011. For 2012, management believes that there are no events or changes in circumstances have indicated that long-lived assets may be impaired. F10 Segment reporting We operate in one segment and have only one reportable segment and one reporting unit component, heavy civil construction. In making this determination, we considered that each project has similar characteristics, includes similar services, has similar types of customers and is subject to similar economic and regulatory environments. We organize, evaluate and manage our financial information around each project when making operating decisions and assessing our overall performance. Even if our local offices were to be considered separate components of our heavy civil construction operating segment, those components could be aggregated into a single reporting unit for purposes of testing goodwill for impairment under Accounting Standards Codification 280 and EITF D-101 because our local offices all have similar economic characteristics and are similar in all of the following areas: The nature of the products and services — each of our local offices perform similar construction projects — they build, reconstruct and repair roads, highways, bridges, light rail and water, waste water and storm drainage systems. The nature of the production processes — our heavy civil construction services rendered in the construction process for each of our construction projects performed by each local office is the same — they excavate dirt, remove existing pavement and pipe, lay aggregate or concrete pavement, pipe and rail and build bridges and similar large structures in order to complete our projects. The type or class of customer for products and services — substantially all of our customers are federal and state departments of transportation, cities, counties, and regional water, rail and toll-road authorities. A substantial portion of the funding for the state departments of transportation to finance the projects we construct is furnished by the federal government. The methods used to distribute products or provide services — the heavy civil construction services rendered on our projects are performed primarily with our own field work crews (laborers, equipment operators and supervisors) and equipment (backhoes, loaders, dozers, graders, cranes, pug mills, crushers, and concrete and asphalt plants). The nature of the regulatory environment — we perform substantially all of our projects for federal, state and municipal governmental agencies, and all of the projects that we perform are subject to substantially similar regulation under U.S. and state department of transportation rules, including prevailing wage and hour laws; codes established by the federal government and municipalities regarding water and waste water systems installation; and laws and regulations relating to workplace safety and worker health of the U.S. Occupational Safety and Health Administration and to the employment of immigrants of the U.S. Department of Homeland Security. While profit margin objectives included in contract bids have some variability from contract to contract, our profit margin objectives are not differentiated by our chief operating decision maker or our office management based on local office location. Instead, the projects undertaken by each local office are primarily competitively-bid, fixed unit or negotiated lump sum price contracts, all of which are bid based on achieving gross margin objectives that reflect the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the makeup and level of our existing backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, anticipated start and completion dates, construction risks, penalties or incentives and general economic conditions. Federal and State Income Taxes We determine deferred income tax assets and liabilities using the balance sheet method. Under this method, the net deferred tax asset or liability is determined based on the tax effects of the temporary differences between the book and tax bases of the various balance sheet assets and liabilities and gives current recognition to changes in tax rates and laws. Valuation allowances are established when necessary to reduce deferred tax assets to the amount expected to be realized. We recognize the financial statement benefit of a tax position only after determining that the relevant tax authority would more likely than not sustain the position following an audit. For tax positions meeting the more-likely-than-not threshold, the amount recognized in the financial statements is the largest benefit that has a greater than 50 percent likelihood of being realized upon ultimate settlement with the relevant tax authority. Stock-Based Compensation The Company’s stock-based incentive plan is administered by the Compensation Committee of the Board of Directors. The Company’s policy is to use the closing price of the common stock on the date of the meeting at which a stock option award is approved for the option’s per-share exercise price. The term of the grants under the plans do not exceed 10 years. Stock options generally vest over a three to five year period, and the fair value of the stock option is recognized on a straight-line basis over the vesting period of the option. See Note 14 for further information regarding the stock-based incentive plans. F11 Interest Costs Approximately $2,000 and $6,000 of interest related to the construction of maintenance facilities and an office building was capitalized as part of construction costs during 2011 and 2010, respectively, no interest was capitalized in 2012. Net Income (Loss) Per Share Attributable to Sterling Common Stockholders Basic net income (loss) per share attributable to Sterling common stockholders is computed by dividing net income (loss) attributable to Sterling common stockholders by the weighted average number of common shares outstanding during the period. Diluted net income (loss) per common share attributable to Sterling common stockholders is the same as basic net income (loss) per share attributable to Sterling common stockholders but assumes the exercise of any convertible subordinated debt securities and includes dilutive stock options and warrants using the treasury stock method. The following table reconciles the numerators and denominators of the basic and diluted per common share computations for net income (loss) attributable to Sterling common stockholders for 2012, 2011 and 2010 (in thousands, except per share data): Years Ended December 31, 2011 2012 2010 Numerator: Net income (loss) attributable to Sterling common stockholders ............... $ Revaluation of noncontrolling interest put/call liability reflected in (297) $ (35,900) $ 19,087 additional paid in capital or retained earnings, net of tax ...................... $ (3,992) (4,289) $ (824) (36,724) $ (449) 18,638 Denominator: Weighted average common shares outstanding — basic ........................... Shares for dilutive stock options and warrants ........................................... Weighted average common shares outstanding and assumed 16,421 -- 16,396 -- 16,195 368 conversions— diluted ........................................................................... 16,421 16,396 16,563 Basic net income (loss) per share attributable to Sterling common stockholders ................................................................................................ $ (0.26) $ (2.24) $ 1.15 Diluted net income (loss) per share attributable to Sterling common stockholders ................................................................................................ $ (0.26) $ (2.24) $ 1.13 Options outstanding but considered antidilutive as the option exercise price exceeded the average share market price were: zero in 2012, 53,900 in 2011, and 95,107 in 2010. In addition, 109,424 shares and 88,426 shares for stock options and warrants were excluded from the diluted weighted average common shares outstanding in 2012 and 2011, respectively, as the Company incurred a loss in these years and the impact of such shares would have been antidilutive. Recent Accounting Pronouncements In July 2012, the FASB amended authoritative guidance associated with indefinite-lived intangible assets. This amended guidance states that an entity would not be required to calculate the fair value of an indefinite-lived intangible asset unless the entity determines, based on a qualitative assessment, that it is not more likely than not that the indefinite-lived intangible asset is impaired. The amendments to this authoritative guidance become effective for the Company after September 15, 2012. The Company does not currently have indefinite-lived intangible assets, other than goodwill; therefore, this guidance did not have a material impact on our consolidated financial statements. In May 2011, the FASB amended authoritative guidance associated with fair value measurements. This amended guidance defines certain requirements for measuring fair value and for disclosing information about fair value measurement in accordance with GAAP. The amendments to authoritative guidance associated with fair value measurements were effective for the Company on January 1, 2012 and have been applied prospectively. The adoption of this guidance did not have a material impact on our consolidated financial statements. Reclassifications Balances related to accrued job costs which had been included in “Other current liabilities” in the prior year balance sheet have been reclassified to “Accounts payable” to conform to current year presentation. F12 2. Acquisitions and Subsidiaries and Joint Ventures with Noncontrolling Owners’ Interests In January 2012, RHB, a wholly owned subsidiary, assumed six construction contracts with $25.0 million of unearned revenues from Aggregate Industries―SWR, Inc. (“AI”), an unrelated third party. In addition, Aggregate South West Holdings, LLC (“ASWH”) and RHB Properties, LLC (“RHBP”), newly formed entities owned by Richard Buenting, the President and Chief Executive Officer of RHB, acquired construction related machinery and equipment and land with quarries from AI. AI entered into a two-year non-compete agreement with respect to Utah, Idaho and Montana as well as certain areas of Nevada. On April 27, 2012, RHB merged with ASWH and acquired RHBP. In exchange, RHB granted Mr. Buenting a 50% member interest in RHB. These transactions allowed RHB to expand its operations in Nevada. The Company also agreed with Mr. Buenting to amend and restate the operating agreement for RHB. The amended agreement provides that the Company is the Manager of RHB and retains full, exclusive and complete power, authority and discretion to manage, supervise, operate and control RHB; therefore, the Company consolidates RHB with its other subsidiaries. The Company also entered into a buy/sell and management agreement with Mr. Buenting. Under this agreement, the Company or Mr. Buenting may annually elect to make offers to buy the other owner’s 50% interest in RHB and sell their 50% interest in RHB at a price which they specify. Upon receipt of the offers, the other owner must elect either to sell their interest or purchase the interest from the owner making the offers. The agreement also requires that the Company acquire Mr. Buenting’s interest in the event of his termination without cause, death, or disability. To the extent that the redemption value under the buy/sell and management agreement exceeds the initial valuation of Mr. Buenting’s noncontrolling interest, the Company shall record an adjustment to retained earnings. In 2012, a pre-tax adjustment of $2.5 million was recorded. Under the agreement, the Company will provide RHB with access to a $5 million line of credit. These transactions were accounted for as a business combination. In December 2012, the Company finalized its valuation of the assets acquired, the membership interest granted and the tax related impact of the transaction. The purchase price for the transaction was $9.8 million for the assets acquired net of a contract liability. In addition, the Company recorded a credit of $233,000 to “Additional paid in capital” resulting from the excess of the post-merger member capital over the Company’s book value of the 50% investment in RHB issued to Mr. Buenting. As a result of the merger, an additional difference between the Company’s tax basis related to RHB and its book basis was created. Accordingly, the Company recorded an additional deferred tax liability of $360,000 with an offset to goodwill. Revenues and earnings related to the contracts assumed and the acquired companies for 2012 were $26.1 million and $152,000, respectively. In connection with this transaction, AI did not agree to provide us with historical information related to the earnings from the acquired operations except for information related to the specific contracts being assumed. Furthermore, we determined that such information was not needed in order to evaluate the transaction based on our knowledge of the assets acquired and the Nevada road and highway construction market. Therefore, we are not able to present pro forma financial information as if the transactions had occurred on January 1, 2011. In connection with the August 1, 2011, acquisition of J. Banicki Construction, Inc. (“JBC”) by 80% owned Ralph L. Wadsworth Construction Company, LLC (“RLW”), RLW agreed to additional purchase price payments of up to $5 million to be paid over a five-year period. The additional purchase price is in the form of an earn-out which is classified as a Level 3 fair value measurement. In making this valuation, the unobservable input consisted of forecasted earnings before interest, taxes and depreciation and amortization (“EBITDA”) for the periods after the period being reported on through July 31, 2016. The additional purchase price is calculated generally as 50% of the amount by which earnings before interest, taxes, depreciation and amortization (“EBITDA”) exceeds $2 million for each of the calendar years 2011 through 2015 and $1.2 million for the seven months ended July 31, 2016. The yearly excess forecasted EBITDA in our calculation ranged from 0% to 205% of the minimum EBITDA threshold for the years 2012 through 2016. The discounted present value of the additional purchase price was estimated to be $2.4 million as of August 1, 2011, the acquisition date, and $2.3 million as of December 31, 2012. The undiscounted earn-out liability as of December 31, 2012 is estimated at $2.4 million and could increase by $2.6 million if EBITDA during the earn-out period increases $5.2 million or more and could decrease by the full amount of the liability if EBITDA does not exceed the minimum threshold in any of the periods during the earn-out period. Any significant increase or decrease in actual EBITDA compared to the forecasted amounts would result in a significantly higher or lower fair value measurement of the additional purchase price. This liability is included in other long-term liabilities in the accompanying consolidated balance sheets. F13 The following table summarizes the initial allocation of the purchase price for JBC (in thousands): Assets acquired and liabilities assumed: Current assets, including cash of $4,662 ............................................................ $ 8,839 Current liabilities ................................................................................................ (5,708) Working capital acquired .................................................................................... 3,131 Property and equipment ...................................................................................... 2,018 Other ................................................................................................................... 9 Total tangible net assets acquired at fair value .......................................... 5,158 Goodwill ............................................................................................................. 4,803 Total consideration .................................................................................... 9,961 Fair value of earn-out ............................................................................................... (2,370) Cash paid, net of $409 receivable from seller .......................................................... $ 7,591 The purchase price allocation has been finalized, and our analysis of the assets acquired indicates that there are no material separately identifiable intangible assets. The goodwill attributable to the acquisition is deductible for tax purposes over 15 years. Acquisition related costs of $328,000 are included in direct costs of acquisitions in the Company’s consolidated statements of operations for the twelve months ended December 31, 2011. The fair value of the financial assets acquired includes receivables with a fair value of $3.8 million, which are deemed fully collectible. On August 1, 2011, the Company purchased a 50% limited partner interest in Myers. Myers is a construction limited partnership located in California and was acquired in order to expand the geographic scope of the Company’s operations into California. The following table summarizes the initial allocation of the purchase price for Myers (in thousands): Assets acquired and liabilities assumed: Current assets, including cash of $654 ........................................................... $ 3,207 Current liabilities ............................................................................................ Working capital acquired ................................................................................ Property and equipment .................................................................................. Debt due to noncontrolling interest owner ...................................................... Total tangible net assets acquired at fair value ........................................ Goodwill ......................................................................................................... Total consideration .................................................................................. Fair value of noncontrolling owners’ interest in Myers ....................................... Cash paid ............................................................................................................. $ 1,227 (2,464) 743 708 (500) 951 1,502 2,453 (1,226) The fair value of the noncontrolling interests was determined based on the negotiated price at which the Company purchased its 50% interest which was based in part on expectations of future earnings. The purchase price allocation has been finalized, and our analysis of the assets acquired indicates that there are no material separately identifiable intangible assets. The goodwill attributable to the acquisition is deductible for tax purposes over 15 years. Acquisition related costs of $128,000 are included in direct costs of acquisitions in the Company’s consolidated statements of operations for the year ended December 31, 2011. The fair value of the financial assets acquired includes receivables with a fair value of $2.1 million, which are expected to be fully collectible. See Note 3 regarding the determination that Myers’ is a variable interest entity and the resulting impact on the consolidated financial statements. The following table shows the amounts of JBC’s and Myers’ revenues and earnings included in the Company’s consolidated statements of operations and cash flows for the year ended December 31, 2011, and the revenues and earnings of the combined entity had the acquisition dates been January 1, 2010 (in thousands): F14 JBC actual from 8/1/2011 – 12/31/2011 ................................................. $ Myers actual from 8/1/2011 – 12/31/2011 ............................................. Supplemental pro forma results of the Company, JBC, and Myers on a combined basis for 1/1/2010 – 12/31/2010 (unaudited) ................... Net Income (Loss) Attributable to Sterling Common Stockholders 245 170 Revenues 12,303 7,153 $ 475,906 19,596 In connection with the December 3, 2009 acquisition of RLW, the noncontrolling interest owners of RLW, who are related and also its executive management, had the right to require the Company to buy their remaining 20.0% interest in RLW in 2013, and concurrently, the Company had the right to require those owners to sell their 20.0% interest to the Company by July 2013 (the “RLW put/call”). The purchase price in each case was 20% of the product of the simple average of RLW’s EBITDA (income before interest, taxes, depreciation and amortization) for the calendar years 2010, 2011 and 2012 times a multiple of a minimum of 4 and a maximum of 4.5. The valuation of this purchase price was classified as a Level 3 fair value measurement. In making this valuation, the observable input was RLW’s EBITDA for the period from January 1, 2010 through December 31, 2012. The noncontrolling owners’ interests, including the obligation under the RLW put/call, were recorded at their estimated fair value at the date of acquisition as “Obligation for noncontrolling owners’ interests in subsidiaries and joint ventures” in the accompanying consolidated balance sheets. Annual interest was accreted for the RLW put/call obligation based on the Company’s borrowing rate under its Credit Facility plus two percent. Such accretion amounted to $993,000, $881,000, and $807,000 for the years ended December 31, 2012, 2011 and 2010, respectively, and is recorded in “Interest expense” in the accompanying consolidated statement of operations. In addition, based on the estimated average of RLW’s EBITDA for the calendar years 2010, 2011 and 2012 and the expected multiple, the estimated fair value of the RLW put/call was increased by $3.8 million and $1.3 million during the years ended December 31, 2012 and 2011, respectively, and this change, net of tax of $1.3 million and $0.5 million, respectively, has been reported as a charge to retained earnings. Under an agreement with the noncontrolling interest owners of RLW, the Company purchased their 20% interest in RLW on December 31, 2012 subject to a final determination of RLW’s EBITDA for the period from January 1, 2010 through December 31, 2012. A payment of $23.1 million was made, and the Company expects to make a final additional payment of $568,000 in March 2013. This amount as well as any undistributed earnings to the noncontrolling interest owners for 2012 is included in current liabilities under “Current obligation for noncontrolling owners’ interests in subsidiaries and joint ventures” in the accompanying consolidated balance sheets. The following table summarizes the initial allocation of the purchase price for RLW (in thousands): Assets acquired and liabilities assumed: Current assets, including cash of $3,370 ................................................. $ Current liabilities ..................................................................................... Working capital acquired ........................................................................ Property and equipment .......................................................................... Total tangible net assets acquired at fair value .............................. Goodwill ................................................................................................. Total consideration ........................................................................ Fair value of noncontrolling owners’ interests in RLW, including put ....... Cash paid .................................................................................................... $ 43,053 (31,953) 11,100 11,212 22,312 57,513 79,825 (15,965) 63,860 The goodwill attributable to the acquisition is deductible for tax purposes over 15 years. On October 31, 2007, the Company purchased a 91.67% interest in RHB. The noncontrolling interest owner of RHB had the right to put, or require the Company to buy, his remaining 8.33% interest in the subsidiary and, concurrently, the Company had the right to require that the owner sell his 8.33% interest to the Company, in 2011. On March 17, 2011, the right to put/call the RHB noncontrolling interest was extended to anytime between that date and December 31, 2012. In addition the price was increased from $7.1 million to $8.2 million which settled $1.1 million of accrued amounts due to the noncontrolling interest owner under the October 31, 2007 purchase F15 agreement. In September 2011, the noncontrolling owner exercised his right to put his remaining interest of 8.33% in RHB to the Company for $8.2 million. This transaction was completed in December 2011 under the terms of the agreement. Changes in noncontrolling interests The following table summarizes the changes in the noncontrolling owners’ interests in subsidiaries and consolidated joint ventures for the years ended December 31, 2010 through 2012 (in thousands): Balance, beginning of period ..................................................................$ 18,375 Net income attributable to noncontrolling interest included in $ 28,724 $ 23,887 Years Ended December 31, 2010 2011 2012 liabilities ............................................................................................. 16,941 1,068 993 3,797 2,473 -- -- Net income attributable to noncontrolling interest included in equity .... Accretion of interest on puts ................................................................... Change in fair value of RLW put/call..................................................... Change in fair value of RHB put/call ..................................................... Acquisition by Sterling of RHB noncontrolling interest ........................ Noncontrolling interest associated with Myers acquisition .................... Issuance of noncontrolling interest in RHB in exchange for net assets of acquired companies ........................................................................ 9,767 Distributions to noncontrolling interests owners .................................... (10,185) Acquisition by Sterling of RLW noncontrolling interest ........................ (23,144) Other ....................................................................................................... (39) Balance, end of period ............................................................................$ 20,046 935 261 881 1,268 1,054 (8,205) 1,227 7,137 -- 1,169 -- 691 -- -- -- (7,809) -- 39 -- (4,160) -- -- $ 18,375 $ 28,724 Noncontrolling owners’ interest in earnings of subsidiaries and joint ventures for the year ended December 31, 2012 shown in the accompanying consolidated statement of operations of $18.0 million includes $15.0 million attributable to the RLW noncontrolling interest owners, which is reflected in “Current obligation for noncontrolling owners’ interests in subsidiaries and joint ventures,” $1.9 million attributable to RHB noncontrolling interest owners, which is reflected in “Obligation for noncontrolling owners’ interest in subsidiaries and joint ventures” and income of $1.1 million attributable to Myers’ noncontrolling interest owners which is reflected in equity in “Noncontrolling interests” in the accompanying consolidated balance sheet. In 2012, the Company agreed to amend RLW’s operating agreement effective January 1, 2012 to provide that any goodwill impairment, including the 2011 fourth quarter goodwill impairment of the Company described in Note 8 below is not to be allocated to RLW for the purpose of calculating the distributions to be made to the RLW noncontrolling interest holders. This amendment resulted in an increase in the net income attributable to RLW’s noncontrolling interests of $6.7 million during the year ended December 31, 2012. This increase is included in “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures” in the accompanying consolidated statement of operations. This increase has a related tax impacted of $2.4 million which increased the tax benefit for the period. 3. Variable Interest Entities Under GAAP, the Company must determine whether each entity, including joint ventures in which it participates, is a variable interest entity. This determination focuses on identifying which owner or joint venture partner, if any, has the power to direct the activities of the entity and the obligation to absorb losses of the entity or the right to receive benefits from the entity disproportionate to its interest in the entity, which could have the effect of requiring us to consolidate the entity in which we have a non-majority variable interest. Where the Company has determined that it is appropriate to consolidate a variable interest entity in which it owns a 50% or less interest, the remaining owners’ interests in the equity and net income of the entity are included in the balance sheet line item: “Noncontrolling owners’ interests in subsidiaries and joint ventures.” The Company owns a 50% interest in Myers of which it is the primary beneficiary and has consolidated Myers into these financial statements. Further see Note 2 above for additional information on the acquisition of this limited partnership. The partnership agreement requires that Sterling provide a $3 million line of credit to the limited partnership. In addition the partnership is relying on the Company’s surety bonding capacity in order to bid and F16 perform large construction jobs resulting in the Company having joint and several liability for completion of such jobs, and the Company will provide management to the partnership to oversee bidding and management of larger projects. Although the Company will receive 50% of the income from the partnership, it may suffer more than 50% of any losses as a result of its obligation to provide the $3 million line of credit and its obligations under the surety bonds. Because the Company exercises primary control over activities of the partnership and it is exposed to the majority of potential losses of the partnership, the Company consolidated Myers within the Company’s financial statements from August 1, 2011, the date of acquisition. The financial information of Myers which is reflected in our consolidated balance sheets and statements of operations is as follows (in thousands): Assets: Current assets: Cash and cash equivalents ........................................................................................... $ Contracts receivable, including retainage ..................................................................... Other current assets ....................................................................................................... Total current assets .................................................................................................. Property and equipment, net ................................................................................................. Goodwill ............................................................................................................................... Total assets .............................................................................................................. $ Liabilities: Current liabilities: Accounts payable .......................................................................................................... $ Other current liabilities ................................................................................................. Total current liabilities ............................................................................................ Long-term liabilities: Other long-term liabilities ............................................................................................. Total long-term liabilities ........................................................................................ Total liabilities ................................................................................................ $ As of December 31, 2011 2012 7,164 2,866 1,214 11,244 3,041 1,501 15,786 4,627 6,283 10,910 -- -- 10,910 $ $ $ $ 1,365 2,244 419 4,028 926 1,541 6,495 1,134 2,323 3,457 -- -- 3,457 Period from August 1, 2011 (the acquisition date) to December 31, 2011 Year Ended December 31, 2012 Revenues ..................................................................................................$ Operating income ..................................................................................... Net income (loss) attributable to Sterling common stockholders ............. 84,877 $ 2,152 694 7,153 531 170 Other current liabilities shown in the table above include $500,000 in demand notes payable that are due to one of the noncontrolling interest owners in 2011 and paid in 2012. 4. Cash and Cash Equivalents and Short-term Investments The Company considers all highly liquid investments with original or remaining maturities of three months or less at the time of purchase to be cash equivalents. At December 31, 2012, approximately $2.7 million of cash and cash equivalents were fully insured by the FDIC under its standard maximum deposit insurance amount guidelines. At December 31, 2012, cash and cash equivalents included $980,000 belonging to majority-owned joint ventures that are consolidated in these financial statements which generally cannot be used for purposes outside such joint ventures. The Company includes certificates of deposit with a remaining maturity of 90 days or less at purchase in “Cash and cash equivalents.” All other short-term investments are included in “Short-term investments.” Mutual funds, government bonds and exchange traded funds are considered available-for-sale securities. Government bonds have maturity dates of 2013-2050. At December 31, 2012 and 2011, the Company had short-term investments as follows (in thousands): F17 Mutual funds ......................................................................... $ Municipal bonds ................................................................... Total securities available-for-sale ......................... $ 27,582 $ 21,629 49,211 $ Total Fair Value As of December 31, 2012 Level 1 27,582 -- 27,582 Level 2 -- $ 21,629 21,629 $ $ $ Gross Unrealized Gains (pre-tax) 337 862 1,199 $ $ Gross Unrealized Losses (pre-tax) 9 128 137 Mutual funds ......................................................................... $ Municipal bonds ................................................................... Total securities available-for-sale ......................... $ As of December 31, 2011 Total Fair Value 24,851 20,004 $ Level 1 24,851 -- 44,855 $ 24,851 Level 2 $ $ -- $ 20,004 20,004 $ Gross Unrealized Gains (pre-tax) 383 $ 617 1,000 $ Gross Unrealized Losses (pre-tax) -- 15 15 The amortized cost basis of the above securities at December 31, 2012 and 2011 was $48.1 million and $44.3 million, respectively. Municipal bond securities are the only securities held by the Company where fair value does not equal amortized cost. The amortized cost for municipal bond securities was $20.5 million and $19.4 million in 2012 and 2011, respectively. The valuation inputs for Levels 1, 2 and 3 are as follows: Level 1 Inputs - Based upon quoted prices for identical assets in active markets that the Company has the ability to access at the measurement date. Level 2 Inputs – Based upon quoted prices (other than Level 1) in active markets for similar assets, quoted prices for identical or similar assets in markets that are not active, inputs other than quoted prices that are observable for the asset such as interest rates, yield curves, volatilities and default rates and inputs that are derived principally from or corroborated by observable market data. Level 3 Inputs – Based on unobservable inputs reflecting the Company’s own assumptions about the assumptions that market participants would use in pricing the asset based on the best information available. The Company had no short-term investments valued with Level 3 inputs at either of the balance sheet dates. Gains and losses realized on short-term investment securities are included in “Gains (losses) on sale of securities and other” in the accompanying statements of operations. Unrealized gains (losses) on short-term investments are included in accumulated other comprehensive income in stockholders’ equity, net of tax, as the gains and losses may be temporary. For the year ended December 31, 2012 and 2011, total proceeds from sales of short-term investments were $26.7 million and $101.4 million, respectively, with gross realized gains of $785,000 and $390,000, respectively, and gross realized losses of $0 and $388,000, respectively. Accumulated other comprehensive income at December 31, 2012 included unrealized gains (losses) on short-term investments of $1.1 million less the associated taxes of $372,000. Upon the sale of short-term investments, the cost basis used to determine the gain or loss is based on the specific identification of the security sold. All items included in accumulated other comprehensive income are at the corporate level, and no portion is attributable to noncontrolling interests. For the years ended December 31, 2012, 2011 and 2010, the Company recorded interest income of $1.3 million, $1.7 million and $1.8 million, respectively. 5. Costs and Estimated Earnings and Billings on Uncompleted Contracts Billing practices for our contracts are governed by the contract terms of each project based on progress toward completion approved by the owner, achievement of milestones or pre-agreed schedules. Billings do not necessarily correlate with revenue recognized under the percentage-of-completion method of accounting. The current liability, “Billings in excess of costs and estimated earnings on uncompleted contracts,” represents billings in excess of revenues recognized. The current asset, “Costs and estimated earnings in excess of billings on uncompleted contracts,” represents revenues recognized in excess of amounts billed to the customer, which are usually billed during normal billing processes following achievement of contractual requirements. The two tables below set forth the costs incurred and earnings accrued on uncompleted contracts (revenues) compared with the billings on those contracts through December 31, 2012 and 2011 and reconcile the net excess billings to the amounts included in the consolidated balance sheets at those dates (in thousands). F18 As of December 31, 2011 2012 Costs incurred and estimated earnings on uncompleted contracts ................................................................................ $ 1,361,973 (1,360,299) Billings on uncompleted contracts ........................................... Excess of costs incurred and estimated earnings over billings $ 997,527 (999,601) (excess of billings over costs incurred and estimated earnings) on uncompleted contracts ...................................... $ 1,674 $ (2,074) Included in the accompanying balance sheets under the following captions: As of December 31, 2011 2012 Costs and estimated earnings in excess of billings on uncompleted contracts .......................................................... $ 20,592 $ 16,509 Billings in excess of costs and estimated earnings on uncompleted contracts ..................................................... Net amount of costs and estimated earnings on uncompleted (18,918) (18,583) contracts above (below) billings ....................................... $ 1,674 $ (2,074) Revenues recognized and billings on uncompleted contracts include cumulative amounts recognized as revenues and billings in prior years. 6. Construction Joint Ventures We participate in various construction joint venture partnerships. Generally, each construction joint venture is formed to accomplish a specific project and is jointly controlled by the joint venture partners. The joint venture agreements typically provide that our interests in any profits and assets, and our respective share in any losses and liabilities that may result from the performance of the contract are limited to our stated percentage interest in the venture. We have no significant commitments beyond completion of the contract with the customer. Our agreements with our joint venture partners provide that each venture partner will receive its share of net income and assume and pay its share of any losses resulting from a project. If one of our venture partners is unable to pay its share of losses, we would be fully liable for those losses under our contract with the project owner. Circumstances that could lead to a loss under our joint venture arrangements beyond our ownership interest include a venture partner’s inability to contribute additional funds required by the venture or additional costs that we could incur should a venture partner fail to provide the services and resources toward project completion that it committed to in the joint venture agreement and the contract with the customer. Under GAAP, the Company must determine whether each joint venture in which it participates is a variable interest entity. This determination focuses on identifying which joint venture partner, if any, has the power to direct the activities of a joint venture and the obligation to absorb losses of the joint venture or the right to receive benefits from the joint venture in excess of their ownership interests and could have the effect of requiring us to consolidate joint ventures in which we have a non-majority variable interest. Except for Myers as discussed in Note 3 above, at December 31, 2012, we had no participation in a joint venture where we had a material non-majority variable interest. Where we are a noncontrolling venture partner, we account for our share of the operations of such construction joint ventures on a pro rata basis using proportionate consolidation in our consolidated statements of operations and as a single line item (“Receivables from and equity in construction joint ventures”) in the consolidated balance sheets. Combined financial amounts of joint ventures in which the Company has a noncontrolling interest and the Company’s share of such amounts which are included in the Company’s consolidated financial statements are shown below (in thousands): F19 Total combined: Current assets ..................................................................... $ 92,102 (48,002) Less current liabilities ........................................................ Net assets ...................................................................... $ 44,100 Backlog .............................................................................. $ 213,924 $ 108,458 (86,023) $ 22,435 $ 539,844 $ As of December 31, 2012 2011 Years Ended December 31, 2011 2010 2012 Total combined: Revenues ............................................................................ $ 438,756 Income before tax ............................................................... $ 95,765 $ 440,085 $ 46,683 Sterling’s noncontrolling interest: Share of revenues ............................................................... $ 82,519 Share of income before tax ................................................ $ 12,424 $ 62,763 6,417 $ $ 302,289 $ 24,573 $ 37,684 3,018 $ As of December 31, 2012 Sterling’s noncontrolling interest in backlog ........................... $ 77,222 Sterling’s receivables from and equity in net assets of $ 127,130 2011 construction joint ventures ................................................... $ 11,005 $ 6,057 7. Property and Equipment Property and equipment are summarized as follows (in thousands): Construction equipment ............................................................................$ 130,014 19,266 Transportation equipment ......................................................................... 10,176 Buildings .................................................................................................. 1,279 Office equipment ...................................................................................... Construction in progress ........................................................................... -- 4,916 Land .......................................................................................................... 200 Water rights .............................................................................................. 165,851 (63,543) $ 102,308 Less accumulated depreciation ................................................................. As of December 31, 2011 2012 $125,222 17,963 4,729 1,077 2,544 3,026 200 154,761 (71,332) $ 83,429 At December 31, 2011, construction in progress primarily consisted of expenditures for new offices in San Antonio and Dallas, Texas, which were completed during 2012. 8. Goodwill Goodwill represents the excess of the cost of companies acquired over the fair value of their net assets at the dates of acquisition. GAAP requires that goodwill not be amortized and that goodwill is to be tested for impairment at least annually at the reporting unit level. The Company tests for goodwill impairment during the last quarter of each calendar year. The first step compares the book value of the Company’s stock (stockholders’ equity) to the adjusted fair market value of those shares. To determine the fair value of the Company’s net assets, the Company used the weighted average of the following valuation techniques: market capitalization plus control premium approach, guideline company (market) approach, and a discounted cash flow (income) approach. If the adjusted fair value of the stock is greater than the calculated book value of the stock, goodwill is deemed not to be impaired and no further testing is required. If the adjusted fair value is less than the calculated book value, additional steps of determining the fair value of net assets must be taken to determine impairment. Testing under step one in 2012 and 2010 did not indicate that the adjusted fair value of the Company’s stock was less than its book value. However, this was not the case in 2011. As a result, in 2011 the Company performed the second-step test to determine the fair value of the Company’s net assets and the amount of implied goodwill. The majority of the Company’s assets and liabilities are current in F20 nature and, therefore, approximate fair value. The Company engaged a third party to conduct an independent appraisal of its property, plant and equipment. In addition, the Company performed a fair market assessment of interest bearing debt, deferred tax assets and liabilities and other intangible assets. The results of the second-step test indicated a goodwill impairment of approximately $67.0 million which was recorded in the fourth quarter of 2011. The following table details changes in recorded goodwill (in thousands): Additional goodwill related to 2011 acquisitions ................... Goodwill impairment in 2011 ................................................ Balance at December 31, 2011 .................................................... Additional goodwill related to acquisitions ............................ Goodwill adjustments ............................................................. Balance at January 1, 2011 and 2010........................................... $ 114,745 6,305 (67,000) 54,050 360 410 Balance at December 31, 2012 .................................................... $ 54,820 9. Derivative Financial Instruments The Company enters into various fixed rate commodity swap contracts in an effort to manage its exposure to price volatility of diesel fuel. Historically, fuel prices have been volatile because of supply and demand factors, worldwide political factors and general economic conditions. The objective of the Company in executing the hedge is to mitigate the fuel price volatility that could adversely affect forecasted cash flows and earnings related to construction contracts. Swaps are designed so that the Company receives or makes payments based on a differential between fixed and variable prices for off-road ultra-low sulfur diesel (“ULSD”). The Company has designated its commodity derivative contracts as cash flow hedges designed to achieve more predictable cash flows, as well as to reduce its exposure to price volatility. While the use of derivative instruments limits the downside risk of adverse price movements, they also limit future benefits from reductions in costs as a result of favorable market price movements. All of the Company’s outstanding derivative financial instruments are recognized in the balance sheet at their fair values. All changes in the fair value of outstanding derivatives, except any ineffective portion, are recorded in accumulated other comprehensive income (loss) until earnings are impacted by the hedged transaction. Amounts in accumulated other comprehensive income (loss) are reclassified to earnings when the related hedged items affect earnings or the anticipated transactions are no longer probable. All items included in accumulated other comprehensive income (loss) are at the corporate level, and no portion is attributable to noncontrolling interests. At December 31, 2012 and 2011, pre-tax accumulated other comprehensive income (loss), excluding taxes of $2,800 and $78,000, respectively, consisted of unrecognized gains of $8,000 and $223,000, respectively, representing the unrealized change in mark-to-market value of the effective portion of the Company’s commodity contracts, designated as cash flow hedges, as of the balance sheet date. For the years ended December 31, 2012, 2011, and 2010, the Company recognized pre-tax net realized cash settlement losses on commodity contracts of $66,000, $111,000, and $0, respectively. At December 31, 2012, the Company had hedged its exposure to the variability in future cash flows from forecasted diesel fuel purchases totaling 1.2 million gallons. The monthly volumes hedged range from 10,000 gallons to 20,000 gallons over the period from January 2013 to December 2014 at fixed prices per gallon ranging from $2.79 to $3.29. The derivative instruments are recorded on the consolidated balance sheet at fair value as follows (in thousands): F21 Balance Sheet Location Derivative assets: Deposits and other current assets...................................... $ Other assets, net ................................................................ $ Derivative liabilities: Other current liabilities ..................................................... $ Other long-term liabilities ................................................ $ As of December 31, 2012 2011 7 1 8 -- -- -- $ $ $ $ -- -- -- 147 76 223 The following table summarizes the effects of commodity derivative instruments on the consolidated statements of operations and comprehensive income (in thousands): Years Ended December 31, 2011 2012 2010 Increase (decrease) in fair value of derivatives included in other comprehensive income (effective portion) ................$ 231 $ (223) $ Realized gain (loss) included in cost of revenues (effective portion) ................................................................................ (66) Increase (decrease) in fair value of derivatives included in cost of revenues (ineffective portion) .................................. -- (111) -- -- -- -- The Company’s derivative instruments contain certain credit-risk-related contingent features which apply both to the Company and to the counterparties. The counterparty to the Company’s derivative contracts is a high credit quality financial institution. Fair Value The Company’s swaps are valued based on a discounted future cash flow model. The primary input for the model is the forecasted prices for ULSD. The Company’s model is validated by the counterparty’s mark-to-market statements. The swaps are designated as Level 2 within the valuation hierarchy. Refer to Note 4 for a description of the inputs used to value the information shown above. At December 31, 2012 and 2011, the Company did not have any derivative assets or liabilities measured at fair value on a recurring basis that meet the definition of Level 1 or Level 3. 10. Line of Credit and Long-Term Debt Long-term debt consists of the following (in thousands): Credit facility...............................................................................$ Notes payable to related party ..................................................... Mortgage due monthly through June 2016 .................................. Less current maturities of long-term debt .................................... Total long-term debt ....................................................................$ As of December 31, 2012 2011 24,012 -- 262 24,274 (73) 24,201 $ $ -- 500 336 836 (573) 263 Line of Credit Facility On October 31, 2007, the Company and its subsidiaries entered into a new credit facility (“Credit Facility”) with Comerica Bank with a maturity date of October 31, 2012. In November 2011, the Credit Facility was amended to extend the maturity date to September 30, 2016. Up to $50 million in borrowings are available under the amended Credit Facility with, under certain circumstances, an optional increase of $50 million. The Credit Facility is secured by all assets of the Company, other than proceeds and other rights under our construction contracts, which are pledged to our bond surety. The Credit Facility requires the payment of a quarterly commitment fee of 0.25% per F22 annum of the unused portion of the Credit Facility. At December 31, 2012 and 2011, the Company had $24.0 million and no aggregate borrowings outstanding under the Credit Facility, respectively, and the aggregate amount of letters of credit outstanding under the Credit Facility was $1.8 million for both years and reduces availability under the Credit Facility. Availability under the Credit Facility was, therefore, $24.2 million and $48.2 million at December 31, 2012 and 2011, respectively, without violating any of the covenants discussed in the next paragraph. The Credit Facility is subject to our compliance with certain covenants, including financial covenants relating to fixed charges, leverage, tangible net worth and asset coverage. The Credit Facility contains restrictions on the Company’s ability to: Make distributions and dividends; Incur liens and encumbrances; Incur further indebtedness; Guarantee obligations; Dispose of a material portion of assets or merge with a third party; Make acquisitions; Make investments in securities. The Company was in compliance with all covenants under the Credit Facility as of December 31, 2012. The unpaid principal balance of each loan will bear interest at a variable rate equal to either Comerica’s prime rate or a rate equal to LIBOR plus 1.75%. The interest rate on funds borrowed under this revolver during the year ended December 31, 2012 was 3.25% at all times that the Company had debt outstanding under this facility. In January 2013, the Company sold approximately $27.7 million of its short-term investments in order to repay the $24.0 million of borrowings outstanding under the Credit Facility at December 31, 2012. Mortgage In 2001, TSC completed the construction of a headquarters building and financed it principally through a mortgage of $1.1 million on the land and facilities, at a floating interest rate, which at December 31, 2012 was 3.5% per annum, repayable over 15 years. The outstanding balance on this mortgage was $262,000 at December 31, 2012. Related Party Notes Payable As of December 31, 2011, Myers had $500,000 of outstanding notes payable to Clinton Charles Myers, a noncontrolling interest owner. These notes were paid in full during 2012. Maturities of Debt The Company’s long-term obligations mature in future years as follows (in thousands): Years Ending December 31, 2013 ....................... $ 2014 ....................... 2015 ....................... 2016 ....................... Thereafter ............... $ 73 73 73 24,055 -- 24,274 11. Income Taxes and Deferred Tax Asset/Liability The Company and its subsidiaries file U.S. federal and various U.S. state income tax returns. The Company’s 2007 through 2009 U.S. federal income tax returns have been examined by the I.R.S. Based on their examination, $314,000 was calculated as additional tax owed. The Company’s policy is to recognize interest related to any underpayment of taxes as interest expense, and penalties as administrative expenses. No interest or penalties have been accrued at December 31, 2012, and interest and penalties for the years ended December 31, 2011 and 2010 were not significant. The Company’s U.S. federal income tax returns for 2010 and later years are open and subject to examination by the I.R.S. Current income tax expense represents federal and state income tax paid or expected to be payable for the years shown in the statements of operations. The income tax expense (benefit) in the accompanying consolidated financial statements consists of the following (in thousands): F23 Current tax expense (benefit) ..........................................$ Deferred tax expense (benefit) ........................................ Total tax expense (benefit) ..............................................$ 588 $ (1,167) 1,639 (18,651) (579) $ (17,012) Deferred tax assets and liabilities consist of the following (in thousands): Years Ended December 31, 2011 2012 $ 2010 6,410 3,860 $ 10,270 As of December 31, 2012 Current Long Term 2011 Current Long Term Assets related to: Accrued compensation and other ...........................$ Amortization and impairment of goodwill ............ Accreted interest to put .......................................... Contingency on lawsuit .......................................... Noncontrolling interest ........................................... Revaluation of put/call liabilities Liabilities related to: Depreciation of property and equipment ................ Noncontrolling interest ........................................... Other ....................................................................... Net asset (liability).......................................................$ 1,803 -- -- -- -- -- -- -- -- 1,803 $ -- $ 13,181 939 130 915 2,194 (13,615) -- (771) 2,973 $ $ 1,302 -- -- -- -- -- -- -- -- 1,302 $ -- 15,900 587 391 -- -- (14,040) (1,720) (290) 828 $ The Company expects that the deferred tax asset will be realized and accordingly no valuation allowance is necessary. During 2012, we recorded a long-term deferred tax liability of $360,000 on depreciable property as a result of a business combination. Refer to Note 2 for a description of the business combination. The income tax provision (benefit) differs from the amount using the statutory federal income tax rate of 35% for the following reasons (amounts in thousands): Years Ended December 31, 2012 2011 2010 Amount % Amount % Amount % Tax expense (benefit) at the U.S. federal statutory rate .............................$ 5,997 35.0 % $ (18,101) 35.0 % $ 12,773 35.0 % State tax based on income, net of refunds and federal benefits ................. (58) (0.3) (573) 1.1 879 2.4 Taxes on subsidiaries’ and joint ventures’ earnings allocated to noncontrolling interests owners ........... Tax benefits of Domestic Production (5,938) (34.7) Activities Deduction ......................... (84) (0.5) (444) (202) 0.9 0.4 (2,498) (6.8) (500) (1.4) Impairment associated with goodwill that is not amortizable for tax ........... Non-taxable interest income .................... Other permanent differences .................... Income tax expense (benefit) ...................$ -- (529) 33 (579) 2,603 -- (376) (3.1) 81 0.2 (3.4)% $ (17,012) -- (5.0) (494) 0.7 110 (0.2) 32.9 % $ 10,270 -- (1.4) 0.3 28.1 % As a result of the Company’s analysis, management has determined that the Company does not have any material uncertain tax positions. 12. Commitments and Contingencies Employment Agreements The Company’s Chief Executive Officer, its Executive Vice Presidents and certain executive officers of its subsidiaries have employment agreements which provide for payments of annual salary, deferred salary, incentive compensation and certain benefits if their employment is terminated without cause. The Company has also entered into change of control agreements with certain officers providing for additional payments in the event that their employment is terminated without cause just before or within two years after a change of control of the Company. F24 Self-Insurance The Company except RLW, JBC and Myers is self-insured for employee health claims, and RLW is partially self-insured. Its policy is to accrue the estimated liability for known claims and for estimated claims that have been incurred but not reported as of each reporting date. The Company has obtained reinsurance coverage for the policy period as follows: Specific excess reinsurance coverage for medical and prescription drug claims per insured person in excess of $95,000 within a plan year. Aggregate reinsurance coverage for medical and prescription drug claims within a plan year with a maximum of $1.0 million in excess of an aggregate deductible of $2.5 million. For the years ended December 31, 2012, 2011 and 2010, the Company incurred $2.0 million, $1.2 million, and $1.1 million, respectively, in expenses related to this plan. The Company and its subsidiaries, other than RLW, JBC and Myers, are also self-insured for workers’ compensation claims up to $250,000 per occurrence, with a maximum aggregate liability of $2.9 million per year. The Company’s policy is to accrue the estimated liability for known claims and for estimated workers compensation, employee health, general liability and other claims that have been incurred but not reported as of each reporting date. At December 31, 2012 and 2011, the Company had recorded an estimated liability of $1.4 million and $1.3 million, respectively, which it believes is adequate for such claims based on its claims history and an actuarial study. The Company has a safety and training program in place to help prevent accidents and injuries and works closely with its employees and the insurance company to monitor all claims. RLW, JBC and Myers have purchased insurance to cover its workers’ compensation losses. The Company obtains bonding on construction contracts through Travelers Casualty and Surety Company of America. As is customary in the construction industry, the Company indemnifies Travelers for any losses incurred by it in connection with bonds that are issued. The Company has granted Travelers a security interest in accounts receivable and contract rights for that obligation. Guarantees The Company typically indemnifies contract owners for claims arising during the construction process and carries insurance coverage for such claims, which in the past have not been material. The Company’s Certificate of Incorporation provides for indemnification of its officers and directors. The Company has a directors and officers insurance policy that limits their exposure to litigation against them in their capacities as such. Litigation In January 2010, a jury trial was held to resolve a dispute between RHB and a subcontractor. The jury rendered a verdict of $1.0 million against RHB, exclusive of interest, court costs and attorney’s fees. The Company recorded this verdict as an expense in the year ended December 31, 2009, but appealed this judgment. The appeal was heard by the Nevada Supreme Court, and during the quarter ended September 30, 2012, the Court upheld the original verdict against RHB. The Company recorded additional expense of $156,000 during that same period to cover court costs and attorney’s fees. Payment for the total judgment, court costs and attorney’s fees was made in October 2012, and this matter is now resolved in its entirety. The Company is the subject of certain other claims and lawsuits occurring in the normal course of business. Management, after consultation with legal counsel, does not believe that the outcome of these other actions will have a material impact on the financial statements of the Company. Purchase Commitments To manage the risk of changes in material prices and subcontracting costs used in tendering bids for construction contracts, most of the time, we obtain firm quotations from suppliers and subcontractors before submitting a bid. These quotations do not include any quantity guarantees. As soon as we are advised that our bid is the lowest, we enter into firm contracts with most of our materials suppliers and sub-contractors, thereby mitigating the risk of future price variations affecting the contract costs. 13. Operating Leases The Company leases certain property and equipment under cancelable and non-cancelable agreements including office space in Texas, Utah, Nevada, Arizona and California. F25 Minimum annual rentals for all operating leases having initial non-cancelable lease terms in excess of one year are as follows (in thousands): Years Ending December 31, 2013 ........................................................... $ 2014 ........................................................... 2015 ........................................................... 2016 ........................................................... 2017 ........................................................... Thereafter .................................................. Total future minimum rental payments $ 941 688 635 580 548 2,614 6,006 Total rent expense for all operating leases amounted to approximately $1.2 million, $1.4 million, and $1.2 million in fiscal years 2012, 2011, and 2010, respectively. 14. Stockholders’ Equity Holders of common stock are entitled to one vote for each share on all matters voted upon by the stockholders, including the election of directors, and do not have cumulative voting rights. Subject to the rights of holders of any then outstanding shares of preferred stock, common stockholders are entitled to receive ratably any dividends that may be declared by the Board of Directors out of funds legally available for that purpose. Holders of common stock are entitled to share ratably in net assets upon any dissolution or liquidation after payment of provision for all liabilities and any preferential liquidation rights of our preferred stock then outstanding. Common stock shares are not subject to any redemption provisions and are not convertible into any other shares of capital stock. The rights, preferences and privileges of holders of common stock are subject to those of the holders of any shares of preferred stock that may be issued in the future. The Board of Directors may authorize the issuance of one or more classes or series of preferred stock without stockholder approval and may establish the voting powers, designations, preferences and rights and restrictions of such shares. No preferred shares have been issued. In October 2008, the Company announced a share-repurchase program to purchase up to $5 million in shares of common stock. In August 2010, the Company announced an increase to the share-repurchase program to purchase an additional $5 million in shares of common stock, for a total up to $10 million. The specific timing and amount of repurchase will vary based on market conditions, securities law limitations and other factors. During 2011, 286,000 shares were repurchased. There were no shares repurchases in 2012 or 2010. The Company accounts for the repurchase of treasury shares under the cost method. When shares are repurchased, cash is paid and the treasury stock account is debited for the price paid. Under the cost method, retirement of treasury stock would result in a debit to the common stock account for the original par value, a debit to additional paid-in capital for the excess between the par value and the original sales price, a debit to retained earnings for any excess amounts paid above the original sales price and a credit to the treasury stock account for the price paid. During 2011, one employee left the Company and forfeited 395 shares of restricted common stock. Such stock was held as treasury stock and canceled during the year. At December 31, 2012 and 2011, there was no treasury stock held by the Company. The total number of authorized shares of the Company’s common stock reserved as of December 31, 2012 for our stock-based compensation plans and warrants was 305,567. Stock Options and Grants The Company has a stock-based incentive plan that is administered by the Compensation Committee of the Board of Directors (the “2001 Plan”). The 2001 Plan provides for the issuance of stock awards for up to 1,000,000 shares of the Company’s common stock. In general, the plan provides for all stock option grants to be issued with a per-share exercise price equal to the fair market value of a share of common stock on the date of grant. The original terms of the grants typically do not exceed 10 years. Stock options generally vest over a three to five year period. The Company’s and its subsidiaries’ directors, officers, employees, consultants and advisors are eligible to be granted awards under the 2001 plan. At December 31, 2012 there were 283,367 shares of common stock available under the 2001 Plan for issuance pursuant to future stock option and share grants. No options are outstanding and no shares are or will be available for grant under the Company’s other option plans, all of which have been terminated. In May 2011, the 2001 Plan was amended to extend its term for an additional ten years. F26 The 2001 plan provides for restricted stock grants, and pursuant to non-employee director compensation arrangements, non-employee directors of the Company were awarded restricted stock with one-year vesting as follows: Years Ended December 31, 2011 2012 2010 Shares awarded to each non-employee director ......................... 5,155 Total shares awarded .................................................................. 30,930 Average grant-date market price per share .................................$ 9.70 Total compensation cost attributable to shares awarded .............$ 300,000 Compensation cost recognized related to current and prior 3,418 20,508 14.46 $ $ 297,000 3,147 25,176 15.89 $ $ 400,000 year awards ...........................................................................$ 283,333 $ 194,667 $ 283,333 In 2012, 2011 and 2010, several key employees were granted an aggregate total of 149,704, 25,815 and 10,714 shares of restricted stock, respectively, with a market value of $9.70, $12.67 and $15.89 per share, respectively, resulting in compensation expense of $1.5 million, $327,000 and $170,000, respectively, to be recognized ratably over the five-year restriction periods. The following tables summarize the stock option activity under the 2001 Plan and previously active plans: 2001 Plan Shares Outstanding at December 31, 2010 ............... 166,540 (20,333) (92,307) 53,900 (24,400) (7,300) 22,200 Exercised .................................................... Expired/forfeited ........................................ Outstanding at December 31, 2011 ............... Exercised .................................................... Expired/forfeited ........................................ Outstanding at December 31, 2012 ............... $ Weighted Average Exercise Price 14.85 2.14 24.12 3.77 3.04 9.35 3.08 The following table summarizes information about stock options outstanding and exercisable at December 31, 2012: Range of Exercise Price per Share $ 3.05 – 3.10 Number of Shares 22,200 Options Outstanding Weighted Average Remaining Contractual Life (Yrs.) 1.30 $ Weighted Average Exercise Price per Share Options Exercisable Weighted Average Exercise Price per Share Number of Shares 3.08 22,200 $ 3.08 Number of Shares Aggregate Intrinsic Value Total outstanding and vested in-the- money options at December 31, 2012 .. 22,200 Total options exercised during 2012 ........ 24,400 $ $ 148,441 176,513 For unexercised options, aggregate intrinsic value represents the total pretax intrinsic value (the difference between the Company’s closing stock price on December 31, 2012 and the exercise price, multiplied by the number of in-the-money option shares) that would have been received by the option holders had all option holders exercised their options and sold them on December 31, 2012. For options exercised during 2012, aggregate intrinsic value represents the total pretax intrinsic value based on the Company’s closing stock price on the day of exercise. At December 31, 2012, total unrecognized compensation cost related to restricted stock was $1.3 million. This cost is expected to be recognized over a weighted average period of 2.1 years. Pre-tax compensation expense for stock options and restricted stock grants was $694,000 ($451,000 after tax benefit of 35%), $503,000 ($327,000 F27 after tax benefit of 35%), and $594,000 ($386,000 after tax benefit of 35.0%), in 2012, 2011 and 2010, respectively. Proceeds received by the Company from the exercise of options in 2012, 2011 and 2010 were $66,000, $43,000, and $692,000, respectively. At December 31, 2012, there was no unrecognized stock-based compensation expense related to stock options. Warrants Warrants attached to zero coupon notes were issued to certain members of management and to certain stockholders in 2001. These ten-year warrants to purchase shares of the Company’s common stock at $1.50 per share became exercisable 54 months from the July 2001 issue date, except that one warrant covering 322,661 shares by amendment became exercisable forty-two months from the issue date. These warrants were fully exercised prior to their 2011 expiration date. The following table shows the warrant shares outstanding and the proceeds that have been received by the Company from exercises during the three years ended December 31, 2012. Shares Warrants outstanding on January 1, 2010 ....................... 314,412 Warrants exercised in 2010 ............................................. 238,981 Warrants exercised in 2011 ............................................. 75,431 -- Warrants exercised in 2012 ............................................. Warrants Exercised Company’s Proceeds from Exercise 33,330 358,471 113,147 -- Year-End Warrant Share Balance 334,046 75,431 -- -- $ $ $ $ 15. Employee Benefit Plans The Company and its subsidiaries maintain a defined contribution profit-sharing plan (401(k)) covering substantially all non-union persons employed by the Company and its subsidiaries, whereby employees may contribute a percentage of compensation, limited to maximum allowed amounts under the Internal Revenue Code. The Plan provides for discretionary employer contributions, the level of which, if any, may vary by subsidiary and is determined annually by each company’s board of directors. The Company made aggregate matching contributions of $570,000, $573,000, and $430,000 for the years ended December 31, 2012, 2011, and 2010, respectively. The Company contributes to a number of multiemployer defined benefit pension plans under the terms of collective-bargaining agreements that cover its union-represented employees. The risks of participating in these multiemployer plans are different from single-employer plans in the following aspects: Assets contributed to the multiemployer plan by one employer may be used to provide benefits to employees of other participating employers. If a participating employer stops contributing to the plan, the unfunded obligations of the plan may be borne by the remaining participating employers. If the Company chooses to stop participating in some of its multiemployer plans, the Company may be required to pay those plans an amount based on the underfunded status of the plan, referred to as a withdrawal liability. F28 The following table presents our participation in these plans (dollars in thousands): Pension Plan Employer Identification Number Pension Protection Act (“PPA”) Certified Zone Status1 2012 2011 FIP / RP Status Pending / Implemented2 Contributions 2011 2012 2010 Expiration Date of Collective Bargaining Agreement3 Surcharge Imposed 94-6090764 Orange Orange Yes $ 508 $ 246 $ 193 No 86-6025732 Yellow Yellow Yes 560 121 -- No 6/30/2008 - 6/30/2014 1/1/2012 - 5/31/2013 94-6277608 Yellow Yellow Yes 431 64 -- No N/A5 94-6277669 Yellow Yellow Yes 265 46 -- No 1,307 Total Contributions: $ 5,541 $ 2,542 $ 1,500 2,065 3,777 6/16/09 – 6/15/13 Various Pension Trust Fund Pension Trust Fund for Operating Engineers Pension Plan .................... Operating Engineers Local 428 Pension Trust Fund ........... Laborers Pension Trust for Northern California ... Cement Mason Pension Trust Fund For Northern California ... All other funds (41)4 .... 1The most recent PPA zone status available in 2012 and 2011 is for the plan’s year-end during 2011 and 2010, respectively. The zone status is based on information that we received from the plan and is certified by the plan’s actuary. Among other factors, plans in the red zone are generally less than 65 percent funded, plans in the orange zone are less than 80 percent funded and have an Accumulated Funding Deficiency in the current year or projected into the next six years, plans in the yellow zone are less than 80 percent funded, and plans in the green zone are at least 80 percent funded. 2Indicates whether the plan has a financial improvement plan (“FIP”) or a rehabilitation plan (“RP”) which is either pending or has been implemented. 3Lists the expiration date(s) of the collective-bargaining agreement(s) to which the plans are subject. 4These funds include multiemployer plans for pensions and other employee benefits. The total individually insignificant multiemployer pension costs contributed were $466,000, $299,000 and $37,000 for 2012, 2011, and 2010, respectively, and are included in the contributions to all other funds along with contributions to other types of benefit plans. Other employee benefits include certain coverage for medical, prescription drug, dental, vision, life and accidental death and dismemberment, disability and other benefit costs. Due to our 2011 acquisitions (see Note 2) there has been an increase in the number of Sterling employees that participate in multiemployer plans affecting the comparability between 2012, 2011 and 2010 years. The acquisitions occurred August 1, 2011 and resulted in five months of pension and other retirement expenses in that year. During 2012, the Company incurred the entire year of expenses and there were no pension and other retirement expenses related to the acquisitions during 2010 5The expiration of the collective bargaining agreement related to this pension fund was not available at the time of our filing. We currently have no intention of withdrawing from any of the multi-employer pension plans in which we participate. F29 16. Customers The following table shows contract revenues generated from the Company’s customers that accounted for more than 10% of revenues (dollars in thousands): Years Ended December 31, 2012 2011 2010 Amount % Amount % Amount % Texas Department of Transportation (“TxDOT”) ............................................ $ * *% $ 75,818 15.1% $ 95,198 20.7% Utah Department of Transportation (“UDOT”) ............................................. 100,658 16.0 144,398 28.8 120,492 26.2 California Department of Transportation (“Caltrans”) ........................................... *Represents less than 10% of revenues 94,171 15.0 * * * * At December 31, 2012, the North Texas Tollway Authority (“NTTA”) owed $8.8 million to the Company, which is greater than 10% of contract receivables. At December 31, 2011, UDOT owed $8.8 million to the Company, which is greater than 10% of contract receivables. At December 31, 2010, TxDOT ($10.8 million), UDOT ($10.1 million), and the Utah Transit Authority ($9.6 million) each owed balances to the Company greater than 10% of contract receivables. 17. Related Party Transactions RLW has historically performed construction contracts for entities owned by its noncontrolling interest owners. These noncontrolling interest owners are also executive managers of RLW, including Mr. Kip Wadsworth who is a member of the board of directors of the Company. During 2011, the Company recognized approximately $283,000 in revenue and $46,000 in gross profit from a few smaller projects owned by the noncontrolling interest owners’ privately-owned entities. These related party contracts had a total contract value of $3.2 million. Collections on account related to these projects during 2011 approximated $525,000. During 2011, one of these contractors filed for bankruptcy and as a result $24,000 billed to such entity was deemed uncollectible. Total related party contract amounts for 2012 were less than $102,000. The noncontrolling interest owners are also majority owners of a company with which RLW has a service agreement to provide monthly professional and other services (accounting, payroll, reimbursement, computer and postage) for which RLW is reimbursed on a monthly basis. Billings for these services totaled $1.0 million in 2012 and $615,000 in 2011. The Company leases its main office for its Utah operations from a second company which is 98% owned by these owners for $228,500 annually plus common area maintenance charges of $80,800 per year. The office lease expires in 2022. In addition, the Company leases its equipment maintenance shop for its Utah operations from a third company, which is 98% owned by those owners, for $178,300 annually, plus common area maintenance charges of $71,700 per year. The shop lease expires in 2022. The Company also leases field housing for its Utah operations from a company owned by the noncontrolling interest owners for $47,000 annually. This lease expires in 2014. During 2012 and 2011, the Company also paid $52,000 and $72,300, respectively, for aircraft services to a company owned 100% by the noncontrolling interest owners of RLW. In June 2012, RLW signed a lease for eighteen months with KIWA Properties LLC for the use of property located in Mesa, Arizona to be used in conjunction with one of RLW’s construction contracts. KIWA Properties LLC is owned by the former owner of JBC who has continued as an employee of JBC. JBC leases office and shop space from the former owner who has continued as an employee of JBC. Monthly rent is approximately $8,000, and the leases expire in August 2016. Rentals under these leases totaled $95,000 and $40,000 in 2012 and 2011, respectively. During 2012, the Company paid $34,000 for aircraft service to a company owned 100% by the noncontrolling interest owner of RHB. During 2012 and 2011, the Company paid approximately $243,000 and $274,000 to businesses owned by family members of Myers’ management for services, materials and partnership distributions. The Company entered into a business combination with Richard Buenting, the President and Chief Executive Officer of RHB. Refer to Note 2 for a description of the related party transaction. An independent member of senior management of the Company reviewed all related party purchases before they were transacted. F30 18. Quarterly Financial Information (amounts in thousands, except per share data) March 31 Revenues................................................... $ 98,425 Gross profit ............................................... Income (loss) before income taxes and 1,873 2012 Quarters Ended (unaudited) June 30 $ 168,709 15,159 September 30 205,284 $ 14,170 December 31 158,089 $ 16,270 Total $ 630,507 47,472 earnings attributable to noncontrolling interests ................................................. Net income (loss) attributable to Sterling common stockholders ........................... Net income (loss) per share attributable to Sterling common stockholders: (3,781) (7,500) 8,652 3,287 4,915 990 7,347 17,133 2,926 (297) Basic ..................................................$ Diluted ............................................... (0.44) (0.44) $ $ 0.15 0.15 $ 0.01 0.01 $ 0.01 0.01 (0.26) (0.26) 2011 Quarters Ended (unaudited) March 31 June 30 September 30 December 31 Total Revenues................................................... $ 99,242 Gross profit ............................................... Income (loss) before income taxes and 7,599 $ 128,498 $ 159,427 $ 113,989 13,582 14,756 3,900 $ 501,156 39,837 earnings attributable to noncontrolling interests ................................................. Net income (loss) attributable to Sterling common stockholders ........................... Net income (loss) per share attributable to Sterling common stockholders: 1,648 44 7,437 4,211 7,925 3,461 (68,726 ) (51,716) (43,616) (35,900) Basic ..................................................$ Diluted ............................................... $ 0.00 0.00 $ 0.26 0.25 $ 0.21 0.21 (2.72) (2.72) $ (2.24) (2.24) During the fourth quarter of 2011, the Company completed an evaluation of the carrying value of goodwill resulting in an impairment charge of $67.0 million. This charge had an impact of $41.8 million on the net loss attributable to Sterling common stockholders (net of the related tax benefits and reduced for the amount attributable to noncontrolling interest owners) or $2.55 per diluted share. During the fourth quarter of 2011, changes in estimated revenues and gross margin resulted in a net charge of $5.9 million included in the operating loss and a $4.2 million after-tax charge, or $0.26 per diluted share attributable to Sterling common stockholders, included in net loss attributable to Sterling common stockholders. During the first quarter of 2012, the Company recorded a $4.4 million after-tax charge, or $0.27 per diluted share attributable to Sterling common shareholders, related to an agreement with the noncontrolling interest owners of RLW to exclude the impact of any goodwill impairment from earning attributable to such owners. F31 20810 Fernbush Lane • Houston, Texas 77073 • 281-821-9091 www.sterlingconstructionco.com
Continue reading text version or see original annual report in PDF format above